HomeMy WebLinkAbout193-20 RESOLUTION113 West Mountain Street
Fayetteville, AR 72701
(479) 575-8323
Resolution: 193-20
File Number: 2020-0496
MCCLELLAND CONSULTING ENGINEERS. INC. - 2019 TRANSPORTATION BOND
PROJECT:
A RESOLUTION TO APPROVE A PROFESSIONAL ENGINEERING SERVICES
AGREEMENT WITH MCCLELLAND CONSULTING ENGINEERS, INC. IN THE AMOUNT
OF $85,894.00 TO PROVIDE CONSTRUCTION PHASE SERVICES AND MATERIALS
TESTING ASSOCIATED WITH THE ZION ROAD - VANTAGE TO CROSSOVER PROJECT,
AND TO APPROVE A BUDGET ADJUSTMENT - 2019 TRANSPORTATION BOND
PROJECT
BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF FAYETTEVILLE,
ARKANSAS:
Section 1: That the City Council of the City of Fayetteville, Arkansas hereby authorizes Mayor Jordan
to sign a professional engineering services agreement with McClelland Consulting Engineers, Inc. in the
amount of $85,894.00 to provide construction phase services and materials testing associated with the
Zion Road - Vantage to Crossover Project.
Section 2: That the City Council of the City of Fayetteville, Arkansas hereby approves a budget
adjustment, a copy of which is attached to this Resolution.
PASSED and APPROVED on 7/21/2020
Page 1 Printed on 7123120
Resolution: 193-20
File Number.' 2020-0496
Attest: `11111 i 1111 pif
F-RK
FAYETTEVILLE
Kara Paxton, City Clerk Treasurer
Page 2 Printed on 7123120
City of Fayetteville, Arkansas 113 West Mountain Street
Fayetteville, AR 72701
(479) 575-8323
Text File
File Number: 2020-0496
Agenda Date: 7/21/2020 Version: 1 Status: Passed
In Control: City Council Meeting File Type: Resolution
Agenda Number: C. 1
MCCLELLAND CONSULTING ENGINEERS. INC. - 2019 TRANSPORTATION BOND
PROJECT:
A RESOLUTION TO APPROVE A PROFESSIONAL ENGINEERING SERVICES AGREEMENT
WITH MCCLELLAND CONSULTING ENGINEERS, INC. IN THE AMOUNT OF $85,894.00 TO
PROVIDE CONSTRUCTION PHASE SERVICES AND MATERIALS TESTING ASSOCIATED WITH
THE ZION ROAD - VANTAGE TO CROSSOVER PROJECT, AND TO APPROVE A BUDGET
ADJUSTMENT - 2019 TRANSPORTATION BOND PROJECT
BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF FAYETTEVILLE, ARKANSAS:
Section 1: That the City Council of the City of Fayetteville, Arkansas hereby authorizes Mayor Jordan to sign a
professional engineering services agreement with McClelland Consulting Engineers, Inc. in the amount of
$85,894.00 to provide construction phase services and materials testing associated with the Zion Road -
Vantage to Crossover Project.
Section 2: That the City Council of the City of Fayetteville. Arkansas hereby approves a budget adjustment. a
copy of which is attached to this Resolution.
City of Fayetteville, Arkansas Page 1 Printed on 7/22/2020
Matt Casey
City of Fayetteville Staff Review Form
2020-0496
Legistar File ID
7/21/2020
City Council Meeting Date - Agenda Item Only
N/A for Non -Agenda Item
ENGINEERING (621)
Submitted By Submitted Date Division / Department
Action Recommendation:
6/17/2020
Approval of a contract amendment for construction phase services and materials testing in the amount of
$85,894.00 with McClelland Consulting Engineers, Inc. for the Zion Road — Vantage to Crossover Project and
approval of a budget adjustment.
4602.860.7212-5860.02
5400.720.5700-5314.00
Account Number
46020.7212
06035.2750
Project Number
Budgeted Item? Yes
Does item have a cost? Yes
Budget Adjustment Attached? Yes
Budget Impact:
4602 - Streets Bond Projects
5400 - Water and Sewer Capital Fund
Fund
Streets Bond Projects, Zion Rd. Improvements
Current Budget
Funds Obligated
Current Balance
Item Cost
Budget Adjustment
Remaining Budget
Project Title
$ 27,301.43
$ 27,301.43
$ 85,894.00
$ 85,894.00
$ 27,301.43
V20180321
Purchase Order Number: 2019-00000609 Previous Ordinance or Resolution # 1 S 19
Change Order Number:
Original Contract Number:
Approval Date:
Comments: Transportation Bond ($52,794.00) Water and Sewer Fund ($33,100.00)
CITY OF
FAYETTEVILLE
%PF ARKANSAS
MEETING OF JULY 21, 2020
TO: Mayor and City Council
THRU: Susan Norton, Chief of Staff
Garner Stoll, Development Services Director
Chris Brown, City Engineer
FROM: Matt Casey, Engineering Design Manager
DATE: June 25, 2020
CITY COUNCIL MEMO
SUBJECT: Approval of a contract amendment for construction phase services and
materials testing in the amount of $85,894.00 with McClelland Consulting
Engineers, Inc. for the Zion Road — Vantage to Crossover Project and
approval of a budget adjustment.
RECOMMENDATION:
Approval of a contract amendment for construction phase services and materials testing in the
amount of $85,894.00 with McClelland Consulting Engineers, Inc. (MCE) for the Zion Road —
Vantage to Crossover Project and approval of a budget adjustment.
BACKGROUND:
Zion Road from College Avenue to Highway 265 was included in the previous Transportation
Improvement Bond Program. The first phase of construction between College Avenue and
Vantage Drive was completed in 2008. In 2013, the second phase, between Vantage Drive and
Highway 265, was approved for funding through the bond program. On May 6, 2014, the
Fayetteville City Council approved a contract with MCE. for the design of the second phase of
Zion Road. The design was completed in early 2015, but there were not sufficient bond funds
remaining at the time to fully fund the construction of the project.
On July 16, 2019, the Council approved a contract with MCE to update the plans to include a
revised cross section consisting of a three -lane section with a 10' wide multi -use trail on the
north side and a 6' wide sidewalk on the south side. On January 7, 2020, the Council approved
a contract amendment to include lighting and tree planting in the design scope.
The project bid opening is scheduled for 6/24/20. The construction contract is planned to be
presented to the City Council for consideration at the July 21, 2020 city council meeting.
DISCUSSION:
The approved contract with MCE does not include construction phase services and materials
testing. Staff has worked with MCE to develop a scope that will include support for the
contractor and city staff as needed through the construction of this project In addition, they will
provide as -built plans at the end of the job documenting any field changes made during
Mailing Address:
113 W. Mountain Street www.fayetteville-ar.gov
Fayetteville, AR 72701
construction. MCE has provided a fee in the amount of $85,894.00 for this additional work. The
contract will be paid based on hourly rates for work completed, up to the total contract amount.
BUDGET/STAFF IMPACT:
This contract amendment and the construction of the project will be funded by the 2019
Transportation Bond Program ($52,794.00) and the Water and Sewer Fund ($33,100.00). A
budget adjustment is included with this council item.
Attachments:
Engineering Agreement
Vicinity Map
AGREEMENT
For
PROFESSIONAL ENGINEERING SERVICES
Between
CITY OF FAYETTEVILLE, ARKANSAS
And
MCCLELLAND CONSULTING ENGINEERS, INC.
THIS AGREEMENT is made as of 2020 by and between City of
Fayetteville, Arkansas, acting by and through its Mayor (hereinafter called CITY OF FAYETTEVILLE)
and MCCLELLAND CONSULTING ENGINEERS (hereinafter called ENGINEER).
CITY OF FAYETTEVILLE from time to time requires professional engineering services in connection
with the evaluation, design, and/or construction supervision of capital improvement projects. Therefore,
CITY OF FAYETTEVILLE and ENGINEER in consideration of their mutual covenants agree as follows:
ENGINEER shall serve as CITY OF FAYETTEVILLE's professional engineering consultant in those
assignments to which this Agreement applies, and shall give consultation and advice to CITY OF
FAYETTEVILLE during the performance of ENGINEER's services. All services shall be performed
under the direction of a professional engineer registered in the State of Arkansas and qualified in the
particular field.
SECTION 1 - Al'"I 10RIZATION OF SERVICES
1.1 Services on any assignment shall be undertaken only upon written Authorization of CITY OF
FAYETTEVILLE and agreement of ENGINEER.
1.2 Assignments may include services described hereafter as Basic Services or as Additional Services
of ENGINEER.
1.3 Changes, modifications or amendments in scope, price or fees to this contract shall not be
allowed without a formal contract amendment approved by the Mayor and the City Council in
advance of the change in scope, costs, fees, or delivery schedule.
SECTION 2 - BASIC SERVICES OF ENGINEER
2.1 Perform professional services in connection with the Project as hereinafter stated.
2.1.1 The Scope of Services to be furnished by ENGINEER during the Project is included in Appendix
A.1 & A.2 attached hereto and made part of this Agreement.
2.2 ENGINEER shall coordinate their activities and services with the CITY OF FAYETTEVILLE.
ENGINEER and CITY OF FAYETTEVILLE agree that ENGINEER has full responsibility for
the engineering services.
Zion Road; Construction Related Services
Meadow View Drive to North Crossover (Hwy 265)
SECTION 3 - RESPONSIBILITIES OF CITY OF FAYETTEVILLE
3.1 CITY OF FAYETTEVILLE shall, within a reasonable time, so as not to delay the services of
ENGINEER.
3.1.1 Provide full information as to CITY OF FAYETTEVILLE's requirements for the Project.
3.1.2 Assist ENGINEER by placing at ENGINEER's disposal all available information pertinent to
the assignment including previous reports and any other data relative thereto.
3.1.3 Assist ENGINEER in obtaining access to property reasonably necessary for ENGINEER to
perform its services under this Agreement.
3.1.4 Examine all studies, reports, sketches, cost opinions, proposals, and other documents
presented by ENGINEER and render in writing decisions pertaining thereto.
3.1.5 The City Engineer is the CITY OF FAYETTEVILLE's project representative with respect to
the services to be performed under this Agreement. The City Engineer shall have complete
authority to transmit instructions, receive information, interpret and define CITY OF
FAYETTEVILLE's policies and decisions with respect to materials, equipment, elements and
systems to be used in the Project, and other matters pertinent to the services covered by this
Agreement.
3.1.6 CITY OF FAYETTEVILLE and/or its representative will review all documents and provide
written comments to ENGINEER in a timely manner.
SECTION 4 - PERIOD OF SERVICE
4.1 This Agreement will become effective upon the first written notice by CITY OF
FAYETTEVILLE authorizing services hereunder.
4.2 The provisions of this Agreement have been agreed to in anticipation of the orderly progress of
the Project through completion of the services stated in the Agreement. ENGINEER will proceed
with providing the authorized services immediately upon receipt of written authorization from
CITY OF FAYETTEVILLE. Said authorization shall include the scope of the services
authorized and the time in which the services are to be completed, effective at commencement of
project construction.
SECTION 5 - PAYMENTS TO ENGINEER
5.1 The CITY OF FAYETTEVILLE shall compensate ENGINEER based on an hourly NTE basis
described in Appendix C.
5.2 Statements
5.2.1 Monthly statements for each calendar month shall be submitted to CITY OF
FAYETTEVILLE or such parties as CITY OF FAYETTEVILLE may designate for
professional services consistent with ENGINEER's normal billing schedule. Once
established, the billing schedule shall be maintained throughout the duration of the Project.
Applications for payment shall be made in accordance with a format to be developed by
ENGINEER and approved by CITY OF FAYETTEVILLE. Applications for payment shall
be accompanied each month by the updated project schedule as the basis for determining the
Zion Road; Construction Related Services
Meadow View Drive to North Crossover (Hwy 265) 2
value earned as the work is accomplished. Final payment for professional services shall be
made upon CITY OF FAYETTEVILLE's approval and acceptance with the satisfactory
completion of the study and report for the Project.
5.3 Payments
5.3.1 All statements are payable upon receipt and due within thirty (30) days. If a portion of
ENGINEER's statement is disputed by CITY OF FAYETTEVILLE, the undisputed portion
shall be paid by CITY OF FAYETTEVILLE by the due date. CITY OF FAYETTEVILLE
shall advise ENGINEER in writing of the basis for any disputed portion of any statement.
CITY OF FAYETTEVILLE will make reasonable effort to pay invoices within 30 days of
date the invoice is approved, however, payment within 30 days is not guaranteed.
5.4 Final Payment
5.4.1 Upon satisfactory completion of the work performed under this Agreement, as a condition
before final payment under this Agreement, or as a termination settlement under this
Agreement, ENGINEER shall execute and deliver to CITY OF FAYETTEVILLE a release of
all claims against CITY OF FAYETTEVILLE arising under or by virtue of this Agreement,
except claims which are specifically exempted by ENGINEER to be set forth therein. Unless
otherwise provided in this Agreement or by State law or otherwise expressly agreed to by the
parties to this Agreement, final payment under this Agreement or settlement upon termination
of this Agreement shall not constitute a waiver of CITY OF FAYETTEVILLE's claims
against ENGINEER or his sureties under this Agreement or applicable performance and
payment bonds, if any.
SECTION 6 - GENERAL CONSIDERATIONS
6.1 Insurance
6.1.1 During the course of performance of these services, ENGINEER will maintain (in United
States Dollars) the following minimum insurance coverages:
Type of Coverage
Workers' Compensation
Employers' Liability
Commercial General Liability
Bodily Injury and
Property Damage
Automobile Liability:
Bodily Injury and
Property Damage
Professional Liability Insurance
Limits of Liability
Statutory
$500,000 Each Accident
$1,000,000 Combined Single Limit
$1,000,000 Combined Single Limit
$1,000,000 Each Claim
ENGINEER will provide to CITY OF FAYETTEVILLE certificates as evidence of the
specified insurance within ten days of the date of this Agreement and upon each renewal of
coverage.
Zion Road; Construction Related Services
Meadow View Drive to North Crossover (Hwy 265)
6.1.2 CITY OF FAYETTEVILLE and ENGINEER waive all rights against each other and their
officers, directors, agents, or employees for damage covered by property insurance during
and after the completion of ENGINEER's services.
6.2 Professional Responsibility
6.2.1 ENGINEER will exercise reasonable skill, care, and diligence in the performance of
ENGINEER's services and will carry out its responsibilities in accordance with customarily
accepted professional engineering practices. CITY OF FAYETTEVILLE will promptly
report to ENGINEER any defects or suspected defects in ENGINEER's services of which
CITY OF FAYETTEVILLE becomes aware, so that ENGINEER can take measures to
minimize the consequences of such a defect. CITY OF FAYETTEVILLE retains all
remedies to recover for its damages caused by any negligence of ENGINEER.
6.3 Cost Opinions and Projections
6.3.1 Cost opinions and projections prepared by ENGINEER relating to construction costs and
schedules, operation and maintenance costs, equipment characteristics and performance, and
operating results are based on ENGINEER's experience, qualifications, and judgment as a
design professional. Since ENGINEER has no control over weather, cost and availability of
labor, material and equipment, labor productivity, construction Contractors' procedures and
methods, unavoidable delays, construction Contractors' methods of determining prices,
economic conditions, competitive bidding or market conditions, and other factors affecting
such cost opinions or projections, ENGINEER does not guarantee that actual rates, costs,
performance, schedules, and related items will not vary from cost opinions and projections
prepared by ENGINEER.
6.4 Changes
6.4.1 CITY OF FAYETTEVILLE shall have the right to make changes within the general scope of
ENGINEER's services, with an appropriate change in compensation and schedule only after
Fayetteville City Council approval of such proposed changes and, upon execution of a
mutually acceptable amendment or change order signed by the Mayor of the CITY OF
FAYETTEVILLE and the duly authorized officer of ENGINEER.
6.5 Termination
6.5.1 This Agreement may be terminated in whole or in part in writing by either party in the event
of substantial failure by the other party to fulfill its obligations under this Agreement through
no fault of the terminating party, provided that no termination may be effected unless the
other party is given:
6.5.1.1 Not less than ten (10) calendar days written notice (delivered by certified mail, return
receipt requested) of intent to terminate,
6.5.1.2 An opportunity for consultation with the terminating party prior to termination.
Zion Road; Construction Related Services
Meadow View Drive to North Crossover (Hwy 265) 4
6.5.2 This Agreement may be terminated in whole or in part in writing by CITY OF
FAYETTEVILLE for its convenience, provided that ENGINEER is given:
6.5.2.1 Not less than ten (10) calendar days written notice (delivered by certified mail, return
receipt requested) of intent to terminate,
6.5.2.2 An opportunity for consultation with the terminating party prior to termination.
6.5.3 If termination for default is effected by CITY OF FAYETTEVILLE, an equitable adjustment
in the price provided for in this Agreement shall be made, but
6.5.3.1 No amount shall be allowed for anticipated profit on unperformed services or other work,
6.5.3.2 Any payment due to ENGINEER at the time of termination may be adjusted to cover any
additional costs to CITY OF FAYETTEVILLE because of ENGINEER's default.
6.5.4 If termination for default is effected by ENGINEER, or if termination for convenience is
effected by CITY OF FAYETTEVILLE, the equitable adjustment shall include a reasonable
profit for services or other work performed. The equitable adjustment for any termination
shall provide for payment to ENGINEER for services rendered and expenses incurred prior to
the termination, in addition to termination settlement costs reasonably incurred by
ENGINEER relating to commitments which had become firm prior to the termination.
6.5.5 Upon receipt of a termination action under Paragraphs 6.5.1 or 6.5.2 above, ENGINEER
shall:
6.5.5.1 Promptly discontinue all affected work (unless the notice directs otherwise),
6.5.5.2 Deliver or otherwise make available to CITY OF FAYETTEVILLE all data, drawings,
specifications, reports, estimates, summaries and such other information and materials as
may have been accumulated by ENGINEER in performing this Agreement, whether
completed or in process.
6.5.6 Upon termination under Paragraphs 6.5.1 or 6.5.2 above CITY OF FAYETTEVILLE may
take over the work and may award another party an agreement to complete the work under
this Agreement.
6.5.7 If, after termination for failure of ENGINEER to fulfill contractual obligations, it is
determined that ENGINEER had not failed to fulfill contractual obligations, the termination
shall be deemed to have been for the convenience of CITY OF FAYETTEVILLE. In such
event, adjustments of the agreement price shall be made as provided in Paragraph 6.5.4 of
this clause.
6.6 Delays
6.6.1 In the event the services of ENGINEER are suspended or delayed by CITY OF
FAYETTEVILLE or by other events beyond ENGINEER's reasonable control, ENGINEER
shall be entitled to additional compensation and time for reasonable costs incurred by
ENGINEER in temporarily closing down or delaying the Project.
Zion Road; Construction Related Services
Meadow View Drive to North Crossover (Hwy 265)
6.7 Rights and Benefits
6.7.1 ENGINEER's services will be performed solely for the benefit of CITY OF
FAYETTEVILLE and not for the benefit of any other persons or entities.
6.8 Dispute Resolution
6.8.1 Scope of Paragraph: The procedures of this Paragraph shall apply to any and all disputes
between CITY OF FAYETTEVILLE and ENGINEER which arise from, or in any way are
related to, this Agreement, including, but not limited to the interpretation of this Agreement,
the enforcement of its terms, any acts, errors, or omissions of CITY OF FAYETTEVILLE or
ENGINEER in the performance of this Agreement, and disputes concerning payment.
6.8.2 Exhaustion of Remedies Required: No action may be filed unless the parties first negotiate.
If timely Notice is given under Paragraph 6.8.3, but an action is initiated prior to exhaustion
of these procedures, such action shall be stayed, upon application by either party to a court of
proper jurisdiction, until the procedures in Paragraphs 6.8.3 and 6.8.4 have been complied
with.
6.8.3 Notice of Dispute
6.8.3.1 For disputes arising prior to the making of final payment promptly after the occurrence of
any incident, action, or failure to act upon which a claim is based, the party seeking relief
shall serve the other party with a written Notice.
6.8.3.2 For disputes arising within one year after the making of final payment, CITY OF
FAYETTEVILLE shall give ENGINEER written Notice at the address listed in
Paragraph 6.14 within thirty (30) days after occurrence of any incident, accident, or first
observance of defect or damage. In both instances, the Notice shall specify the nature
and amount of relief sought, the reason relief should be granted, and the appropriate
portions of this Agreement that authorize the relief requested.
6.8.4 Negotiation: Within seven days of receipt of the Notice, the Project Managers for CITY OF
FAYETTEVILLE and ENGINEER shall confer in an effort to resolve the dispute. If the
dispute cannot be resolved at that level, then, upon written request of either side, the matter
shall be referred to the President of ENGINEER and the Mayor of CITY OF
FAYETTEVILLE or his designee. These officers shall meet at the Project Site or such other
location as is agreed upon within 30 days of the written request to resolve the dispute.
6.9 CITY OF FAYETTEVILLE represents that it has sufficient funds or the means of obtaining
funds to remit payment to ENGINEER for services rendered by ENGINEER.
6.10 Publications
6.10.1 Recognizing the importance of professional development on the part of ENGINEER's
employees and the importance of ENGINEER's public relations, ENGINEER may prepare
publications, such as technical papers, articles for periodicals, and press releases, pertaining
to ENGINEER's services for the Project. Such publications will be provided to CITY OF
FAYETTEVILLE in draft form for CITY OF FAYETTEVILLE's advance review. CITY OF
FAYETTEVILLE shall review such drafts promptly and provide CITY OF
FAYETTEVILLE's comments to ENGINEER CITY OF FAYETTEVILLE may require
Zion Road; Construction Related Services
Meadow View Drive to North Crossover (Hwy 265) 6
deletion of proprietary data or confidential information from such publications, but otherwise
CITY OF FAYETTEVILLE will not unreasonably withhold approval. The cost of
ENGINEER's activities pertaining to any such publication shall be for ENGINEER's
account.
6.11 Indemnification
6.11.1 CITY OF FAYETTEVILLE agrees that it will require all construction Contractors to
indemnify, defend, and hold harmless CITY OF FAYETTEVILLE and ENGINEER from and
against any and all loss where loss is caused or incurred or alleged to be caused or incurred in
whole or in part as a result of the negligence or other actionable fault of the Contractors, or
their employees, agents, Subcontractors, and Suppliers.
6.12 Ownership of Documents
6.12.1 All documents provided by CITY OF FAYETTEVILLE including original drawings, CAD
drawings, estimates, field notes, and project data are and remain the property of CITY OF
FAYETTEVILLE. ENGINEER may retain reproduced copies of drawings and copies of
other documents.
6.12.2 Engineering documents, computer models, drawings, specifications and other hard copy or
electronic media prepared by ENGINEER as part of the Services shall become the property
of CITY OF FAYETTEVILLE when ENGINEER has been compensated for all Services
rendered, provided, however, that ENGINEER shall have the unrestricted right to their use.
ENGINEER shall, however, retain its rights in its standard drawings details, specifications,
databases, computer software, and other proprietary property. Rights to intellectual property
developed, utilized, or modified in the performance of the Services shall remain the property
of ENGINEER.
6.12.3 Any files delivered in electronic medium may not work on systems and software different
than those with which they were originally produced. ENGINEER makes no warranty as to
the compatibility of these files with any other system or software. Because of the potential
degradation of electronic medium over time, in the event of a conflict between the sealed
original drawings/hard copies and the electronic files, the sealed drawings/hard copies will
govern.
6.13 Notices
6.13.1 Any Notice required under this Agreement will be in writing, addressed to the appropriate
party at the following addresses:
CITY OF FAYETTEVILLE's address:
113 West Mountain Street
Fayetteville, Arkansas 72701
MCCLELLAND CONSULTING ENGINEER's address:
1810 N. College Avenue
Fayetteville, Arkansas 72701
Zion Road; Construction Related Services
Meadow View Drive to North Crossover (Hwy 265) 7
6.14 Successor and Assigns
6.14.1 CITY OF FAYETTEVILLE and ENGINEER each binds himself and his successors,
executors, administrators, and assigns to the other party of this Agreement and to the
successors, executors, administrators, and assigns of such other party, in respect to all
covenants of this Agreement; except as above, neither CITY OF FAYETTEVILLE nor
ENGINEER shall assign, sublet, or transfer his interest in the Agreement without the written
consent of the other.
6.15 Controlling Law
6.15.1 This Agreement shall be subject to, interpreted and enforced according to the laws of the
State of Arkansas without regard to any conflicts of law provisions.
6.16 Entire Agreement
6.16.1 This Agreement represents the entire Agreement between ENGINEER and CITY OF
FAYETTEVILLE relative to the Scope of Services herein. Since terms contained in
purchase orders do not generally apply to professional services, in the event CITY OF
FAYETTEVILLE issues to ENGINEER a purchase order, no preprinted terms thereon shall
become a part of this Agreement. Said purchase order document, whether or not signed by
ENGINEER, shall be considered as a document for CITY OF FAYETTEVILLE's internal
management of its operations.
SECTION 7 - SPECIAL CONDITIONS
7.1 Additional Responsibilities of ENGINEER
7.1.1 CITY OF FAYETTEVILLE's review, approval, or acceptance of design drawings,
specifications, reports and other services furnished hereunder shall not in any way relieve
ENGINEER of responsibility for the technical adequacy of the work. Neither CITY OF
FAYETTEVILLE's review, approval or acceptance of, nor payment for any of the services
shall be construed as a waiver of any rights under this Agreement or of any cause of action
arising out of the performance of this Agreement.
7.1.2 ENGINEER shall be and shall remain liable, in accordance with applicable law, for all
damages to CITY OF FAYETTEVILLE caused by ENGINEER's negligent performance of
any of the services furnished under this Agreement except for errors, omissions or other
deficiencies to the extent attributable to CITY OF FAYETTEVILLE or CITY OF
FAYETTEVILLE-furnished data.
7.1.3 ENGINEER's obligations under this clause are in addition to ENGINEER's other express or
implied assurances under this Agreement or State law and in no way diminish any other
rights that CITY OF FAYETTEVILLE may have against ENGINEER for faulty materials,
equipment, or work.
7.2 Remedies
7.2.1 Except as may be otherwise provided in this Agreement, all claims, counter -claims, disputes
and other matters in question between CITY OF FAYETTEVILLE and ENGINEER arising
Zion Road; Construction Related Services
Meadow View Drive to North Crossover (Hwy 265) 8
out of or relating to this Agreement or the breach thereof will be decided in a court of
competent jurisdiction within Arkansas.
7.3 Audit: Access to Records
7.3.1 ENGINEER shall maintain books, records, documents and other evidence directly pertinent
to performance on work under this Agreement in accordance with generally accepted
accounting principles and practices consistently applied in effect on the date of execution of
this Agreement. ENGINEER shall also maintain the financial information and data used by
ENGINEER in the preparation of support of the cost submission required for any negotiated
agreement or change order and send to CITY OF FAYETTEVILLE a copy of the cost
summary submitted. CITY OF FAYETTEVILLE, the State or any of their authorized
representatives shall have access to all such books, records, documents and other evidence for
the purpose of inspection, audit and copying during normal business hours. ENGINEER will
provide proper facilities for such access and inspection.
7.3.2 Records under Paragraph 7.3.1 above, shall be maintained and made available during
performance on assisted work under this Agreement and until three years from the date of
final payment for the project. In addition, those records which relate to any controversy
arising out of such performance, or to costs or items to which an audit exception has been
taken, shall be maintained and made available until three years after the date of resolution of
such appeal, litigation, claim or exception.
7.3.3 This right of access clause (with respect to financial records) applies to:
7.3.3.1 Negotiated prime agreements:
7.3.3.2 Negotiated change orders or agreement amendments in excess of $10,000 affecting the
price of any formally advertised, competitively awarded, fixed price agreement:
7.3.3.3 Agreements or purchase orders under any agreement other than a formally advertised,
competitively awarded, fixed price agreement. However, this right of access does not
apply to a prime agreement, lower tier subagreement or purchase order awarded after
effective price competition, except:
7.3.3.3.1 With respect to record pertaining directly to subagreement performance, excluding
any financial records of ENGINEER;
7.3.3.3.2 If there is any indication that fraud, gross abuse or corrupt practices may be involved;
7.3.3.3.3 If the subagreement is terminated for default or for convenience.
7.4 Covenant Against Contingent Fees
7.4.1 ENGINEER warrants that no person or selling agency has been employed or retained to
solicit or secure this Agreement upon an agreement of understanding for a commission,
percentage, brokerage or continent fee, excepting bona fide employees or bona fide
established commercial or selling agencies maintained by ENGINEER for the purpose of
securing business. For breach or violation of this warranty, CITY OF FAYETTEVILLE shall
have the right to annul this Agreement without liability or at its discretion, to deduct from the
Zion Road; Construction Related Services
Meadow View Drive to North Crossover (Hwy 265) 9
contract price or consideration, or otherwise recover, the full amount of such commission,
percentage, brokerage, or contingent fee.
7.5 Gratuities
7.5.1 If CITY OF FAYETTEVILLE finds after a notice and hearing that ENGINEER or any of
ENGINEER's agents or representatives, offered or gave gratuities (in the form of
entertainment, gifts or otherwise) to any official, employee or agent of CITY OF
FAYETTEVILLE, in an attempt to secure an agreement or favorable treatment in awarding,
amending or making any determinations related to the performance of this Agreement, CITY
OF FAYETTEVILLE may, by written notice to ENGINEER terminate this Agreement. CITY
OF FAYETTEVILLE may also pursue other rights and remedies that the law or this
Agreement provides. However, the existence of the facts on which CITY OF
FAYETTEVILLE bases such finding shall be in issue and may be reviewed in proceedings
under the Remedies clause of this Agreement.
7.5.2 In the event this Agreement is terminated as provided in Paragraph 7.5.1, CITY OF
FAYETTEVILLE may pursue the same remedies against ENGINEER as it could pursue in
the event of a breach of the Agreement by ENGINEER As a penalty, in addition to any other
damages to which it may be entitled by law, CITY OF FAYETTEVILLE may pursue
exemplary damages in an amount (as determined by CITY OF FAYETTEVILLE) which
shall be not less than three nor more than ten times the costs ENGINEER incurs in providing
any such gratuities to any such officer or employee.
7.6 Arkansas Freedom of Information Act
7.6.1 City contracts and documents, including internal documents and documents of subcontractors
and sub -consultants, prepared while performing City contractual work are subject to the
Arkansas Freedom of Information Act (FOIA). If a Freedom of Information Act request is
presented to the CITY OF FAYETTEVILLE, ENGINEER will do everything possible to
provide the documents in a prompt and timely manner as prescribed in the Arkansas Freedom
of Information Act (A.C.A. §25-19-101 et seq.). Only legally authorized photocopying costs
pursuant to the FOIA may be assessed for this compliance.
IN WITNESS WHEREOF, CITY OF FAYETTEVILLE, ARKANSAS by and through its Mayor, and
ENGINEER, by its authorized officer have made and executed this Agreement as of the day and year first
above written.
CITY OF FA
MCCLELLAND CONSULTING ENGINEERS,
INC.
Kevin Beaumont
r, L oneld J aE,RK / TR ���i� ✓
=.`�\,�'� GXTY O,c��;(�'� Kevin BeaUll on Date: 2020.06.30
ATTEST- 15:49:53-05'00'
2Z�Z�Z4 rnt
By
FAYETTEVILLE ; title: Vice President
City Clerk
GANSEND OF AGREEMEN*,)4WNAL ENGINEERING SERVICES
Zion Road; Construction Related Services
Meadow View Drive to North Crossover (Hwy 265) 10
APPENDIX 'A.1'
SCOPE OF SERVICES
PROFESSIONAL SERVICES AGREEMENT
CITY OF FAYETTEVILLE, ARKANSAS
ZION ROAD;
MEADOW VIEW DRIVE TO NORTH CROSSOVER ROAD (HWY 265)
1. Scope of Project
1. Make the following additions to the Zion Road Project.
a. Provide Construction Administration Support for the street component (excludes
Water & Sewer) for the duration of the project based on the 540-calendar day
contract proposed. Scope of professional services to comprise design assistance with
field changes or other construction related issues, estimated to not exceed 154 hours.
b. Provide Construction Administration Support for the water & sewer component for
the duration of the project. Scope of professional services shall be in accordance
with Appendix "A.2" attached hereto.
c. Compile As -Built drawings for both the street and water/ sewer components upon
completion of construction phase.
d. Provide Materials Testing Services for project. Refer to attached CMTS Proposal.
APPENDIX A.1 — Scope of Services A-1 Zion Road Construction Related Services
APPENDIX 'A.2'
SCOPE OF SERVICES;
PROFESSIONAL SERVICES AGREEMENT
CITY OF FAYETTEVILLE, ARKANSAS
ZION ROAD;
MEADOW VIEW DRIVE TO NORTH CROSSOVER ROAD (HWY 265)
WATER AND SEWER UTILITY RELOCATIONS
1.0 General
The scope of additional services includes construction administration services for the water and
sewer utility relocation for the referenced project, which includes approximately 5,600 linear feet
of 12-inch water main; 600 linear feet of 8-inch water main; 3,500 linear feet of 15-inch sewer
main; 1,100 linear feet of 8-inch sewer main; new water/sewer services; and related appurtenances
and interconnections along Zion Road. It is assumed that the water and sewer utility construction
will occur over a 270 consecutive calendar day period as part of the overall construction contract
for the roadway improvements. The CITY OF FAYETTEVILLE will provide construction
observation services for the water and sewer utilities.
2.0 Construction Administration
2.1 Attend the pre -construction meeting with the Contractor.
2.2 Review and respond to Contractor submittals on water and sewer related items for
conformance to the Contract Documents, Drawings, and Specifications. Up to five
(5) submittals are anticipated on this project. The initial review and one (1) re -
submittal review are included in this scope of services. Additional re -submittal
reviews will be considered Additional Services.
2.3 Review Contractor's Requests for Information (RFIs) on water and sewer related
items and issue clarifications as required. Up to ten (10) RFIs are anticipated on
this project.
2.4 Assist the CITY OF FAYETTEVILLE with the evaluation, negotiation, and
processing of Contractor change order requests related to water and sewer related
items, if required.
2.5 Engineer of Record shall conduct monthly site visits and attendance at monthly
progress meetings as required to observe the progress and quality of the executed
work to determine compliance with approved Contract Documents, Drawings, and
Specifications in accordance with Arkansas State Law 22-9-101. A total of twenty
(20) site visits/progress meetings are estimated over the course of the assumed 270
consecutive calendar day construction schedule for water and sewer utilities.
APPENDIX A.2 — Scope of Services A.2-1 Zion Road Construction Related Services
2.6 Assist the CITY OF FAYETTEVILLE with the final inspection walk-through on
the water and sewer related items. Develop a punch list of outstanding items, and
review project closeout documents.
2.7 Prepare Record Drawings for water and sewer utilities based upon information
furnished by the Contractor and field representatives.
3.0 Project Deliverables
3.1 PDF copy of the approved shop drawings and submittals from the Contractor.
3.2 One (1) hard copy set, a PDF copy and AutoCAD file of the Record Drawings for
the water and sewer utilities.
3.3 Other electronic files as requested by the CITY OF FAYETTEVILLE.
4.0 General
4.1 All water and sewer main construction shall follow the guidelines described in the
CITY OF FAYETTEVILLE Standard Specifications for Design and Construction
of Water Lines and Sewer Lines (2017 Edition), the Contract Documents,
Drawings, and Specifications.
4.2 Attendance at meetings other than progress meetings and the pre -construction
meeting will be considered Additional Services.
4.3 Should construction delays occur, which are beyond the control of the ENGINEER
and cause the water and sewer utility construction to be completed later than 270
consecutive calendar days, the ENGINEER and CITY OF FAYETTEVILLE will
review the ENGINEER' remaining budget and mutually agree upon a plan of
action, whether it be a reduction in the scope of services to stay within budget, or
authorize Additional Services.
4.4 Subcontracting of services by the ENGINEER shall have prior approval of the
OWNER.
APPENDIX A.2 —Scope of Services A.2-2 Zion Road Construction Related Services
APPENDIX "C"
COMPENSATION
PROFESSIONAL SERVICES AGREEMENT
CITY OF FAYETTEVILLE, ARKANSAS
ZION ROAD;
MEADOW VIEW DRIVE TO NORTH CROSSOVER ROAD (HWY 265)
CITY OF FAYETTEVILLE shall pay ENGINEER for Basic Services rendered an amount
equal to the cumulative hours charged to the Project for each class of ENGINEER's
employees multiplied by ENGINEER'S Hourly Rates as shown on the attached Exhibit "I",
plus approved Reimbursable Expenses and ENGINEER's Consultant charges, if any.
ENGINEER's Hourly Rates as shown on the attached Exhibit "1" shall be adjusted annually
each January 1. For ENGINEER's Consultant charges, the CITY OF FAYETTEVILLE shall
pay the ENGINEER the amount billed to the ENGINEER times a factor of 1.00.
• Basic Services: Payment by CITY OF FAYETTEVILLE based on ENGINEER's Hourly
Rates shall approximate the following schedule. Payment for a specific phase shall not exceed
the scheduled amount prior to completion of that phase. Underruns in one phase may be used
to offset overruns in another phase as long as the contract amount is not exceeded.
Construction Administration Support; Street $ 19,750.00
As -Built Drawings; Street $ 5,200.00
Construction Administration Support; W&S $ 29,320.00
As -Built Drawings; W&S $ 3,780.00
Materials Testing Services $ 27,544.00
(Refer to attached CMTS Proposal)
SUB -TOTAL Basic Services $ 85,594.00
Additional Services: Any and all Additional Services must be approved, and maximum
amount to be paid for said services agreed to, in writing by CITY OF FAYETTEVILLE prior
to rendering of same. CITY OF FAYETTEVILLE shall pay ENGINEER for Additional
Services rendered an amount equal to the cumulative hours charged to the Project for each
class of ENGINEER's employees multiplied by ENGINEER'S Hourly Rates as shown on the
Attached Exhibit "1", plus approved Reimbursable Expenses and ENGINEER'S Consultant
charges, if any. For ENGINEER's Consultant charges, the CITY OF FAYETTEVILLE shall
pay the ENGINEER the amount billed to the ENGINEER times a factor of 1.00.
• CITY OF FAYETTEVILLE shall pay ENGINEER the actual cost of Reimbursable Expenses
APPENDIX C — Scope of Services C-1 Zion Road Construction Related Services
incurred in connection with Basic and Additional Services. Reimbursable Expenses must be
approved by the CITY OF FAYETTEVILLE prior to the incurrence of such expenses. The
estimated amount of Reimbursable Expenses to be incurred in connection with Basic Services
is:
SUB -TOTAL Reimbursable Expenses $ 300.00
• The maximum payment to the ENGINEER for all of the Basic Services and
Reimbursable Expenses identified within this Agreement shall not exceed $85,894.00.
• ENGINEER shall submit invoices monthly for services rendered and expenses borne. The
invoices shall be accompanied by a copy of the timesheets for all ENGINEER's personnel
working on the project.
The Hourly Rates used as a basis for payment mean salaries and wages (basic and incentive)
paid to all personnel engaged directly on the PROJECT, including, but not limited to,
engineers, architects, surveyors, designers, draftsman, specification writers, estimators, other
technical personnel, stenographers, typists and clerks; plus the cost of customary and statutory
benefits including, but not limited to, social security contributions, unemployment, excise and
payroll taxes, workers' compensation, health and retirement benefits, bonuses, sick leave,
vacation and holiday pay applicable thereto; plus operating margin or profit, non -project
operating costs, and all general and administrative overhead costs, including but not limited
to, furnishing and maintaining office facilities, furniture, utilities, vehicles and equipment.
Reimbursable Expenses mean the actual expenses incurred directly or indirectly in connection
with the PROJECT for printing and reproduction costs and ENGINEER's consultant charges.
Any and all expenditures for reimbursable expenses must be approved by the CITY OF
FAYETTEVILLE prior to rendering or obtaining same. Overtime salary costs are not
considered Reimbursable Expenses.
APPENDIX C — Scope of Services C-2 Zion Road Construction Related Services
McCLELLAND
NEECIONSULTING
ENGINEERS, INC.
2020
McCLELLAND CONSULTING ENGINEERS, INC.
*STANDARD HOURLY RATES
Chief Draftsman
$95 - $110
Clerical
$45 - $75
Construction Observer
$70 - $135
Draftsman
$65 - $95
Environmental Scientist/Designer
$105 - $120
Geotech Engineer
$85 - $170
HR/Payroll Admin
$75-$100
Landscape Architect
$90 - $130
Media Specialist
$80 - $100
Principal
$160 - $230
Project Accountant
$70 - $145
Project Designer
$80 - $140
Project Engineer
$120 - $175
Project Manager
$120 - $200
Registered Land Surveyor
$95 - $140
Soils Lab Technician
$50 - $135
Specification Writer
$50 - $90
Sr. Project Manager
$140 - $240
Survey (2 man or Robotic) Crew
$115 - $160
Survey (3 man) Crew
$135 - $180
Survey Field (1 Man or Rodman)
$45 - $95
Survey GPS
$75 - $130
Survey Technician
$65 - $95
Water Lab Supervisor
$70 - $120
Expenses
@ Cost
Mileage
.575/m i
* Standard Hourly Rates may be adjusted annually in accordance with
the normal salary review practices of McClelland Consulting Engineers.
NSULTINGNEE,D
ENGINEERS, INC.
April 27, 2020
CITY OF
WiM FAYETTEVILLE
ARKANSAS
Engineering Division
125 West Mountain Street
Fayetteville, Arkansas 72701
ATTN: Mr. Matt Casey P.E.
Engineering Design Manager
RE: Proposal for Construction Materials Testing Services
Zion Road Phase II Improvements
Fayetteville, Arkansas
Dear Mr. Casey,
1810 N. College Avenue
P.O. Box 1229
Fayetteville, AR 73703172702-1229
479-443-2377/Fax 479-443-9241
www.mce.us.com
We are pleased to present a Proposal for Construction Materials Testing Services relevant to the planned Zion Road
Phase II Improvements project located in Fayetteville, Arkansas. The information below and on the following pages
provides further detail regarding the anticipated construction materials testing scope on the project. This includes
number of trips for each service, time spent onsite for each service, and other anticipations which are integral in to
the proposed not -to -exceed fee.
Site Description
The project site is generally located in the northeastern portion of Fayetteville, Arkansas along the existing
alignment of Zion Road from Vantage Drive in the west to Highway 265 in the east. Based on the provided project
drawings dated April, 2020, and our general understanding of the project, the scope consists of improvements to the
existing Zion Road and surrounding drainage features and utilities.
Project Description
Based on the current project plans, we understand the project scope to include pavement improvements and new
road construction within the existing dimensions of Zion Road from Vantage Drive in the west to Highway 265.
The anticipated pavement improvements include approximately 3,132 linear feet of full -depth pavement
reconstruction and approximately 2,006 linear feet of mill -and -overlay within the project dimensions. Additionally,
the project is expected to include new pedestrian sidewalks on both sides of the roadway improvements as well as the
new construction of a roundabout at the existing intersection of Old Missouri Road and Zion Road. Several aprons,
driveways, and utility improvements are also anticipated being included as part of the project scope.
Zion Road Phase II Improvements - Construction Materials Testing Services
Mr. Matt Casey, P.E. — City of Fayetteville
April 27, 2020
Page 12
If any of the anticipated or assumed information is incorrect, please allow us to make appropriate revisions to
the proposed scope of work prior to construction.
Scope of Work
To better your understanding of our associated fees, we have presented estimated per -trip prices for the construction
materials testing services that we anticipate on the project.
Construction Materials Testing Services
It is anticipated that construction materials testing will consist of subgrade observations/recommendations, soil and
base density testing, concrete testing, and asphalt testing. The following outline identifies material tests that we
anticipate along with their associated cost;
• A Geotechnical Engineer/engineering technician spending one (1) hour onsite for proof -roll observations
and/or subgrade recommendations regarding pavement improvement area subgrade
• MCE conducting proctors for select fill material to be utilized at the project site
• A certified technician spending 30 minutes on -site for each soil and base course density testing trip.
Three (3) tests are anticipated for each density trip
- Reporting fees are included in the per -trip amount for this service
• A certified technician spending 30 minutes on -site for each cast -in -place concrete testing trip.
Five (5) 4"x8" concrete samples being conducted each trip
Reporting fees are included in the per -trip amount for this service
Additional time spent on -site and concrete cylinder samples may be required for concrete
placement operations exceeding 50 cubic yards
• A certified technician spending one (1) hour on -site to assist with establishing a roll pattern during the
placement of asphalt.
Reporting fees are included in the per -trip amount for this service
- Additional time spent on -site may be required if asphalt placement operations require rolling
patterns at intervals per the project specifications or if the contractor requests a technician
remain on -site to assist until daily placement operations conclude
• A certified technician spending three (3) hours at an asphalt plant to sample asphalt during placement
operations.
• A certified technician spending one (1) hour on -site coring asphalt samples for laboratory testing.
A travel mileage fee from the office to the job site is already included with this service
Zion Road Phase II Improvements - Construction Materials Testing Services
Mr. Matt Casey, P.E. — City of Fayetteville
April27, 2020
Page 13
We expect that the project duration will be approximately 12 months. Fees related to travel, reporting, and
administration are incorporated into the provided per trip estimates for each service, if applicable. From the
assumptions and project details referenced above, we estimated the following per -trip prices and subtotals for each
service anticipated being required:
Proof Roll Observations/Subgrade Recommendations $200.00 per trip
• Sidewalk Subgrade — 5 trips
• Roadway Subgrade — 7 trips
Subtotal: $2,400.00
Laboratory Proctor Test $400.00 per test
• It is anticipated that one (1) proctor test will be conducted for the duration of the project.
Subtotal: $400.00
Soil & Base Density Testing $120.00 per trip
• Sidewalk Select Fill Material —10 trips
• Sidewalk Base Course Material —10 trips
• Roadway Select Fill Material —14 trips
• Roadway Base Course Material— 7 trips
• Utility -Related Base Course Material —10 trips
Subtotal: $6,120.00
Cast -In -Place Concrete $220.00 per trip
• Sidewalks —15 trips
• Curb & Gutter —10 trips
• Utility Improvements —20trips
• Aprons and other Improvements —12 trips
Subtotal: $12,540.00
Concrete Cylinder Pick -Up $53.00 per trip
• A charge for concrete cylinder pick-up will only be applied in the event that is the sole reason for the site
visit on days where no other testing is scheduled. We have assumed that only one-half (%) of the total
concrete testing trips will be needed for this service.
Subtotal: $1,484.00
Zion Road Phase II Improvements - Construction Materials Testing Services April 27, 2020
Mr. Matt Casey, P.E. — City of Fayetteville P a g e 14
Asphalt Rolling Pattern $80.00 per trip
• A certified technician conducting asphalt rolling patterns during asphalt placement operations. It is
anticipated that five (5) trips will be required for this service.
Subtotal: $400.00
Asphalt Bulk Sampling
$600.00 per sample(s)
• A certified technician sampling asphalt from the designated asphalt provider for laboratory testing. It is
anticipated that three (3) bulk samples for asphalt binder and four (4) asphalt surface samples will be
required for quality verification. It is anticipated that four (4) trips to the asphalt plant for asphalt bulk
sampling will be required for this project.
Subtotal: $2,400.00
Asphalt Coring
$450.00 per trip
• A certified technician coring asphalt samples for final laboratory acceptance testing. It is anticipated that
36 cores will be required for laboratory testing:14 binder cores and 22 surface cores. This frequency expects
one (1) core per 500 linear feet of new pavement, per lane. The cores will be tested for air voids and
thickness verification. It is anticipated that up to four (4) trips may be required for this service.
Subtotal: $1,800.00
Proposed Fee
Based on the assumptions detailed in the forgoing proposal, we can provide construction phase services on this
project for a not -to -exceed amount as detailed below:
• Proof Roll Observations/Subgrade Recommendations................................................................................. $2,400.00
• Laboratory Proctor Test..........................................................................................................................................
$400.00
• Soil & Base Density Testing..................................................................................................................................
$6,120.00
• Cast -In -Place Concrete......................................................................................................................................
$12,540.00
• Concrete Cylinder Pick-Up..................................................................................................................................
$1,484.00
• Asphalt Rolling Pattern..........................................................................................................................................
$400.00
• Asphalt Bulk Sampling.........................................................................................................................................
$2,400.00
• Asphalt Coring.......................................................................................................................................................
$1,800.00
Total Not -to -Exceed Amount: $27,544.00
Zion Road Phase II Improvements - Construction Materials Testing Services
Mr. Matt Casey, P.E. — City of Fayetteville
April27, 2020
Page 15
Our estimated number of trips for each testing service is based on our experience on projects in the area with similar
scope and size. Our fees are directly related to the number of trips made for each service and time spent onsite. If the
project scope or timeline varies after submittal of this document and prior to construction, please allow for the
review/revision of this document.
We appreciate the opportunity to submit this proposal for construction materials testing services relevant to the Zion
Road Phase II Improvements project located in Fayetteville, Arkansas. Please contact us with any questions or
concerns that you might have regarding the information contained in this proposal.
Sincerely,
Steven J. Head, P.E.
Principal I Geotechnical Department Head
FRoger Bahen
Construction Materials Testing Supervisor
Work Authorization Agreement
McClelland Consulting Engineers, Inc., is authorized to proceed in accordance with this Letter of Proposal,
consisting of five (5) pages.
nature
Title
-7- ZI - 20
Date
IR�
MTrITI
441
I.wf _il�
tj
F F 30'FIF MIN..
TYP 'F, I TYP. SEC. "2"
77"
114
VARIES
Ty6P. 30' F/F
TYP
MULTI -USE SIDEWALK
TRAIL l0.�TRAEL�CLANER�TLANEL�
CIDE URB&
TYPICAL SECTION "'I" GUTTER
—VARIES
6- VARIES
TYP. 39 TO 32' TYP.
VARIES VARIES EX.—
101 �SW
MULTI -USE
TRAIL MNlo' 10, MIN.
CENTER TRAVEL �
18" WIDE
LANE LANE LANE CURB &
LANE WIDTHS VARY GUTTER
TYPICAL SECTION "2"
City of Fayetteville, Arkansas - Budget Adjustment Form (Legistar)
Budget Year Division Adjustment Number
/Org2 ENGINEERING (621)
2020
Requestor: Matt Casey
BUDGET ADJUSTMENT DESCRIPTION / JUSTIFICATION:
Approval of a contract amendment for construction phase services and materials testing in the amount of $85,894.00
with McClelland Consulting Engineers, Inc. for the Zion Road — Vantage to Crossover Project and approval of a budget
adjustment.
COUNCIL DATE:
LEGISTAR FILE ID#:
7/21/2020
2020-0496
Matthew Maddox,
611712020 11:58 AM
Budget Director
TYPE:
JOURNAL #:
Date
D - (City Council)
7/21/2020
GLDATE:
RESOLUTION/ORDINANCE
CHKD/POSTED:
TOTAL
- -
v.20200528
Increase / (Decrease)
Proiect.Sub#
Account Number
Expense Revenue
Project
Sub.Detl AT
Account Name
4602.860.7212-5860.02
52,794
46020
7212 EX
Capital Prof Svcs - Engineering/Architects
4602.860.7999-5899.00
(52,794)
46020
7999 EX
Unallocated - Budget
5400.720.5700-5314.00
33,100
06035
2750 EX
Professional Services
5400.720.5600-5808.00
(33,100)
06035
3100 EX
Improvements - Water Line
HABudget Adjustments\2020_Budget\City Council\07-21-2020\2020-0496
BA Zion Construction
1 of 1