HomeMy WebLinkAbout43-15 RESOLUTIONRESOLUTION NO. 43-15
A RESOLUTION TO AUTHORIZE A PROFESSIONAL ENGINEERING
SERVICES AGREEMENT WITH GARVER, LLC FOR FINAL DESIGN
SERVICES FOR WATER AND SEWER RELOCATIONS ASSOCIATED
WITH ARKANSAS HIGHWAY AND TRANSPORATION DEPARTMENT
PROJECT BB0414 — INTERSTATE 49 AND HIGHWAY 112 INTERCHANGE
IN AN AMOUNT NOT TO EXCEED $102,742.50, AND TO APPROVE A
BUDGET ADJUSTMENT
BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF
FAYETTEVILLE, ARKANSAS:
Section 1. That the City Council of the City of Fayetteville, Arkansas hereby authorizes
the Mayor to sign a professional engineering services agreement with Garver, LLC for final
design services for water and sewer relocations associated with Arkansas Highway and
Transportation Department Project BB0414 — Interstate 49 and Highway 112 interchange in an
amount not to exceed $102,742.50.
Section 2. That the City Council of the City of Fayetteville, Arkansas hereby approves a
budget adjustment, attached to this Resolution and made a part hereof
PASSED and APPROVED this 17th day of February, 2015.
A PPR OVFI)-
LM
ATTEST:
By: 4aA' cs'� 'J41
SONDRA E. SMITH, City Clerk/I%qj%s}lfpr
®®®® GLER K
ciTY
0
®®®®.�A
yamNS PS m
�0
tE{{1
City of Fayetteville, Arkansas 113 West Mountain Street
J Fayetteville, AR 72701
479-575-8323
Ha
Text File
File Number: 2015-0054
Agenda Date: 2/17/2015 Version: 1 Status: Passed
In Control: City Council File Type: Resolution
Agenda Number: A. 6
GARVER, LLC:
A RESOLUTION TO AUTHORIZE A PROFESSIONAL ENGINEERING SERVICES AGREEMENT
WITH GARVER, LLC FOR FINAL DESIGN SERVICES FOR WATER AND SEWER
RELOCATIONS ASSOCIATED WITH ARKANSAS HIGHWAY AND TRANSPORATION
DEPARTMENT PROJECT BB0414 - INTERSTATE 49 AND HIGHWAY 112 INTERCHANGE IN
AN AMOUNT NOT TO EXCEED $102,742.50, AND TO APPROVE A BUDGET ADJUSTMENT
BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF FAYETTEVILLE,
ARKANSAS:
Section 1. That the City Council of the City of Fayetteville, Arkansas hereby authorizes the Mayor to
sign a professional engineering services agreement with Garver, LLC for final design services for water
and sewer relocations associated with Arkansas Highway and Transportation Department Project
BB0414 - Interstate 49 and Highway 112 interchange in an amount not to exceed $102,742.50.
Section 2. That the City Council of the City of Fayetteville, Arkansas hereby approves a budget
adjustment, attached to this Resolution and made a part hereof
City of Fayetteville, Arkansas Page 1 Printed on 211812015
Jim Beavers
Submitted By
City of Fayetteville Staff Review Form
2015-0054
Legistar File ID
2/17/2015
City Council Meeting Date - Agenda Item Only
N/A for Non -Agenda Item
1/29/2015 Utilities Director/
_ Utilities Department
Submitted Date Division / Department
Action Recommendation:
Approve Professional Engineering Service Contract with Garver Engineers LLC for $102,742.50 for engineering
services to perform the final design of the water/sewer relocations associated with AHTD project BB0414 - 1-
49/Hwy112 and approval of budget adjustment.
Budget Impact:
5400.5700.5314.00 Water/Sewer
Account Number Fund
11011.1501 Water/Sewer Relocations -Bond Projects
Project Number Project Title
Budgeted Item? No
Current Budget
$ 1,300,000.00
Funds Obligated
$ 19,500.00
Current Balance1,280,500.00
Does item have a cost? Yes
Item Cost
$ 102,742.50
Budget Adjustment Attached? Yes
Budget Adjustment
$ 102,743.00
Remaining Budget
$ 1,280,500.50
V20140710
Previous Ordinance or Resolution #
Original Contract Number:
Comments:
Approval Date:
CITY OF
Tay4
eevle
ARKANSAS
TO: Mayor Jordan and City Council
THRU: Don Marr, Chief of Staff
Tim Nyander, Utilities Director
Legistar Review
FROM: Jim Beavers, P.E. Utilities Engineer
DATE: January 27, 2015
SUBJECT: Approval of an Engineering contract with Garver LLC to perform the final design
and construction phase engineering services for the water/sewer relocations
associated with AHTD project BB0414 —1-49/Hwy 112 and approval of a budget
adjustment.
RECOMMENDATION:
Approval of the attached Engineering Services Contract with Garver LLC in the amount of
$102,742.50 for engineering services to perform the final design of the water/sewer relocations
associated with AHTD project BB0414 —1-49/Hwy 112.
BACKGROUND:
AHTD has requested final plans, specifications and cost estimates for utility relocations no later
than April 1, 2015 for the new intersection of 1-49/Hwy112. Construction is planned for fall 2015.
DISCUSSION:
Based upon a formal Engineering Selection Committee meeting, Garver LLC was selected to
perform the design of the engineering services associated with AHTD project BB0414 (1-49/Hwy
112). A portion of these costs will be reimbursable from AHTD to the City. This amount will be
determined by AHTD after we submit the final plans to AHTD for their review. A current, non-
binding, estimate of reimbursable percentage is 80 percent.
BUDGET/STAFF IMPACT:
Budgeted funds will be moved from the Sanitary Sewer Rehabilitation Project to fund the cost of
this request. In the Water/Sewer Relocation Project $1,300,000.00 is budgeted for 2015. This
$1,300,000.00 is already obligated and will be spent in 2015 on 2 CIP projects — Zion
RdNantage Dr. to Hwy 265 and Stadium Dr. to Razorback Rd.
Attachments:
1. Staff Review Form
2. Staff Review Memo
3. Purchase Order Request
4. Budget Adjustment
5. Proposed Contract
6. Copy of AHTD Preliminary Improvements
Mailing Address:
113 W. Mountain Street www.fayetteville-ar.gov
Fayetteville, AR 72701
Vendor 52650 Vendor
Garver Engineers
a., R Yes r No
: Name:2015-0054
FOB Point:
Taxable
Address: 2049 E Joyce Blvd Ste 400
r Yes F No
Expected Delivery Date:
Zip Code:
Ship to code:
Quotes Attached
City: Fayetteville
State: AR
72703
Fay
r Yes I No
Requesters Employee #:
Extension:
Requester: Cheryl Partain
2548
8224
Item
Description
Quantity
Unit of Issue
Unit Cost
Extended Cost
Account Number
Project.Sub#
Inventory #
Fixed Asset #
1
Professional Services-Fina
design of the waterlsewer relocations for 1.49
1
EA
102,742.50
$102,742.50
5400.5700.5314.00
11011.1501
Interchan eM 112
2
$0.00
3
$0.00
4
$0.00
5
$0.00
6
$0.00
7
$0.00
8
$0.00
9
$0.00
10
$0.00
Shipping/Handling
Lot
$0.00
Special i..pecial Instructions:
Subtotal: $102,742.50
Tax: $0.00
Total: $102,742.50
Approvals:
Mayor: Department Director: Purchasing Manager:
Chief Financial Officer: Budget Director: IT Director:
Dispatch Manager: Utilities Manager: Other:
AGREEMENT
For
PROFESSIONAL ENGINEERING SERVICES
Between
CITY OF FAYETTEVILLE, ARKANSAS
And
GARVER, LLC
THIS AGREEMENT is made as of Y LF , 2015, by and between City of Fayetteville,
Arkansas, acting by and through its Mayor ereinafter called CITY OF FAYETTEVILLE) and
GARVER, LLC (hereinafter called ENGINEER).
CITY OF FAYETTEVILLE from time to time requires professional engineering services in connection
with the evaluation, design, and/or construction supervision of capital improvement projects. Therefore,
CITY OF FAYETTEVILLE and ENGINEER in consideration of their mutual covenants agree as follows:
ENGINEER shall serve as CITY OF FAYETTEVILLE's professional engineering consultant in those
assignments to which this Agreement applies, and shall give consultation and advice to CITY OF
FAYETTEVILLE during the performance of ENGINEER's services. All services shall be performed
under the direction of a professional engineer registered in the State of Arkansas and qualified in the
particular field.
SECTION 1- AUTHORIZATION OF SERVICES
1.1 Services on any assignment shall be undertaken only upon written Authorization of CITY OF
FAYETTEVILLE and agreement of ENGINEER
1.2 Assignments may include services described hereafter as Basic Services or as Additional
Services of ENGINEER.
1.3 Changes, modifications or amendments in scope, price or fees to this contract shall not be
allowed without a formal contract amendment approved by the Mayor and the City Council
in advance of the change in scope, costs, fees, or delivery schedule.
SECTION 2- BASIC SERVICES OF ENGINEER
2.1 Perform professional services in connection with the Project as hereinafter stated.
2.1.1 The Scope of Services to be furnished by ENGINEER during the Project is included in
Appendix A attached hereto and made part of this Agreement.
2.2 ENGINEER shall coordinate their activities and services with the CITY OF
FAYETTEVILLE. ENGINEER and CITY OF FAYETTEVILLE agree that ENGINEER has
fall responsibility for the engineering services.
SECTION 3- RESPONSIBILITIES OF CITY OF FAYETTEVILLE
3.1 CITY OF FAYETTEVILLE shall, within a reasonable time, so as not to delay the services of
ENGINEER:
Garver Contract — Professional Engineering Services 1 1/13/2015
3.1.1 Provide full information as to CITY OF FAYETTEVILLE's requirements for the
Project.
3.1.2 Assist ENGINEER by placing at ENGINEER's disposal all available information
pertinent to the assignment including previous reports and any other data relative
thereto.
3.1.3 Assist ENGINEER in obtaining access to property reasonably necessary for
ENGINEER to perform his services under this Agreement.
3.1.4 Examine all studies, reports, sketches, cost opinions, proposals, and other documents
presented by ENGINEER and render in writing decisions pertaining thereto.
3.1.5 Provide such professional legal, accounting, financial, and insurance counseling services
as may be required for the Project.
3.1.6 The City Engineer is the CITY OF FAYETTEVILLE's project representative with
respect to the services to be performed under this Agreement. The City Engineer shall
have complete authority to transmit instructions, receive information, interpret and
define CITY OF FAYETTEVILLE's policies and decisions with respect to materials,
equipment, elements and systems to be used in the Project, and other matters pertinent to
the services covered by this Agreement.
3.1.7 CITY OF FAYETTEVILLE and/or its representative will review all documents and
provide written comments to ENGINEER in a timely manner.
SECTION 4- PERIOD OF SERVICE
4.1 This Agreement will become effective upon the first written notice by CITY OF
FAYETTEVILLE authorizing services hereunder.
4.2 The provisions of this Agreement have been agreed to in anticipation of the orderly progress
of the Project through completion of the services stated in the Agreement. ENGINEER will
proceed with providing the authorized services immediately upon receipt of written
authorization from CITY OF FAYETTEVILLE. Said authorization shall include the scope of
the services authorized and the time in which the services are to be completed. The
anticipated schedule for this project is included as Appendix A.
SECTION 5- PAYMENTS TO ENGINEER
5.1 The maximum not -to -exceed amount authorized for this Agreement shall be based upon on a
Unit Price or Lump Sum basis as described in Appendix A.
5.2 Statements
5.2.1 Monthly statements for each calendar month shall be submitted to CITY OF
FAYETTEVILLE or such parties as CITY OF FAYETTEVILLE may designate for
professional services consistent with ENGINEER'S normal billing schedule. Once
established, the billing schedule shall be maintained throughout the duration of the
Project.
Applications for payment shall be made in accordance with a format to be developed by
ENGINEER and as approved by CITY OF FAYETTEVILLE. Applications for payment
Garver Contract — Professional Engineering Services 2 1/13/2015
shall be accompanied each month by the updated project schedule as the basis for
determining the value earned as the work is accomplished. Final payment for
professional services shall be made upon CITY OF FAYETTEVILLE's approval and
acceptance with the satisfactory completion of the study and report for the Project.
5.3 Payments
5.3.1 All statements are payable upon receipt and due within thirty (30) days. If a portion of
ENGINEER's statement is disputed by CITY OF FAYETTEVILLE, the undisputed
portion shall be paid by CITY OF FAYETTEVILLE by the due date. CITY OF
FAYETTEVILLE shall advise ENGINEER in writing of the basis for any disputed
portion of any statement. CITY OF FAYETTEVILLE will make reasonable effort to
pay invoices within 30 days of date the invoice is approved, however, payment within
30 days is not guaranteed.
5.4 Final Payment
5.4.1 Upon satisfactory completion of the work performed under this Agreement, as a
condition before final payment under this Agreement, or as a termination settlement
under this Agreement, ENGINEER shall execute and deliver to CITY OF
FAYETTEVILLE a release of all claims against CITY OF FAYETTEVILLE arising
under or by virtue of this Agreement, except claims which are specifically exempted by
ENGINEER to be set forth therein. Unless otherwise provided in this Agreement or by
State law or otherwise expressly agreed to by the parties to this Agreement, final
payment under this Agreement or settlement upon termination of this Agreement shall
not constitute a waiver of CITY OF FAYETTEVILLE's claims against ENGINEER or
his sureties under this Agreement or applicable performance and payment bonds, if any.
SECTION 6- GENERAL CONSIDERATIONS
6.1 Insurance
6.1.1 During the course of performance of these services, ENGINEER will maintain (in
United States Dollars) the following minimum insurance coverages:
Type of Coverage
Workers' Compensation
Employers' Liability
Commercial General Liability
Bodily Injury and
Property Damage
Automobile Liability:
Bodily Injury and
Property Damage
Professional Liability Insurance
Limits of Liability
Statutory
$500,000 Each Accident
$1,000,000 Combined Single Limit
$1,000,000 Combined Single Limit
$1,000,000 Each Claim
ENGINEER will provide to CITY OF FAYETTEVILLE certificates as evidence of the
specified insurance within ten days of the date of this Agreement and upon each renewal
of coverage.
Garver Contract — Professional Engineering Services 3 1/13/2015
6.1.2 CITY OF FAYETTEVILLE and ENGINEER waive all rights against each other and
their officers, directors, agents, or employees for damage covered by property insurance
during and after the completion of ENGINEER's services.
6.2 Professional Responsibility
6.2.1 ENGINEER will exercise reasonable skill, care, and diligence in the performance of
ENGINEER's services and will carry out its responsibilities in accordance with
customarily accepted professional engineering practices. CITY OF FAYETTEVILLE
will promptly report to ENGINEER any defects or suspected defects in ENGINEER's
services of which CITY OF FAYETTEVILLE becomes aware, so that ENGINEER can
take measures to minimize the consequences of such a defect. CITY OF
FAYETTEVILLE retains all remedies to recover for its damages caused by any
negligence of ENGINEER.
6.3 Cost Opinions and Projections
6.3.1 Cost opinions and projections prepared by ENGINEER relating to construction costs
and schedules, operation and maintenance costs, equipment characteristics and
performance, and operating results are based on ENGINEER's experience,
qualifications, and judgment as a design professional. Since ENGINEER has no control
over weather, cost and availability of labor, material and equipment, labor productivity,
construction Contractors' procedures and methods, unavoidable delays, construction
Contractors' methods of determining prices, economic conditions, competitive bidding
or market conditions, and other factors affecting such cost opinions or projections,
ENGINEER does not guarantee that actual rates, costs, performance, schedules, and
related items will not vary from cost opinions and projections prepared by ENGINEER.
6.4 Changes
6.4.1 CITY OF FAYETTEVILLE shall have the right to make changes within the general
scope of ENGINEER's services, with an appropriate change in compensation and
schedule only after Fayetteville City Council approval of such proposed changes and,
upon execution of a mutually acceptable amendment or change order signed by the
Mayor of the CITY OF FAYETTEVILLE and the duly authorized officer of
ENGINEER.
6.5 Termination
6.5.1 This Agreement may be terminated in whole or in part in writing by either party in the
event of substantial failure by the other party to fulfill its obligations under this
Agreement through no fault of the terminating party, provided that no termination may
be effected unless the other party is given:
6.5.1.1 Not less than ten (10) calendar days written notice (delivered by certified mail, return
receipt requested) of intent to terminate,
6.5.1.2 An opportunity for consultation with the terminating party prior to termination.
6.5.2 This Agreement may be terminated in whole or in part in writing by CITY OF
FAYETTEVILLE for its convenience, provided that ENGINEER is given:
Garver Contract — Professional Engineering Services 4 1/13/2015
6.5.2.1 Not less than ten (10) calendar days written notice (delivered by certified mail, return
receipt requested) of intent to terminate,
6.5.2.2 An opportunity for consultation with the terminating party prior to termination.
6.5.3 If termination for default is effected by CITY OF FAYETTEVILLE, an equitable
adjustment in the price provided for in this Agreement shall be made, but
6.5.3.1 No amount shall be allowed for anticipated profit on unperformed services or other
work,
6.5.3.2 Any payment due to ENGINEER at the time of termination may be adjusted to cover
any additional costs to CITY OF FAYETTEVILLE because of ENGINEER's
default.
6.5.4 If termination for default is effected by ENGINEER, or if termination for convenience is
effected by CITY OF FAYETTEVILLE, the equitable adjustment shall include a
reasonable profit for services or other work performed. The equitable adjustment for
any termination shall provide for payment to ENGINEER for services rendered and
expenses incurred prior to the termination, in addition to termination settlement costs
reasonably incurred by ENGINEER relating to commitments which had become firm
prior to the termination.
6.5.5 Upon receipt of a termination action under Paragraphs 6.5.1 or 6.5.2 above, ENGINEER
shall:
6.5.5.1 Promptly discontinue all affected work (unless the notice directs otherwise),
6.5.5.2 Deliver or otherwise make available to CITY OF FAYETTEVILLE all data,
drawings, specifications, reports, estimates, summaries and such other information
and materials as may have been accumulated by ENGINEER in performing this
Agreement, whether completed or in process.
6.5.6 Upon termination under Paragraphs 6.5.1 or 6.5.2 above CITY OF FAYETTEVILLE
may take over the work and may award another party an agreement to complete the
work under this Agreement.
6.5.7 If, after termination for failure of ENGINEER to fulfill contractual obligations, it is
determined that ENGINEER had not failed to fulfill contractual obligations, the
termination shall be deemed to have been for the convenience of CITY OF
FAYETTEVILLE. In such event, adjustments of the agreement price shall be made as
provided in Paragraph 6.5.4 of this clause.
6.6 Delays
6.6.1 In the event the services of ENGINEER are suspended or delayed by CITY OF
FAYETTEVILLE or by other events beyond ENGINEER's reasonable control,
ENGINEER shall be entitled to additional compensation and time for reasonable costs
incurred by ENGINEER in temporarily closing down or delaying the Project.
Garver Contract — Professional Engineering Services 5 1/13/2015
6.7 Rights and Benefits
6.7.1 ENGINEER's services will be performed solely for the benefit of CITY OF
FAYETTEVILLE and not for the benefit of any other persons or entities.
6.8 Dispute Resolution
6.8.1 Scope of Paragraph: The procedures of this Paragraph shall apply to any and all disputes
between CITY OF FAYETTEVILLE and ENGINEER which arise from, or in any way
are related to, this Agreement, including, but not limited to the interpretation of this
Agreement, the enforcement of its terms, any acts, errors, or omissions of CITY OF
FAYETTEVILLE or ENGINEER in the performance of this Agreement, and disputes
concerning payment.
6.8.2 Exhaustion of Remedies Required: No action may be filed unless the parties first
negotiate. If timely Notice is given under Paragraph 6.8.3, but an action is initiated prior
to exhaustion of these procedures, such action shall be stayed, upon application by either
party to a court of proper jurisdiction, until the procedures in Paragraphs 6.8.3 and 6.8.4
have been complied with.
6.8.3 Notice of Dispute
6.8.3.1 For disputes arising prior to the making of final payment promptly after the
occurrence of any incident, action, or failure to act upon which a claim is based, the
party seeking relief shall serve the other party with a written Notice;
6.8.3.2 For disputes arising within one year after the making of final payment, CITY OF
FAYETTEVILLE shall give ENGINEER written Notice at the address listed in
Paragraph 6.14 within thirty (30) days after occurrence of any incident, accident, or
first observance of defect or damage. In both instances, the Notice shall specify the
nature and amount of relief sought, the reason relief should be granted, and the
appropriate portions of this Agreement that authorize the relief requested.
6.8.4 Negotiation: Within seven days of receipt of the Notice, the Project Managers for CITY
OF FAYETTEVILLE and ENGINEER shall confer in an effort to resolve the dispute. If
the dispute cannot be resolved at that level, then, upon written request of either side, the
matter shall be referred to the President of ENGINEER and the Mayor of CITY OF
FAYETTEVILLE or his designee. These officers shall meet at the Project Site or such
other location as is agreed upon within 30 days of the written request to resolve the
dispute.
6.9 CITY OF FAYETTEVILLE represents that it has sufficient funds or the means of obtaining
funds to remit payment to ENGINEER for services rendered by ENGINEER.
6.10 Publications
6.10.1 Recognizing the importance of professional development on the part of ENGINEER's
employees and the importance of ENGINEER's public relations, ENGINEER may
prepare publications, such as technical papers, articles for periodicals, and press releases,
pertaining to ENGINEER's services for the Project. Such publications will be provided
to CITY OF FAYETTEVILLE in draft form for CITY OF FAYETTEVILLE's advance
review. CITY OF FAYETTEVILLE shall review such drafts promptly and provide
CITY OF FAYETTEVILLE's comments to ENGINEER. CITY OF FAYETTEVILLE
Garver Contract — Professional Engineering Services 6 1/13/2015
may require deletion of proprietary data or confidential information from such
publications, but otherwise CITY OF FAYETTEVILLE will not unreasonably withhold
approval. The cost of ENGINEER's activities pertaining to any such publication shall be
for ENGINEER's account.
6.11 Indemnification
6.11.1 CITY OF FAYETTEVILLE agrees that it will require all construction Contractors to
indemnify, defend, and hold harmless CITY OF FAYETTEVILLE and ENGINEER from
and against any and all loss where loss is caused or incurred or alleged to be caused or
incurred in whole or in part as a result of the negligence or other actionable fault of the
Contractors, or their employees, agents, Subcontractors, and Suppliers.
6.12 Ownership of Documents
6.12.1 All documents provided by CITY OF FAYETTEVILLE including original drawings,
disks of CADD drawings and cross sections, estimates, specification field notes, and data
are and remain the property of CITY OF FAYETTEVILLE. ENGINEER may retain
reproduced copies of drawings and copies of other documents.
6.12.2 Engineering documents, drawings, and specifications prepared by ENGINEER as part of
the Services shall become the property of CITY OF FAYETTEVILLE when ENGINEER
has been compensated for all Services rendered, provided, however, that ENGINEER
shall have the unrestricted right to their use. ENGINEER shall, however, retain its rights
in its standard drawings details, specifications, databases, computer software, and other
proprietary property. Rights to intellectual property developed, utilized, or modified in
the performance of the Services shall remain the property of ENGINEER.
6.12.3 Any files delivered in electronic medium may not work on systems and software different
than those with which they were originally produced. ENGINEER makes no warranty as
to the compatibility of these files with any other system or software. Because of the
potential degradation of electronic medium over time, in the event of a conflict between
the sealed original drawings/hard copies and the electronic files, the sealed drawings/hard
copies will govern.
6.13 Notices
6.13.1 Any Notice required under this Agreement will be in writing, addressed to the
appropriate party at the following addresses:
CITY OF FAYETTEVILLE's address:
125 West Mountain Street
Fayetteville, Arkansas 72701
ENGINEER's address:
2049 E. Joyce Blvd, Suite 400
Fayetteville, Arkansas 72703
Garver Contract — Professional Engineering Services 7 1/13/2015
6.14 Successor and Assigns
6.14.1 CITY OF FAYETTEVILLE and ENGINEER each binds himself and his successors,
executors, administrators, and assigns to the other party of this Agreement and to the
successors, executors, administrators, and assigns of such other party, in respect to all
covenants of this Agreement; except as above, neither CITY OF FAYETTEVILLE nor
ENGINEER shall assign, sublet, or transfer his interest in the Agreement without the
written consent of the other.
6.15 Controlling Law
6.15.1 This Agreement shall be subject to, interpreted and enforced according to the laws of the
State of Arkansas without regard to any conflicts of law provisions.
6.16 Entire Agreement
6.16.1 This Agreement represents the entire Agreement between ENGINEER and CITY OF
FAYETTEVILLE relative to the Scope of Services herein. Since terms contained in
purchase orders do not generally apply to professional services, in the event CITY OF
FAYETTEVILLE issues to ENGINEER a purchase order, no preprinted terms thereon
shall become a part of this Agreement. Said purchase order document, whether or not
signed by ENGINEER, shall be considered as a document for CITY OF
FAYETTEVILLE's internal management of its operations.
SECTION 7- SPECIAL CONDITIONS
7.1 Additional Responsibilities of ENGINEER
7.1.1 CITY OF FAYETTEVILLE's review, approval, or acceptance of design drawings,
specifications, reports and other services furnished hereunder shall not in any way relieve
ENGINEER of responsibility for the technical adequacy of the work. Neither CITY OF
FAYETTEVILLE's review, approval or acceptance of, nor payment for any of the
services shall be construed as a waiver of any rights under this Agreement or of any cause
of action arising out of the performance of this Agreement.
7.1.2 ENGINEER shall be and shall remain liable, in accordance with applicable law, for all
damages to CITY OF FAYETTEVILLE caused by ENGINEER's negligent performance
of any of the services furnished under this Agreement except for errors, omissions or
other deficiencies to the extent attributable to CITY OF FAYETTEVILLE or CITY OF
FAYETTEVILLE-furnished data.
7.1.3 ENGINEER's obligations under this clause are in addition to ENGINEER's other express
or implied assurances under this Agreement or State law and in no way diminish any
other rights that CITY OF FAYETTEVILLE may have against ENGINEER for faulty
materials, equipment, or work.
7.2 Remedies
7.2.1 Except as may be otherwise provided in this Agreement, all claims, counter -claims,
disputes and other matters in question between CITY OF FAYETTEVILLE and
ENGINEER arising out of or relating to this Agreement or the breach thereof will be
Garver Contract — Professional Engineering Services 8 1/13/2015
decided in a court of competent jurisdiction within Arkansas.
7.3 Audit: Access to Records
7.3.1 ENGINEER shall maintain books, records, documents and other evidence directly
pertinent to performance on work under this Agreement in accordance with generally
accepted accounting principles and practices consistently applied in effect on the date of
execution of this Agreement. ENGINEER shall also maintain the financial information
and data used by ENGINEER in the preparation of support of the cost submission
required for any negotiated agreement or change order and send to CITY OF
FAYETTEVILLE a copy of the cost summary submitted. CITY OF FAYETTEVILLE,
the State or any of their authorized representatives shall have access to all such books,
records, documents and other evidence for the purpose of inspection, audit and copying
during normal business hours. ENGINEER will provide proper facilities for such access
and inspection.
7.3.2 Records under Paragraph 7.3.1 above shall be maintained and made available during
performance on assisted work under this Agreement and until three years from the date of
final payment for the project. In addition, those records which relate to any controversy
arising out of such performance, or to costs or items to which an audit exception has been
taken, shall be maintained and made available until three years after the date of resolution
of such appeal, litigation, claim or exception.
7.3.3 This right of access clause (with respect to financial records) applies to:
7.3.3.1 Negotiated prime agreements:
7.3.3.2 Negotiated change orders or agreement amendments in excess of $10,000 affecting
the price of any formally advertised, competitively awarded, fixed price agreement:
7.3.3.3 Agreements or purchase orders under any agreement other than a formally
advertised, competitively awarded, fixed price agreement. However, this right of
access does not apply to a prime agreement, lower tier subagreement or purchase
order awarded after effective price competition, except:
7.3.3.3.1 With respect to record pertaining directly to subagreement performance,
excluding any financial records of ENGINEER;
7.3.3.3.2 If there is any indication that fraud, gross abuse or corrupt practices may be
involved;
7.3.3.3.3 If the subagreement is terminated for default or for convenience.
7.4 Covenant Against Contingent Fees
7.4.1 ENGINEER warrants that no person or selling agency has been employed or retained to
solicit or secure this Agreement upon an agreement of understanding for a commission,
percentage, brokerage or continent fee, excepting bona fide employees or bona fide
established commercial or selling agencies maintained by ENGINEER for the purpose of
securing business. For breach or violation of this warranty, CITY OF FAYETTEVILLE
shall have the right to annul this Agreement without liability or at its discretion, to deduct
from the contract price or consideration, or otherwise recover, the full amount of such
commission, percentage, brokerage, or contingent fee.
Garver Contract — Professional Engineering Services 9 1/13/2015
7.5 Gratuities
7.5.1 If CITY OF FAYETTEVILLE finds after a notice and hearing that ENGINEER or any of
ENGINEER's agents or representatives, offered or gave gratuities (in the form of
entertainment, gifts or otherwise) to any official, employee or agent of CITY OF
FAYETTEVILLE, in an attempt to secure an agreement or favorable treatment in
awarding, amending or making any determinations related to the performance of this
Agreement, CITY OF FAYETTEVILLE may, by written notice to ENGINEER terminate
this Agreement. CITY OF FAYETTEVILLE may also pursue other rights and remedies
that the law or this Agreement provides. However, the existence of the facts on which
CITY OF FAYETTEVILLE bases such finding shall be in issue and may be reviewed in
proceedings under the Remedies clause of this Agreement.
7.5.2 In the event this Agreement is terminated as provided in Paragraph 7.5.1, CITY OF
FAYETTEVILLE may pursue the same remedies against ENGINEER as it could pursue
in the event of a breach of the Agreement by ENGINEER As a penalty, in addition to
any other damages to which it may be entitled by law, CITY OF FAYETTEVILLE may
pursue exemplary damages in an amount (as determined by CITY OF FAYETTEVILLE)
which shall be not less than three nor more than ten times the costs ENGINEER incurs in
providing any such gratuities to any such officer or employee.
7.6 Arkansas Freedom of Information Act
7.6.1 City contracts and documents, including internal documents and documents of
subcontractors and sub -consultants, prepared while performing City contractual work are
subject to the Arkansas Freedom of Information Act (FOIA). If .a Freedom of
Information Act request is presented to the CITY OF FAYETTEVILLE, ENGINEER
will do everything possible to provide the documents in a prompt and timely manner as
prescribed in the Arkansas Freedom of Information Act (A.C.A. §25-19-101 et seq.).
Only legally authorized photocopying costs pursuant to the FOIA may be assessed for
this compliance.
IN WITNESS WHEREOF, CITY OF FAYETTEVILLE, ARKANSAS by and through its Mayor, and
ENGINEER, by its authorized officer have made and executed this Agreement as of the day and year first
above written.
CITY OF FAYETTEVILLE, ARKANSAS
ENGINEER
By
By:
or ioneld r n
Vice Presid Scott Zotti
ATTEST: A
By: OFL�it #.
Project anager
�o1f
®� • ,\T Y p,� .sG ro.
Ev, FAYETTEVILLE
OF AGREEMENT FOR PROFESSIONAL ENGINEERING SERVICES
Garver Contract — Professional Engineering Services 10 1/13/2015
APPENDIX A - SCOPE OF SERVICES - REVISED
2.1 General
Generally, the scope of services includes surveying, design, and preparation of property acquisition
documents for improvements to relocate City of Fayetteville owned water and wastewater facilities to
accommodate roadway improvements by others, Porter Road — Highway 112/71B Widening and
Interchange Improvements (AHTD Job BB0414) in Fayetteville, Arkansas. The water and sanitary
sewer relocations will be along Highway 112 from Drake Street to Truckers Drive and along the
southern portion of the AHTD Improvements from McConnell Avenue to the Fulbright Expressway.
Specifically, the gravity sewer relocations, up to 15 inch, include approximately 5,000 linear feet, and
the water line relocations, up to 12 inch, include approximately 3,000 linear feet.
2.2 Surveys
2.2.1 Design Surveys
Garver will provide supplemental survey data for designing the project, and this survey will be tied to
AHTD control. Garver will utilize previous survey data by others for AHTD Job BB0414, and assume
the previous data is correct. Previous survey control points will be used for the supplemental survey
and construction by others. Garver will not set any new survey control. In addition to topographic
survey outside the limits previously surveyed, the supplemental survey will include sanitary sewer
manhole rim and inverts, water facilities, and other utilities marked by utility owners. Work beyond
10 days for Design Surveys for a two man survey crew, at 10 hours per day, is Extra Work. The City
of Fayetteville will reimburse Garver for ARKUPS (utility marking). Utility marking beyond $2,500 is
Extra Work.
2.2.2 Property Surveys
Garver will provide supplemental survey data for property surveys for preparing property acquisition
documents. Work beyond 20 hours for Property Surveys for a two man survey crew is Extra Work.
Garver will utilize previous record research, property deeds obtained by others for AHTD Job
BB0414. Garver will subcontract with an abstractor to obtain existing easements, and Garver will
show existing easements on construction drawings and property acquisition documents. The City of
Fayetteville will reimburse Garver for record research. Record research beyond $3,500 is Extra
Work.
2.3 Coordination
Garver will furnish electronic plans and coordinate with all known utility owners potentially affected by
the project. Garver will include the surveyed locations of the observable and marked utilities in the
construction plans. Any special requirements by utility owners will be noted on the construction
drawings. In addition to utilities, Garver will furnish final plans and coordinate approval with AHTD.
Garver will also attend up to a maximum of three coordination meetings with the City of Fayetteville and
other agencies as required. Garver will prepare exhibits for these meetings when appropriate.
Appendix A - Scope of Services 1 of 5 14048160
Porter Road-HWY 112/71 B Widening
and Interchange — AHTD Job BB0414
2.4 Environmental Services
GARVER will a perform wetland delineation for the entire project outside the proposed AHTD right-of-
way. GARVER will prepare a wetland report and submit to the US Army Corps of Engineers
(USACE) requesting a jurisdictional determination if required. If USACE requires mitigation, a
mitigation plan and approval is considered Extra Work outside this agreement. GARVER will also
request authorization to proceed under a Nationwide 404 permit. If an individual 404 permit is
required, it shall be considered Extra Work outside this agreement. For stream crossings, Garver will
notify the Arkansas Department of Environmental Quality (ADEQ) during construction, and the CITY
OF FAYETTEVILLE will pay all permitting fees for the Short Term Activity Authorization(s) (STAA)
outside this agreement. GARVER will note stream crossings on construction drawings. GARVER will
prepare and submit initial clearance letters from the US Fish and Wildlife Service (USFWS) and the
State Historic Preservation Officer (SHPO). If USFWS or SHPO requires a cultural resource survey,
an endangered species survey, or any other items, this shall be considered Extra Work outside this
agreement. GARVER will prepare a Stormwater Pollution Prevention Plan (SWPPP). Surface
disturbance will be limited to less than 5 acres. As such, submittal of the SWPPP and fee to ADEQ is
considered Extra Work.
2.5 Detailed Design
During the detailed design phase of the project, Garver will conduct final designs to prepare
construction plans and specifications, for one construction contract, including final construction details
and quantities, special provisions, and opinion of probable construction cost with AHTD cost sharing.
Garver will conduct a workshop with the City of Fayetteville to review the Detailed Design and make any
needed changes based upon written comments provided by the City of Fayetteville. Garver will also
make final field inspection with City of Fayetteville, make any needed plan changes as a result of the
final field inspection and/or special easement acquisition considerations, and prepare the construction
documents as required to advertise for bids.
2.6 Property Acquisition Documents
Garver will provide mapping as required for preparing easement acquisition documents for the City of
Fayetteville's use in acquiring the property. Documentation will include an individual tract map with
description of temporary and permanent acquisition for each property. The fee for providing property
acquisition documentation is based on permanent right of way and temporary construction easements
for no more than 20 properties.
2.7 Bidding Services
Bidding Services are excluded and may be added by amendment as approved by the City of
Fayetteville and Garver.
2.8 Construction Phase Services
Construction Phase Services are excluded and may be added by amendment as approved by the City
of Fayetteville and Garver. In the event GARVER's Scope of Services under this agreement is not
amended to include construction phase services, the City of Fayetteville assumes all responsibility for
interpretation of the Construction Contract Documents and for construction observation and supervision
and waives any claims against GARVER that may be in any way connected thereto.
In addition, the City of Fayetteville agrees, to the fullest extent permitted by law, to indemnify and hold
GARVER harmless from any loss, claim or cost, including reasonable attorneys' fees and costs of
Appendix A - Scope of Services 2 of 5 14048160
Porter Road-HWY 112/71 B Widening
and Interchange — AHTD Job BB0414
defense, arising or resulting from the performance of such services by other persons or entities and
from any and all claims arising from modifications, clarifications, interpretations, adjustments or
changes made to the Construction Contract Documents to reflect changed field or other conditions,
except for claims arising from the sole negligence or willful misconduct of GARVER.
2.14 Project Deliverables
The following will be submitted to the City of Fayetteville, or others as indicated, by Garver:
1. Three full size copies of the Detailed Design plans, specifications, and opinion of probable
construction cost with cost sharing to the City of Fayetteville.
2. Electronic copies of all correspondence to the City of Fayetteville.
3. Electronic files as requested by the City of Fayetteville and AHTD.
2.15 Extra Work
The following items are not included under this agreement but will be considered as extra work:
1. Redesign for the City of Fayetteville's convenience or due to changed conditions after previous
alternate direction and/or approval.
2. Improvements to water and sewer facilities at locations beyond what is required to
accommodate AHTD improvements.
3. Submittals or deliverables in addition to those listed herein.
4. Geotechnical services.
5. Design of any utilities relocation other than water and sewer.
6. Retaining walls or other significant structural design beyond that required for water and sanitary
sewer relocations.
7. Construction materials testing.
8. Environmental Handling, including NEPA documentation and other environmental clearances
beyond initial coordination letters from SHPO, USACE, and USFWS.
9. Wetland mitigation plans, cultural resource surveys, threatened, endangered, and candidate
species surveys, and any other work related to environmentally or historically (culturally)
significant items.
10. Preparation of AHTD Utility Permits.
11. Coordination with FEMA and preparation/submittal of a CLOMR and/or LOMR.
12. Arkansas Department of Health coordination, approval, and review fee.
13. Bidding and Construction Services.
14. Services after construction, such as warranty follow-up, operations support, etc.
Extra Work will be as directed by the City of Fayetteville in writing for an additional fee as agreed upon
by the City of Fayetteville and Garver.
2.16 Schedule
Garver shall begin work under this Agreement upon receipt of a Notice to
Proceed and shall complete the work in accordance with the schedule below:
Phase Description Calendar Days
Detailed Design 45 days from Notice to Proceed
3.0 Payment
Appendix A - Scope of Services 3 of 5 14048160
Porter Road-HWY 112/71B Widening
and Interchange — AHTD Job BB0414
For the work described herein the CITY OF FAYETTEVILLE, except for property record research and.
ARKUPS, will pay GARVER on an hourly rate basis. The CITY OF FAYETTEVILLE represents that
funding sources are in place with the available funds necessary to pay GARVER.
If any payment due GARVER under this agreement is not received within 60 days from date of
invoice, GARVER may elect to suspend services under this agreement without penalty or liquidated
damages assessed from the CITY OF FAYETTEVILLE.
The table below presents a summary of the fee amounts and fee types for this contract.
WORK DESCRIPTION
FEE AMOUNT
FEE TYPE
ARKUPS (Utility Marking)
$2,500
Direct Cost + 10%
Record Research (Abstractor)
$3,500
Direct Cost + 10%
Design and Property Surveys
$29,860.50
Hourly Rate +
Expenses
Environmental Services
$9,093.75
Detailed Design
$44,588.25
Property Acquisition Documents
$13,200
Bidding Services
$0 (may be added by
amendment)
Construction Services
$0 (may be added by
amendment)
TOTAL FEE
$102,742.50
Except for ARKUPS and Record Research, the CITY OF FAYETTEVILLE will pay GARVER, for time
spent on the project, at the rates shown in Appendix B for each classification of GARVER's personnel
(may include contract staff classified at GARVER's discretion) plus reimbursable expenses including
but not limited to printing, courier service, reproduction, and travel. For ARKUPS and Record
Research, the City of Fayetteville will reimburse Garver the actual amount invoiced to Garver plus a
ten (10) percent administrative fee. The total amount paid to GARVER under this agreement is
estimated to be $102,742.50. The actual total fee may not exceed this estimate without authorization
from the CITY OF FAYETTEVILLE. The rates shown in Appendix B will be increased 4% annually
with the first increase effective on or about June 1, 2015. For any delays beyond Carver's control,
any unused portion of the fee will be increased 4% annually with the first increase on June 1, 2016.
Underruns in any phase may be used to offset overruns in another phase as long as the overall
contract amount is not exceeded. For informational purposes, a breakdown of GARVER's estimated
costs are included in Appendix B.
Expenses other than salary costs that are directly attributable to performance of our professional
services will be billed as follows:
1. Direct cost for travel, long distance and wireless communications, outside reproduction and
presentation material preparation, and mail/courier expenses.
2. Direct cost for subcontract/subconsultant fees.
3. Charges similar to commercial rates for reports, plan sheets, presentation materials, etc.
4. The amount allowed by AHTD ($0.42 per mile) for mileage.
5. $20 per hour for CPS survey equipment use for Environmental Services only, excludes
design and property surveys.
The CITY OF FAYETTEVILLE will pay GARVER on a monthly basis, based upon statements
submitted by GARVER to the CITY OF FAYETTEVILLE for the scope of services described in this
Appendix A - Scope of Services 4 of 5 14048160
Porter Road-HWY 112/71 B Widening
and Interchange — AHTD Job BB0414
agreement. Payments not received within 60 days of invoice date will be subject to a one percent
monthly simple interest charge.
As directed by the CITY OF FAYETTEVILLE, some billable work may have been performed by
GARVER prior to execution of this agreement. Payment for this work will be made in accordance
with the fee arrangement established herein, as approved by the CITY OF FAYETTEVILLE.
Additional Services (Extra Work). For work not described or included herein but requested by the
CITY OF FAYETTEVILLE in writing, the CITY OF FAYETTEVILLE will pay GARVER, for time spent
on the project, at the rates shown in Appendix B for each classification of GARVER's personnel (may
include contract staff classified at GARVER's discretion) plus reimbursable expenses including but
not limited to printing, courier service, reproduction, and travel. The rates shown in Appendix B will be
increased 4% annually with the first increase effective on or about June 1, 2015.
4.0 Appendices
The following Appendices are attached to and made a part of this Agreement:
Appendix B — Hourly Rate Schedule and Estimated Costs
Appendix A - Scope of Services 5 of 5 14048160
Porter Road-HWY 112/718 Widening
and Interchange — AHTD Job BB0414
APPENDIX B
CITY OF FAYETTEVILLE
Porter Rd-HWY 112/71 B Widening and
Interchange - AHTD Job BB0414
ESTIMATED FEE SUMMARY
Title I Services Estimated Fees
ARKUPS (Utility Marking) $2,500.00
Record Research $3,500.00
Design and Property Surveys $29,860.50
Environmental Services $9,093.75
Detailed Design $44,588.25
Property Acquisition Documents $13,200.00
Total for Title I Services $102,742.50
1 of 5
APPENDIX B
CITY OF FAYETTEVILLE
Porter Rd-HWY 112171 B Widening and Interchange - AHTD Job BB0414
DESIGN AND PROPERTY SURVEYS
WORK TASK DESCRIPTION
E-3
S-5
S-4
2 -Man Crew
(GPS Survey)
X-2
T-2
$132.00
$141.00
$107.00
$192.00
$73.00
$87.00
hr
hr
hr
hr
hr
hr
1. Surveys - Topographic
Coordination for Surveys
4
8
Topographic Surveys
100
Data Processing and Drawing and Surface Updates
16
Subtotal - Surveying
4
8
16
100
0
0
2. Surveys - Property
Coordination for Surveys
1
4
Property Surveys
20
Data Processing
8
Adding Existing Easements and Drawing Updates
16
Subtotal - Surveying
1
4
24
20
0
0
Hours 5 12 40 120 0 0
Salary Costs $660.00 $1,692.00 $4,280.00 $23,040.00 $0.00 $0.00
SUBTOTAL - SALARIES: $29,672.00
DIRECT NON -LABOR EXPENSES
Document Printing/Reproduction/Assembly
$20.00
Postage/Freight/Courier
$0.00
Office Supplies/Equipment
$0.00
Communications
$0.00
Survey Supplies
$50.00
Aerial Photography
$0.00
GPS Equipment
$0.00
Computer Modeling/Software Use
$0.00
Traffic Counting Equipment
$0.00
Locator/Tracer/Thermal Imager Equipment
$0.00
Travel Costs (@ $0.42/mile)
$118.50
SUBTOTAL - DIRECT NON -LABOR EXPENSES: $188.50
SUBTOTAL:
SUBCONSULTANTS FEE:
$29,860.50
$0.00
TOTAL FEE: $29,860.50
2 of 5
APPENDIX B
CITY OF FAYETTEVILLE
Porter Rd-HWY 112/71 B Widening and Interchange - AHTD Job BB0414
ENVIRONMENTAL SERVICES
WORK TASK DESCRIPTION
E-5
E-4
E-3
P-1
T-2
X-2
X-1
$187.00
$153.00
$132.00
$113.00
$87.00
$73.00
$54.00
hr
hr
hr
hr
hr
hr
hr
1. Civil Engineering
Wetlands Delineation
6
SHPO and USFW Clearance Letters
4
USACE Nationwide and Wetland Report
12
SWPPP
8
Erosion Control Plans and Details
16
24
Coordination with City
4
QA/QC
8
Subtotal - Civil Engineering
0
0
12
46
24
0
0
2. Structural Engineering
Subtotal - Structural Engineering
0
0
0
0
0
0
0
3. Mechanical Engineering
Subtotal - Mechanical Engineering
0
0
0
0
0
0
0
4. Electrical Engineering
Subtotal - Electrical Engineering
0
0
0
0
0
0
0
Hours 0 0 12 46 24 0 0
SalaryCosts $0.00 $0.00 $1,584.00 $5,198.00 $2,088.00 $0.00 $0.00
SUBTOTAL - SALARIES: $8,870.00
DIRECT NON -LABOR EXPENSES
Document Printing/Reproduction/Assembly
$60.00
Postage/Freight/Courier
$25.00
Office Supplies/Equipment
$0.00
Communications
$0.00
Survey Supplies
$0.00
Aerial Photography
$0.00
GPS Equipment
$120.00
Computer Modeling/Software Use
$0.00
Traffic Counting Equipment
$0.00
Locator/Tracer/Thermal Imager Equipment
$0.00
Travel Costs (@ $0.42/mile)
$18.75
SUBTOTAL - DIRECT NON -LABOR EXPENSES: $223.75
SUBTOTAL:
SUBCONSULTANTS FEE:
TOTAL FEE:
$9,093.75
$0.00
$9,093.75
3 of 5
APPENDIX B
CITY OF FAYETTEVILLE
Porter Rd-HWY 112171B Widening and Interchange - AHTD Job BB0414
DETAILED DESIGN
WORK TASK DESCRIPTION
E-3
E-2
E-1
T-2
C-3
T-1
S-4
$132.00
$108.00
$94.00
$87.00
$130.00
$68.00
$107.00
hr
hr
hr
hr
hr
hr
hr
1. Civil Engineering
Quality Control
4
8
Owner/AHTD/Utility Coordination
24
16
8
Drawings
Cover
1
General Notes and Survey Control
2
4
Design and Water and Sewer Plan and
Profiles (16 sheets)
32
80
100
Construction Details
4
8
8
Construction Quantities and Cost Sharing
2
8
Specifications
12
8
Project Management
40
Owner Workshop
4
Field Inspection
8
Easement Considerations
2
8
Owner and AHTD Comments
4
4
16
Arkansas Department of Health
2
4
Subtotal - Civil Engineering
141
16
104
144
8
8
0
2. Structural Engineering
Subtotal - Structural Engineering
0
0
0
0
0
0
0
3. Mechanical Engineering
Subtotal - Mechanical Engineering
0
0
0
0
0
0
0
4. Electrical Engineering
Subtotal - Electrical Engineering
0
0
0
0
0
0
0
Hours
141 16 104 144
SalaryCosts $18,612.00 $1,728.00 $9,776.00 $12,528.00 $1,040.00 $544.00 $0.00
SUBTOTAL - SALARIES: $44,228.00
DIRECT NON -LABOR EXPENSES
Document Printing/Reproduction/Assembly
$300.00
Postage/Freight/Courier
$25.00
Office Supplies/Equipment
$0.00
Communications
$0.00
Survey Supplies
$0.00
Aerial Photography
$0.00
GPS Equipment
$0.00
Traffic Counting Equipment
$0.00
Locator/Tracer/Thermal Imager Equipment
$0.00
Travel Costs (@ $0.42/mile)
$35.25
SUBTOTAL - DIRECT NON -LABOR EXPENSES: $360.25
SUBTOTAL: $44,588.25
SUBCONSULTANTS FEE: $0.00
TOTAL FEE:
$44,588.25
4 of 5
APPENDIX B
CITY OF FAYETTEVILLE
Porter Rd-HWY 112/71B Widening and Interchange - AHTD Job BB0414
PROPERTY ACQUISITION DOCUMENTS
WORK TASK DESCRIPTION
E-3
S-5
S-4
T-2
X-2
$132.00
$141.00
$107.00
$87.00
$73.00
hr
hr
hr
hr
hr
1. Acquisition Documents
Easement Acquisition Documents
30
80
Coordination with Owner
2
Subtotal - Civil Engineering
2
30
80
0
0
Hours
2 30 80 0 0
Salary Costs $264.00 $4,230.00 $8,560.00 $0.00 $0.00
SUBTOTAL - SALARIES: $13,054.00
DIRECT NON -LABOR EXPENSES
Document Printing/Reproduction/Assembly
$146.00
Postage/Freight/Courier
$0.00
Office Supplies/Equipment
$0.00
Communications
$0.00
Survey Supplies
$0.00
Aerial Photography
$0.00
GPS Equipment
$0.00
Computer Modeling/Software Use
$0.00
Traffic Counting Equipment
$0.00
Locator/Tracer/Thermal Imager Equipment
$0.00
Travel Costs (@ $0.42/mile)
$0.00
SUBTOTAL - DIRECT NON -LABOR EXPENSES: $146.00
SUBTOTAL: $13,200.00
SUBCONSULTANTS FEE: $0.00
TOTAL FEE: $13,200.00
5 of 5
A r :
� ..,. I
i:._ ,._Q�y ff•.. ..., �.— a ';,Y •�p ��!j ��-�"�""„ i ��i�J� � _� r�• I _ r ,.-,•.+'..�r'r.
... � y.���..���.�- �k'"_ _• i�.' s—';�vAy�''' .sA y.�1����', � �1 •I.' { ',;. !
:i:T : I iN L
- -- - _ '.ice `-w '`ti
City of Fayetteville, Arkansas - Budget Adjustment Form (Legistar)
Budget Year Division: Utilities Director Adjustment Number
2015 Dept.: Utilities
Requestor: Cheryl Partain
BUDGET ADJUSTMENT DESCRIPTION / JUSTIFICATION:
A BA is needed in the Water/Sewer Relocations -Bond Projects project for costs associated with an engineering contract
with Garver Engineering, LLC. Garver Engineering LLC will perform the final design and construction phase engineering
services for the water/sewer relocations at the 1/49 Interchange and HWY 112 .
RESOLUTION/ORDINANCE
COUNCIL DATE:
LEGISTAR FILE ID#:
1/26/2015
2015-0054
3arba ra' 7e,W
1/3O/2O15 2:O9 PM
Budget Director
TYPE:
DESCRIPTION:
GLDATE:
POSTED:
Date
TOTAL - -
v.20141 1 13
Increase / (Decrease) Proiect.Sub#
Account Number Expense Revenue Project Sub AT Account Name
5400.5700.5314.00 102,743 - 11011 1501 EX Professional Services
5400.5700.5815.00 (102,743) - 02017 1 EX Sewer Improvements
C:\Users\dmccoy\AppData\Roaming\L5\Temp\a7bd428b-75c6-40ea-84af-71 c9da7dd82c I of