Loading...
HomeMy WebLinkAbout237-05 RESOLUTION• • RESOLUTION NO. 237-05 A RESOLUTION APPROVING A CONTRACT WITH BOSSLER CONTRACTING, INC. IN THE AMOUNT OF $254,600.00 TO REMODEL THE TERMINAL BUILDING AT THE FAYETTEVILLE MUNICIPAL AIRPORT; APPROVING A 10% PROJECT CONTINGENCY IN THE AMOUNT OF $25,460.00; AND APPROVING A BUDGET ADJUSTMENT IN THE AMOUNT OF $40,000.00. BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF FAYETTEVILLE, ARKANSAS: Section 1: That the City Council of the City of Fayetteville, Arkansas, hereby approves a contract with Bossier Contracting, Inc. in the amount of $254,600.00 to remodel the Terminal Building at the Fayetteville Municipal Airport. A copy of the contract marked Exhibit "A" is attached hereto and made a part hereof. Sechon 2: That the City Council of the City of Fayetteville, Arkansas, hereby approves a 10°% project contingency in the amount of $25,460.00. Section 3: That the City Council of the City of Fayetteville, Arkansas, hereby approves a Budget Adjustment recognizing Woolsey Aviation's contribution to the project in the amount of $40,000.00. PASSED and APPROVED this 6w day of December, 2005. ,4%VT1? w•Y O • •,G •▪ Cr. -QP s- • :FAYETTEVILLE' g ;ATTEST. 9snNANSC • or ,yNc$6.',IG,ON``` ,, By: qot. _.!J Moixtb• - SONDRA SMITH, City Clerk APPROVED: By DAN COODY, May • • • CONTRACT THIS AGREEMENT, made and entered into on the (tI h day of bit ,Q fl &r 2005, by and between Bossier Contracting Inc. and the City of Fayetteville: WITNESSETH: That Bossier Contracting Inc., of Siloam Springs, Arkansas, for the consideration hereinafter fully set out, hereby agrees with the City of Fayetteville as follows: 1. That Bossier Contracting Inc. shall furnish all the materials, and perform all of the work in manner and form as provided by the following enumerated Specifications, and Documents, which are attached hereto and made a part hereof, as if fully contained herein and are entitled: Drake Field Terminal Building Renovation Project Advertisement for Bids Instructions to Bidders Bid and acceptance thereof Performance Bond "Attachments A & B" Payment Bond General Conditions Supplemental Conditions Specifications Drawings -15 Sheets 2. That the City of Fayetteville hereby agrees to pay to Bossier Contracting Inc. for the faithful performance of this Agreement, subject to additions and deductions as provided in the Specifications or Bid, in lawful money of the United States, the amount of 254,600 and 00/100 dollars ($254,600.00). 3. The Work will be completed and ready for final payment in accordance with the General Conditions within 182 days after the date when the Contract Time commences to run, as provided in the Notice to Proceed. 4. Liquidated Damages: The City of Fayetteville and Bossier Contracting Inc., recognize that time is of the essence of this Agreement and the City of Fayetteville will suffer financial loss if the Work is not completed within the times specified above, plus any extensions thereof allowed in accordance with the General Conditions. They also recognize the delays, expense, and difficulties involved in proving the actual loss suffered by City of Fayetteville if the Work is not completed on time. Accordingly, instead of requiring any such proof, City of Fayetteville and Bossier Contracting Inc. , agree that as liquidated damages for delay (but not as a penalty) Bossier Contracting Inc. shall pay City of Fayetteville, 150 Dollars ($150.00) for each day that expires after the time specified in Paragraph 3 for completion and readiness for final payment. C:\DOCUMENTS AND SETTINGS ICHRISTIEK WDD\LOCAL SETTINGS\TEMPORARY INTERNET FILES IOLKEFCONST CONTRACT REMODEL TERMINAL REVISED.DOC Section 00500 - 1 • • 5. That within 30 days of receipt of an approved payment request, the City of Fayetteville shall make partial payments to Bossler Contracting, Inc., on the basis of a duly certified and approved estimate of work performed during the preceding calendar month by Bossler Contracting, Inc., LESS the retainage provided in the General Conditions, which is to be withheld by the City of Fayetteville until all work within a particular part has been performed strictly in accordance with this Agreement and until such work has been accepted by the City of Fayetteville. 6. That upon submission by Bossler Contracting, Inc. of evidence satisfactory to the City of Fayetteville that all payrolls, material bills, and other costs incurred by Bossler Contracting, Inc. in connection with the construction of the work have been paid in full, final payment on account of this Agreement shall be made within 60 days after the completion by Bossier Contracting, Inc., of all work covered by this Agreement and the acceptance of such work by the City of Fayetteville. 7. It is further mutually agreed between the parties hereto that if, at any time after the execution of this Agreement and the Surety Bond hereto attached for its faithful performance and payment, the City of Fayetteville shall deem the Surety or Sureties upon such bond to be unsatisfactory or if, for any reason such bond ceases to be adequate to cover the performance of the work, Bossler Contracting, Inc. shall, at its expense, within 5 days after the receipt of notice from the City of Fayetteville, furnish an additional bond or bonds in such form and amount and with such Surety or Sureties as shall be satisfactory to the City of Fayetteville. In such event, no further payment to Bossler Contracting, Inc. shall be deemed to be due under this Agreement until such new or additional security for the faithful performance of the work shall be furnished in manner and form satisfactory to the City of Fayetteville. 8. Changes, modifications, or amendments in scope, price or fees to this contract shall not be allowed without a prior formal contract amendment approved by the Mayor and the City Council in advance of the change in scope, cost or fees. 9. Freedom of Information Act. City contracts and documents prepared while performing city contractual work are subject to the Arkansas Freedom of Information Act. If a Arkansas Freedom of Information Act request is presented to the City of Fayetteville, Bossler Contracting, Inc., will do everything possible to provide the documents in a prompt and timely manner as prescribed in the Arkansas Freedom of Information Act (A.C.A. §25-19-101 et. Seq.). Only Legally authorized photocopying cost pursuant to the FOIA may be assessed for this compliance. C:\DOCUMENFS AND SETTINGS\CHRISTIEK. W DD.LOCAL SETTINGS \TEMPORARY INTERNET FILES\OLKEF\CONST CONTRACT REMODEL TERMINAL REVISED DOC Section 00500 - 2 IN WITNESS WHEREOF, the parties hereto have executed this Agreement on the day and date first above written, in three (3) counterparts, each of which shall, without proof or accounting for the other counterparts be deemed an original Contract. BOSSLER CONTRACTING INC. WITN :+.•: By Title ATTEST: CITY OF FAYETTEVILLE 14"3,arTar~----- 4 SO DRA SMITH, City Clerk ` .................. c G• c•; O o •..p .SJ: FAYETTEVILLE; • ••%9s•9�,KANS?� J).,. ,ti,;y :.. re By 14 � . D N COODY, Mayol C:\DOCUMEN TS AND SETTINGS \CHRISTIEK. W DD\LOCAL SETTINGS \TEMPORARY INTERNET FILES\OLKEF\CONST CONTRACT REMODEL TERMINAL REVISED DOC Section 00500 - 3 • Drake Field Renovation Fayetteville, Arkansas WDD JOB # 05-054 "ATTACHMENT A" Page 1 of 2 • General Supplementary and other Conditions of the Contract are those contained in the Project Manual dated October 5, 2005, and are as follows: DOCUMENT NO. TITLE 00100 BID SOLICITATION 00200 INSTRUCTIONS TO BIDDERS 00300 EXISTING CONDITIONS 00400 BID FORM 00600 BONDS 00700 GENERAL CONDITIONS 00800 SUPPLEMENTARY CONDITIONS 00865 WAGE RATE REQUIREMENTS PAGES 1 4 2 4 1 41 8 6 The Specifications are those contained in the Project Manual dated October 5, 2005, and are as follows: SECTION 01100 01210 01300 01500 01640 02050 05400 06100 06400 07200 07850 07900 08100 08200 08400 08700 TITLE SUMMARY OF WORK ALLOWANCES SUBMITTALS AND SUBSTITUTIONS TEMPORARY FACILITIES AND CONTROLS 3 OWNER FURNISHED PRODUCTS 3 DEMOLITION FOR INTERIOR RENOVATION 4 COLD FORMED STRUCTURAL STEEL FRAMING 5 ROUGH CARPENTRY 4 ARCHITECTURAL WOODWORK 5 INSULATION 2 FIRESTOPPING 5 JOINT SEALANTS 6 HOLLOW METAL DOORS AND FRAMES 5 WOOD DOORS 4 ALUMINUM STOREFRONT 3 HARDWARE 6 PAGES 5 1 10 08800 GLAZING 3 09250 GYPSUM DRYWALL 10 09310 TILE 7 09510 ACOUSTICAL CEILINGS 3 09650 RESILIENT FLOORING 6 09680 CARPET 5 09900 PAINTING 5 09950 GLAZE COATING 2 10155 TOILET PARTITIONS 6 10520 FIRE PROTECTION SPECIALTIES 2 10800 TOILET AND BATH ACCESSORIES 2 15010 GENERAL MECHANICAL REQUIREMENTS 12 15240 VIBRATION ISOLATION 2 15250 MECHANICAL INSULATION 2 15411 SANITARY DRAIN, WASTE AND VENT PIPING SYSTEM 4 15412 DOMESTIC WATER PIPING SYSTEM 3 15440 PLUMBING FIXTURES AND TRIM 3 15890 LOW PRESSURE DUCTWORK AND ACCESSORIES 3 16010 GENERAL ELECTRICAL REQUIREMENTS 8 16110 RACEWAYS 4 16120 WIRES AND CABLES 3 16130 BOXES AND ENCLOSURES 2 16140 WIRING DEVICES 4 16190 SUPPORTING DEVICES 3 16195 ELECTRICAL IDENTIFICATION 3 16510 LIGHTING FIXTURES 7 • • • Drake Field Renovation Fayetteville, Arkansas WDD JOB # 05-054 "ATTACHMENT B" Page 1 of 1 The drawings arc as follows and are dated October 27, 2005, unless a different date is shown below: SHEET NO. TITLE DATE CS PROJECT INFORMATION A1.0 OVERALL FLOOR PLAN AI.I ENLARGED DEMOLITION PLAN PHASE 1 AI.2 ENLARGED FLOOR PLAN PHASE I A I.3 REFLECTED CEILING PLAN PHASE 1 A2.1 MILLWORK ELEVATIONS INTERIOR ELEVATIONS A2.2 ELEVATIONS A2.3 MILLWORK. SECTIONS A3.1 FINISH SCHEDULES DOOR & WINDOW TYPES P1.1 PLUMBING PLAN M1.1 MECHANICAL PLAN M2.1 MECHANICAL DETAILS AND SCHEDULES E1.1 ELECTRICAL POWER PLAN E2.1 LIGHTING PLAN E3.1 ELECTRICAL NOTES ADDENDA NO. DATE PAGES 1 11-11-05 6 THE ANIOR ICAN INSTITUTE OF ARCH*CTS Premium Amount Based or, F:nai Contract Amount E'nnd No. ARD0002'1172 AIA Document A312 Performance Bond Any VSw,arts :aCor&.c'o1, Ent, . Owr.I r 3,211 racy Nm te c,Wlea Y'J Y wrw. 1“11{110•• CONTRACTOR (Name and Address) BOSSLER CONTRACTING, INC. P.O. BOX 1008 SILOAM SPRINGS, AR 72761 OWNER (Name and Address): CITY OF FAYETTEVILLE 113 WEST MOUNTAIN, ROOM 372 FAYETTEVILLE, AR 72701 CONSTRUCTION CONTRACT Date. Amount: $ 254,600.00 Descnption (Name and Location). RENOVATION OF THE DRAKE FIELD TERMINAL BUILDING @ THE FAYETTEVILLE MUNICIPAL AIRPORT SURETY (Name and Pnneple Place or Business). MID-CONTINENT CASUALTY COMPANY P.O. BOX 1409 TULSA, OK 74101 I 11I1111111111VVICN'V�q���Vll Doc ID. R corded F e Amt: Waehlnot B tte St 00939 000007 Tvoe: LIE 12/0 /2005 a 08:31 67 AM $6.00 Pace 1 f 7 n Coun v. AR mos C1 cult C erk F 1sB027-00000548 BOND Date (Not earlier than Construction Contract Date). Amount $ 254,600.00 Modifications to this Bond: CONTRACTOR AS PRINCIPAL COMPANY: (Corporate Seal) BOSSLER CONT 'TING, IN Signature. Name and itle , btei G "Etas VP opent-t A' -S (Any additional signatures appear on page 3) IX) None LJ See Page 3 SURETY COMPANY: -- (Corporate S MID-CONTINENT .ALTY COMPANY Signatu Name and KIMBERLY L. BABB , Atto ney-in-Fact FOR INFORMATION ONLY -Name, Address and Telephone AGENT OR BROKER' Babb Bonding, Inc P.O. Box 6255 Sherwood, AR 72124 OWNER'S REPRESENTATIVE (Architect, or Engineer or other party). Green Anderson Engineers, Inc. 2233 N. Green Acres Road Fayetteville, AR 72703, ??. ?? ALA DOCUMENT A311 PERFORMANCE BOND AND PAYMENT BOND DECEMBER 1984 ED., AIA o THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W. WASHINGTON D C 70006 THIRD PRINTING • MARCH 1987 A 312-1964 1 1. I ne uontractcr ane ine :surety. joir.uy arc severally. Bind themselves, their heirs. executors. agaistrators. successors, and assigns to the Owner forarformance �.! the Construction Contract. which is incorporated herein y re;erence. 2. li the Contractor perforns the Construction Contract. .'.3 Surely and ;he Contractor shall have r.o obligation ender this Sand, except to pannepate ;n conferences as erovided in Subparagraph 11. 5. If there is nc Owner Default, the Surety's obligation :aider This Bond shall arise after. 3.1 The Owner has notified the Contractor and the Surety at its address described in Paragraph 10 below That the Owner is considering declaring a Contractor Default and has requested and attempted to arrange a conference with the Contractor and the Surety to be held not later than fifteen days after receipt of such notice to discuss methods of performing the Construe tion Contract. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reason- able time to perform the Construction Contract, but such an agreement shall not waive the Owners right. if any. subsequently to declare a Contractor Default; and 3.2 The Owner has declared a Contractor Default and formally terrninated the Contractor's richt to complete the contract. Such Contractor Default shall not be de- clared earlier than twenty days after the Contractor and the Surety have received notice as provided in Sub- paragraph 3.1; and 3.3 The Owner has agreed to pay the Balance of the Contract Price to the Surety in accordance with the terms of the Construction Contract or to a contractor selected to perform the Construction Contract in accor- dance with the terms of the contract with the Owner. 4. When the Owner has satisfied the conditions of Para- graph 3, the Surety shall promptly and at the Surety's ex- pense take one of the following actions: 4.1 Arrange for the Contractor, with consent of the Owner, to perform and complete the Construction Contract; or 4.2 Undertake to perform and complete the Construc- tion Contract itself, through its agents or through inde- pendent contractors; or 4.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Con- struction Contract, arrange for a contract to be pre- pared for execution by the Owner and the contractor selected with the Owners concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds Issued on the Construction Contract, and pay to (he Owner the amount of damages as described in Paragraph 6 in ex- cess of the Balance of the Contract Price incurred by the Owner resulting from the Contractor's default; or 4.4 Waive its rights to perform and complete. arrange for completion. or obtain a new contractor and with AIA DOCUMEN T A312 PERFORMANCE BOND AND PAYMENT BONO DEC reasonane promptness unser the c:rcurrstarces .1 After Irvesfigau etermine the amount for which it may be liable to the er and, as soon as practicable after the amount is determined. tender payment therefor lc the Owner, or .2 Deny liability in whsle or in part and notify the Owner citing reasons therefor. 5. If the Surety does nct crccced as provided in Paragra:H. d wuh r. asonab:e promptness. the Surely shat be deemed to be in defau't on this Bond fifteen days after receipt cf ar additional written notice from the Comer to the Surety demanding tnal the Sere:y perform its obications under this Bond, and the Owner shall be entitled to enforcn any I'r.I.Irdy av-ai L'rh'r, In the Ovine!. If 'h:; Sir.et'y Il:nora.atx provided in Subparagraph 4.4, anu the Owner refuses the payment tendered or the Surety has denied liability. in whole or in pari, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. 6. After the Owner has terminated the Contractor's right to complete the Construction Contract, and if the Surety elects to act under Subparagraph 4.1. 4.2, or 4.3 above, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surely shall not be greater than those of the Owner under the Construction Contract. To the limit of the amount of this Bond, but subject to commitment by the Owr.er of the Balance of the Contract Price to mitigation of costs and damages on the Construction Contract, the Sure- ty is obligated without duplication for. 6.1 The responsibilities of the Contractor for correc- tion of defective work and completion of the Construc- tion Contract: 6.2 Additional legal, design professional and delay costs resulting from the Contractor's Default, and re- sulting from the actions or failure to act of the Surety under Paragraph 4: and 6.3 Liquidated damages. or if no liquidated damages are specified in the Construction Contract, actual dam- ages caused by delayed performance or non-perfor- mance of the Contractor. 7. The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Con- struction Contract, and the Balance of the Contract Price shall not he reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than (he Owner or its heirs. executors, administrators, or successors. 8. The Surety hereby waives notice of any change, includ- ing changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obliga- tions. 9. Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after Contractor Default or within two years after the Contractor ceased working or wrthln two years aftter the Surety refuses or fails to perform its obligations under this Bond, whichever oc- curs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of :imitation avail - A 312-1984 2 EMBER 1984 ED. AIA o THE AMERICAN INSTITUTE OF ARCHITECTS. 1735 NEW YORK AVE . N W . Y/ASH:NGTON 0 C. 20006 THIRD PRINTING -MARCH 1987 • aoie tc sureties as a cetense in the;unsaicaor or ;re suit • shall be applicable 1C. Notice to the Surety. the Owner or the Contractor shall to mailed or delivered to the address shown on the sig- nature page. 11. When this Bond has been furnished to comply with a statutory or other legal requirement in the locatior. where construction was to be performe.f. any prevision in this Bond conflicting with said statutory or legal requirement snail be deemed deleted herefrom and provisions ccn- `crrning to such statutory cr other twat requirement shall he deemed incorporated herein The Intent is that this lion(' shall he consdhued a:; a I.lelutwv bona anu not r!; a common law bond. ;2 DEFINITIONS 12.1 Balance of the Contract Price The total amount payable by the Owner to the Contractor under the Construction Contract after ail proper adjustments have been made, including allowance to the Con - MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: racier 31 any amounts ren.sIvec cr to oe rerervec cy the Owner in settlement surarce or cher claimsfor damages to which the o.ntractor is entitled, re- duced by all valid and proper payments made to or on behalf of the Contractor under the Construction Con- tract. 12.2 Construction Contract: The agreement between the Owner and the Contractor :dentiSE: on :he sig- nature pace, including all Contract Documents art cnarges there D. 12.3 Contractor Default Failure of the Contratcr. wh:cn has neither been remedic-d nor waived, to pZr- loi:) or liIIT!`Iwi`:C to comply alit, II.I Cnui of Uhe Construction Contract. 12.4 Owner Default. Failure of the Owner. which has neither been remedied nor waived. to pay the Con- tractor as required by the Construction Contract or to perform and complete or comply with the other terir.s thereof. (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL Company Signature: Address: SURETY (Corporate Seal) Company me and Title: abler f L. Bass' ✓R bplrw tf JKS Signatu Address. (Corpora - Seal) BB Attorney -in -Fact me and Tale: AN DOCUMENT A312 PERFORM.ANE BONG AN PAYMENT BOND DECEMBER 1944 30. AIA 0 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE.. N W. WASHINGTON. D C 20006 THIRD PRINTING • MARCH 1967 A312-1984 3 'toad No. P.L;D0002".i?2 THE AMERICAN INSTITUTE OF ARCHITECTS MA Document A312 Payment Bond Any unp,nu nln•ncs to Cont.cvo% Scantly. Corte or Other party w4 be conr,wna dwtl wrier, •pd'ud•. CONTRACTOR (Name and Address): 3OSSLER CONTRACTING, INC. P.O. BOX 1008 SILOAM SPRINGS, AR 72761 OWNER (Name and Address): CITY OF FAYETTEVILLE 113 WEST MOUNTAIN, ROOM 372 SURETY (Narne and Principle Place of Business) MID-CONTINENT CASUALTY COMPANY P.O. BOX 1409 TULSA, OK 74101 FAYETTEVILLE, AR 72701 CONSTRUCTION CONTRACT Date: Amount: $ 254,600.00 Description (Name and Location). RENOVATION OF THE DRAKE FIELD TERMINAL BUILDING © THE FAYETTEVILLE MUNICIPAL AIRPORT BOND Date (Not earlier than Construct:on Contract Date) Amount: $ 254,600.00 Modifications to this Bond: x None CONTRACTOR AS PRINCIPAL COMPANY: (Corporate Seal) ROSS LCR CONT ING, INC. Signature: Name an re • itle: ,P46ecuL.BSss 07-„7`nafo.+S (Any additional signatures appear on page 6) See Page 6 SURETY COMPANY: Corporate Seal) MID-CONTINEN A LrY COMPANY Signal Name and KIMBERLY L. BABB, Attorney -in -Fact FOR INFORMATION ONLY -Name. Address and Telephone AGENT OR BROKER. Babb Bonding, Inc P.O. Box 6255 Sherwood, AR 72124 OWNER'S REPRESENTATIVE (Architect. Engineer or other party) Green Anderson Engineers, Inc. 2233 N. Green Acres Road Fayetteville, AR 72703, 77, ?? AIA DOCUMENT A312 PERFORMANCE DOND AND PAYMENT BOND DECEMBER 1984 E0.. MAO THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE.. N.W . WASHINGTON, D.0 20006 WIRD PRINTING - MARCH 1987 A312.1904 4 1. The Contra:tor and the Surety. jointlyseverally, :::ind themselves, their heirs, executers. a Inislra fors, successors. and assigns to the Owner to pay for labor, materials and equipment fumishec for use In the perror- rmance of the Construction Contract, which is incorpo- rated herein by reference. 2. 'Mth respect to the Owner, this eb':gat'on shall be Hell and void if the Contractor 2.1 Promptly makes payment. direst:y. w irlrirecdy. for a!l sums due Claimants, and 2.2 Defends. indemnifies and horis harmless We O vner (rain claims, ( enn: d ,. lien; or f.uds by; ny person or entity whose claim, demand. igen or suit is ;or the payment for labor. materials. or equipment fur- nished for use in the perforrnance of the Construction Contract. provided the Owner has promptly notified the Contractor and the Surety (at the address descnbed in Paragraph 12) of any claims, demands. liens, or suits and tendered defense of such claims, demands, liens or sults to the Contractor and the Surety, and provided there is no Owner Default. 3. With respect to Claimants, this obligation shall be null and void if the Contractor promptly makes pay- ment, directly or indirectly, for all sums due 4. The Surety shall have no obligation to Claimants under this Bond until: 4.1 Claimants who are employed by or have a direct contract with the Contractor have given notice to the Surety (at the addres described in Paragraph 12) and sent a copy, or notice thereof, to the Owner, stating that a claim is being made under this Bond and, with substantial accuracy, the amount of the claim. 4.2 Claimants who do not have a direct contract with the Contractor: .1 Have furnished written notice to the Con- tractor and sent a copy, or notice thereof, to the Owner, within 90 days after having last performed labor or last furnished materials or equipment included in the claim stating, with substantial accuracy, the amount of the claim and the name of the party to whom the materials were furnished or supplied or for whom the labor was done or performed; and .2 Have either received a rejection in whole or in part from the Contractor, or not received within 30 days of furnishing the above no- tice any communication from the Contractor by which the Contractor has indicated the claim will be paid directly or indirectly; and .3 Not having been paid within the above 30 clays, have sent a written notice to the Surety (at the address descnbed in Paragraph 12) and sent a copy. or notice thereof. to the Owner, stating that a claim is being made under this Bond and enclosing a copy of the previous written notice furnished to the Contractor. 8. When the Claimant-sa isfied ;he conditions of Paragraph 4, the Surety snail promptly and at the Surety's expense take the following actions: 6.1 Send an answer to tna Clamant, with a copy to the Owner, within 45 days after receipt of the claim, stat'nc the amounts that are undisputed and the basis for challenging any amounts that are rfispc'.ed 6.2 Pay cr arrange fcr payment of any undisputed amounts. 7. Th ) Surety's total eblioa:ion s`all not exceei1 the amount of this Bond. and the amount of this Bail shall be crcrlitc/.I for any payments ill,;tla in yew; faith by :I le f;wrh, 8. Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the perfor- mance of the Construction Contract and to satisfy claims. if any, under any Construction Performance Bond. By the Contractor furnishirq and the Owner accepting this Bond, they agree that all furds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and the Surety under this Bond, subject to the Owner's prior- ity to use the funds for the completion of the work 9. The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelat- ed to the Construction Contract. The Owner shall not be liable for payment of any costs or expenses of any Claim- ant under this Bond, and shall have under this Bond no obli- gations to make payments to. give notices on behalf of, or otherwise have obligations to Claimants under this Bond. 10. The Surety hereby waives notice of any change. including changes of time, to the Construction Contract or to related subcontracts. purchase orders and other obligations. 11. No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent juris- diction in the location in which the work or part of the work is located or after the expiration of one year from the date (1) on which the Claimant gave the notice recuired by Subparagraph 4 1 or Clause 4.2.3, or (2) on which the last labor or service was performed by anyone or the last mate- rials or equipment were furnished by anyone under the Con- struction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 12. Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the signature page Actual receipt of notice by Surety, the Owner or the Contractor, however accomplished, shall be sufficient compliance as of the date received at the address shown on the signature page 13. When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions con- forming to such statutory or other legal requirement shall be deemed incorporated herein The intent is that This 5. If a notice required by Paragraph 4 is gven by the Owner to the Contractor or to the Surety. that is sufficient compliance. AIA DOCUMENT A312 PERFORMANCE BOND AND PAYMENT BOND DECEMBER 1984 ED. MAO THE AMERICAN INSTITUTE OF ARCHITECTS. 1735 NEW YORK AVE., N.W. WASHING ION, C.0 20006 THIRD PRIN T W G . MARCH 1907 A312.1984 5 Bond shall be construe° as a statutory bend .d nct as a common law bondii 14. Upon request by any person or entity appearing to be a atential beneficiary of this Bond, the Contractor shall promptly furnish a copy of this Bond or shag permit a copy :u be made. .5. DEFINITIONS 15.1 Claimant An indiviCual or entity having a r•irect contract with the Contractor or with a subcontractor of the Contractor to furnish labor. meter:els or equip- ment for use in the performance of the Contract The intent of tliis Bond skill be to Includ` Without (notal tion in the terms "labor, materials or eauipmenl" that part of water, gas, power, light, heat, cit. gasoline, telephone service or rental equipment used in the N1ODIFICATIONS TO THIS BOND ARE AS FOLLOWS' Construction Contract, amcicral and engineering serv:ces required for peri nce of the ...fork of the Contractor and the Conlrau ars subcontractors. and all other Mems for which a mechanic's her may be asserted in the jurisdiction where the labor. materials or equipment were furnished. 15.2 Construction Contract The agreement between the Owner and the Contractor ident:hed on t: -.e sIg- nah:re pane. including a:l Contract Documents and changes thereto 15.3 Owner Default. Failure of the Owner, which has neither been remcd;cd nor wn:ved, to pev the Cnn- :raeinl ion:I:red by ttca t: r s'ru';ion 1 onhi rt or In perform and complete or comply ;'lith the other terms thereof. (Space is provided below for additional signatures of added parties, other than those appearing en the cover page ) CONTRACTOR AS PRINCIPAL Company: BOSSLER CONTRACTING, INC. Signature Name a Title -v ,tort Address: P.O. BOX 1008 SILOAM SPRINGS, AR 72761 SURETY (Corporate Seal) Company MID-CONTINENT CASU (Corporate Seat) Y COMPANY ///Lecoo_ Signature. .� "w Name a + Till KIMBERLY L BB. Attorney-INFact Address. P.O BOX 14 9 TULSA. OK 74101 AIA DOCUMENT A313 PERFORMANCE BOND AND PAYMENT BOND DECEMBER 1984 ED. MAO THE AMERICAN INSTITUTE OF ARCHITECTS, 1736 NEW YORK AVE , N.W., WASWNGTON, 0 C. 20006 THIRD PRINTING - MARCH 1987 A312-1984 6 MID-WNTINENT CASUALTY CONY Tulsa, Oklahoma Know all Men by these presents: That the MID-CONTINENT CASUALTY COMPANY, a corporation of the State of Oklahoma, having its principal office in the city of Tulsa, Oklahoma, pursuant to the following By -Law, which was adopted by the Stockholders of the said Company on March 13th, 1947, to -wit . - , "Article tV, Section 7. - The Executive Officers of the Company shall have power and authorityto,appoint; for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof, one mare Resident Vice President,. Resident Assistant - Secretaries and Attorneys-in-Factand atany.time to remove any such -Resident Vice President, Resident Assistant Secretary, or Attorney -in -Fact and revoke the power and authority given him.`. None of such appointees need be Directors of the Company:" - The Company does -hereby constitute and app " - - Rogers, individually of SHERWOOD, AR its true and lawful attorney(s)-in-fast, to execute, seal and deliver for and on its'behalfas Surety, and, as its act and deed, ' Any and all bonds and undertakings:of Suretyship _ • -' • And the execution ofsuch instnunmt(i) in pursuance of these -presents, shall be as binding upon the said' MID-CONTINENT" CASUALTY COMPANY, as fully and amply, to all intents and purposes, as if the same had been duly executed and acknowledged by its regularly elected officers at its principal office in Tulsa, Oklahoma. • • IN WITNESS WHEREOF,: presents this ` 03 ATTEST: MID-CONTINENT CASUALTY COMPANY day of June ties executed and attested these 2005 4l 15 • SARA ANDERSON ; ASSISTANT'SECRETARY . TODD BAZATA r ',' VICE PRESIDENT, On this 03 ' ' - day of-. June ., 2005 before me, a Notary Public of the State of Oklahoma in and „' for the County of Tulsa, came the individual to me personally known to, be the officer described in, and who executed the'preieding instriunent, Wand he acknowledged the execution ofthe seine, and being by me drily sworn, said that he -is the therein dci&ibed and authorized °MTteer of the- ' MID-CONTINENT CASUALTY COMPANY aforesaid, and that the seal affixed to the preceding instrument is the corporate of said Company, and the said corporate seal and hissigature as such officer were duly affixed to the said instrument,by. he authority and direction of the said Company, and that Article, IV, Section 7, of the By -Laws of said Company, referred to lathe precechng instrument, is now in force. IN TESTIMONY WHEREOF, I have hereunto ser my bend and affixed my official seal at the City of Tulsa, the day and year fust above written. • Oe LA ��'"Commission p 99009381 ' STATE OF OK[sl� LAHO.4.1A41.47 yb ' e.�= mmissio_n exp. es 06-07-07 -: coUNTY or TULSA 7' V IOC' : . CZE �Q • a. �StO r • },' Notary Public • :.:SARA ANDERSOI%fr f/[. -S' ( Secretary of MID-CONTINENT CASUALTY COMPANY do hereby certify that the foregoing �( extracts of the By -Laws and of A ResdhHlon'of the Board of Directors of this corporation, and of a Power of Attorney issued pursuant thereto, are' true and correct, and that both the By -Laws, the Resolution and the Power of Attorney are still in full force and effect. This certifies that sayfaesiniile or meehuucalr ced ai re of anyofficer of file Ca and C seal, wherever e Y -produced gnatu Company Company appearing upon a power of attorney ensued 7:. by the Company, shall be valid and binding upon the Company with the same force and effect as though manually affixed.. • IN WETNESS WHEREOF, I hhyfhereunto set my hand and Minced the facsimile seal of said corporation ' 401 CA .. fi?;� this day or' U ✓l IiiL- is7rt1' 3 ''frE /m .. Hz Date/Tire NUT-ZZ-2UU51TUtl 09:33 870 535 8318 From: Celia Bolen At: Fust Arkansas insurance Fax10�5355318 To: Leah Hrdlid,lu 4iipata: 11/22!2005 05:37 AM Page 5 0112 P. 005 COVERAGES THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REWIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WMICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, 1HE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN 15 SUBJECT TO ALL THE TERMS. EXCLUSIONS AND CONDITIONS OF SUCH POLLIIICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. ACORD ,N CERTIFICATE OF LIABILITY INSURANCE DATE(BW,NYYM1) 11/22/2005 POLLS* FF DATEAMWDO/ PIOOUCER (870) 541-0020 First Arkansas Insurance/Pine Bluff THIS CERTIFICATE IS ISSUED AS A MATTER OF ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, ALTER THE COVERAGE AFFORDED BY THE POLICIES INFORMATION EXTEND OR BELOW. PO Box 8367 Pine Bluff, AR 716114367 INSURERS AFFORDING COVERAGE NAIC 0 aaLaED Bossier Contracting. Inc. 116 S Broadway Siloam Springs, AR 72761- NAAERA Cypress Insurance Company uAa&rry INSURER 0 ARC030009 NsFERc 3114/2006 CURER 0 F e.9.AER E X COVERAGES THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REWIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WMICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, 1HE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN 15 SUBJECT TO ALL THE TERMS. EXCLUSIONS AND CONDITIONS OF SUCH POLLIIICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. Lrn N]Ro 11Tl OF MMIAMfl POLICY MJYBER POLLS* FF DATEAMWDO/ EC1TNE YI PDXPRATO OAATSTEftIStQ!Yn LINTS A GENERAL coats/CAL LABILITY GOON. C1Aua5MADE uAa&rry DOOR ARC030009 311412005 3114/2006 EACH CCCLI ENCE F 1,000,000 X 'IMAGE ID PIEw5ES1E Runcu mama) 1 100.000 X .ED DIP(AN m. p..m) $ 5,000 PERSOPAL s ADV PLANT 1 1,000,000 GEAERAL AGGREGATE 1 2,000.000 GEM AGGREGATE POLICY LNIT APPLIES PER n LOC PRODUCTS- COW/CFAG G 1 1,000,000 n ..FR A ALROATaeaE LMBLm ANY AuraaW ALL OAMFD AUTOS OAuras SEDLLED ROS BRED AUTOS PDfaOMTED AUTOS ARC030009 3/14/2005 3/14/2006 COMOIED SNGLE OM it. *WWII { 1,000,000 BCDAY PLLAY (Par peso') { X X Breit WARY (Pe.cREeS) $ X PRCPERTY OMIACE (Pe wont) { GARAGE LABILITY AM ALTO ARO CtLY- EA ACCDENT { ODER TANMJTO AUTO CPLY EA ACC 5 AGG 1 A EXCESSAMBREL LA LABRnY 1 Occup 1 amess stem ARC030009 311412005 3114/2006 EACH OCCJME,VLE { s 1,000,000 1,000,000 AGGREGATE CED REIENnn $ { CT al { $ WORKERS E.PLOTERY Pi ANY 0PRIETORN OFFICEWI,EL6ER SPEII yywN AI.Pnb.CNL PROV51O COIPENSCON ND IA LMM AM•EPoEXEIVE EXCLUDED, M WT: INT TORY LLINTS On. ER E L EACH KCOEM { E L. DISEASE - EAENTLOYEE { ISKA C b.Ier E L. DISEASE - PQICY LIMIT 1 OTHER DESCRIPTOR OF OPERATIONS 1 LOCATION! 1 VEHCL EB 1 EIS MOO ADDED BY ENDORSEMENT 1 SPECIAL PROVISION! Project Name: Drake Field Terminal Building Renovation Owner Is the certificate holder. Architect Is Wittenburg, Colony, d Davidson, Inc.; 2434 East Joyce Blvd; Suite 10; Fayetteville, AR 72703 CERTIFICATE HOLDER CANCELLATION City of Fayetteville 113 West Mountain Street Fayetteville. AR 72701 - ACORD 25 (2001/08) SHOULD PRY 0E THE ABOVE DES CASED POLCES BE CANCELLED BEFORE 1)U EXPIRATION DAT! TIEREOF, TIDE WRFC INSURER WAS ENDEAVOR TO IML 10 DAYS WRITTEN NOTICE TO THE CEATFICATE HOLDER NAMED TO ALE LEFT. BUT FALUIE TO DO W WALL PPM NO OBLIGATxxL OR UNARY CO AHY HIND UPON THE INSURER. ITS ACENTS OR REPRESENTATIVES NMMORBEEP RE PRE SENTATNE ®ACORD CORPORATION 1988 Rx Dale/Tiee NOV-22-2005(TUE) 09:33 From: CeIm Bolen At: Fut Manns Insurance Fax1D 535-8318 To: Leah Ffttli(lrla 870 535 8318 P. 006 ere: 1122!2005 0837 AM Page: 6 of 12 SOSSCON-03 BOCE IMPORTANT If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). It SUBROGATION IS WANED. subject to the terms and conditions of the policy. certain policies may require an endorsement A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). DISCLAIMER The Certificate of Insurance on the reverse side of this form does not constitute a contract between the issuing insurer(s). authorized representative or producer. and the certificate holder, nor does it affirmatively or negatively amend. extend or alter the coverage afforded by the policies listed thereon. ACORD 25 (2001108) Rx Date/Time NOV-22-2005(TUE) 09:33 From: Celia Bolen At: First Aransas Insurance Fax1r-535.8316 To: Leah I*dliUdo 870 535 8318 P. 010 Ste: 11/22/2C05 OS 37 AM Page: 10 o/ 12 COVERAGES ACORD,, CERTIFICATE OF LIABILITY INSURANCE DATEIM"TIDA"Y" 11122/2005 MM. MO PRODUCER (870) 541-0020 First Arkansas InsurancelPlne Bluff THIS CERTIFICATE IS ISSUED ONLY AND CONFERS NO RIGHTS HOLDER. THIS CERTIFICATE ALTER THE COVERAGE AFFORDED AS A MATTER OF UPON THE CERT DOES NOT AMEND, BY THE POLICIES INFORMATION FICATE EXTEND OR BELOW. PO Box 8367 Pine Bluff, AR 71611-8367 INSURERS AFFORDING COVERAGE NAIC Ili NwREO Bossier Contracting, Inc. 116 S Broadway Siloam Springs, AR 72761 - Arkansas Home Builders Association LIABIRY GENERAL CLAWS AIDE RO RERA S.rERe ASLEEP C MLnm D. F INSURER E _ [WAN* RI PORTED PREMISES (Es amFera) F COVERAGES CERTIFICATE HOLDER CANCELLATION City of Fayetteville 113 West Mountain Street Fayetteville, AR 72701- S$GULO ANY OF TIE ABOVE DESCRIBED POLICES BE CANCELLED BEFORE THE CREMATOR GATE THEREOF, THE AWHO REAMER WILL ENDEAVOR TO MAIL 30 DAYS %RITTER NOTICE TO TIE CERTIFICATE HOLDER FLARED TO THE LEFT, BMT FAILURE TO DO SO WALL DMO SE NO OBLIGAMIN OR LA1a&RY Of ANY 100 VON TIE NIEU E, FM AGENTS OR REPRESENTATNEA AuT ORDEDREPREEEMAITYE •��.�j �' •� -.— —#( ACORD 25 (2001108) ® ACORD CORPORATION 1988 THE POLICIES OF INSURANCE LISTED BELOW NAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REOUIREMEWT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE NAY BE ISSUED OR MAY PERTAIN. THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS. EXCLUSIONS MD CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE SEEN REDUCED BY PAID CLAMS NSA LTR MM. MO TYPE Of PIStNMrE POLICY NRaCR POLICY EFFEC1NE DATE tIICONTI POLICY EXPIRATION DATE mLMDoNYYI LAM GENERAL CON.ETiCW LIABIRY GENERAL CLAWS AIDE LUBIL DY OCCLA EACH OCORRFJCE F _ [WAN* RI PORTED PREMISES (Es amFera) F LED E)P (Any MM P nm) t PERSONAL A ADV NARY $ GOERAL AGGREGATE 1 GEM AGGREGATE LMC APPLIES PER PRO n LOC POLICY n PRE000TS. CCMPNP AGO $ AUTOMOBILE U*SU1Y ANY NATO ALL OWNED AUTOS SCHEELILED AUTOS HIRED AUTOS NONOTMED AUTOS COIA3 ED SINGLE IMIT IES loan) S BODILY HURT IPM MOTS S B'uCEY RAFT NPM aaOMFI S PRCPERfY DAMAGE (Pw pomp r GARAGE tuition ANY AUTO AUTO My EA MCOENT 1 OBER PAN AUTO ONY. EA ACC S AGs S EX CESSAIYBRELIA OCCW CEDUCTIBLE RETENTION UMLOY CLAWS MADE EACH OCCURRENCE 1 AGGREGATE S S S S S A WORIMER,CoIPOAATON AND EMPLOYERS' ' ANY PROPRIETCRRNnKRIFJE WTI VE OFFICERA¢?BER EXCLlX1EDT It yesAAa,b unit SPECIAL FROV'SIONS bear 297 111/2005 11112006 XI WC SfASLL i4RY UMTS OM ER E L EACH *cocoa 2 300,000 E L. [DISEASE - EAQPLOYEE 5 300,000 LMR f 300,000 E L ISEASE - PDLCY OTHER DESCRVIIOM OF OPERATORS 1 LOCATORS I VEHICLES 1 EXCLUSIONS ADOEO BY EPCORSEME PR I SPECIAL PROVEada See attached page. CERTIFICATE HOLDER CANCELLATION City of Fayetteville 113 West Mountain Street Fayetteville, AR 72701- S$GULO ANY OF TIE ABOVE DESCRIBED POLICES BE CANCELLED BEFORE THE CREMATOR GATE THEREOF, THE AWHO REAMER WILL ENDEAVOR TO MAIL 30 DAYS %RITTER NOTICE TO TIE CERTIFICATE HOLDER FLARED TO THE LEFT, BMT FAILURE TO DO SO WALL DMO SE NO OBLIGAMIN OR LA1a&RY Of ANY 100 VON TIE NIEU E, FM AGENTS OR REPRESENTATNEA AuT ORDEDREPREEEMAITYE •��.�j �' •� -.— —#( ACORD 25 (2001108) ® ACORD CORPORATION 1988 Nx trate/Tine NOV-22-2005(TUE) 09:33 From Celia Brien At: Fine Ananias Insurance Fax1 535-8318 To: Leah Md4Wo 870 535 8318 P. 011 este: 11/22/2005 0837 AM Page: 11 of 12 BOSSCON-02 BOCE IMPORTANT If the certificate holder is an ADDITIONAL INSURED. the policy(ies) must be endorsed A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). If SUBROGATION IS WAIVED. subject to the terms and conditions of the policy. certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s) DISCLAIMER The Certificate of Insurance on the reverse side of this form does not constitute a contract between the issuing insurer(s). authorized representative or producer. and the certificate holder. nor does it affirmatively or negatively amend, extend or alter the coverage afforded by the policies listed thereon. ACORD 25 (2001103) ex nate/rice ?UY-24-2UU5LTUtl UV: 870 535 8318 Fran: Glia Bolen At: First Arkansas Insurance Fax1D�535.8318 To: Le&1 Itdliddm ate: 11/22/2035 08:37 AM Page: 12 of 12 P. 011 BOSSCON-02 B DESCRIPTION OF OPERATIONS - Bossier Contracting, Inc. 116 S Broadway Siloam Springs AR 72761- City of Fayetteville 113 West Mountain Street Fayetteville AR 72701 - Arkansas Home Builders Association Workers Compensation Self Insured Fund, A Qualified Self Insuror Project Name: Drake Field Terminal Building Renovation Owner Is the certificate holder. Architect Is Wlttenburg, Delony, & Davidson, Inc.; 2434 East Joyce Blvd; Suite 10: Fayetteville, AR 72703 CITYOFF-01 ACORQ, CERTIFICATE OF LIABILITY INSURANCE DATE(MWDOrYYY) 11/30/2005 PRODUCER (870) 541-0020 Frost Arkansas Insurance/Pine Bluff PO Bo Box Pine ox 8367ff 71611 8367 THIS CERTIFICATE ONLY AND HOLDER. ALTER THE CONFERS THIS COVERAGE IS ISSUED AS A MATTER OF NO RIGHTS UPON THE CERTIFICATE CERTIFICATE DOES NOT AMEND, AFFORDED BY THE POLICIES INFORMATION EXTEND OR BELOW. INSURERS AFFORDING COVERAGE NAIL # INSURED City of Fayetteville 113 West Mountain Street Fayetteville, AR 72701- INSURER A: Cypress Insurance Company INSURER B: LIABILITY GENERAL ('A MMS MADE Contractors INSURER c OCCUR INSURER 0: 11/30/2005 INSURER E: FACS OCCURRENCE taccrulIENTED PREMISE na) COVERAGES THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS. EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. SJSR 1.1R ADM MU INSURANCE POUCY NUMBER POUCY EFFECTIVE M,Dyy.y1 CY DATUM OMITS PI LH OF A GENERAL LIABILITY GENERAL ('A MMS MADE Contractors LABILITY OCCUR BINDER 11/30/2005 11/30/2006 FACS OCCURRENCE taccrulIENTED PREMISE na) S 1,000,000 X COMMERCVL f X MED EXP 1 (Any one person) X Owners PERSONAL b ADV INJURY f f 1,000,000 X Protective Liability GENERAL AGGREGATE GENT. AGGREGATE LIMIT APPLIES PER Jn LOC n 1F O PRCOUCTS- COMPIOP AGG f POLICY AUTOMOBU,E LIABILITY ANY AUTO COMBINED SINGLE LIMIT (Ea ocacHn ) f _ ALL OWNED AUTOS AUTOS AUTOS -OWNED AUTOS BODILY INNRY (Per Demon) $ SCHEDULED HIRED NON BODILY INA/RV (Par occIdoM) f PROPERTY DAMAGE (Pet eorJMOni) S GARAGE UABUJTY ANY AUTO AUTO ONLY - EA ACCIDENT f OTHER THAN EA ACC 1 AUTO ONLY AGG S EXCESSNMBRELLA OCCUR DEDUCTIBLE RETENTION LABILITY CLAMS MADE EACH OCCURRENCE 1 AGGREGATE f 1 S S S WORKERS COMPENSATION EMPLOYERS' LIABILITY ANY PROPRETORPARTNERIEXECUTTVE OFFICERAEMBER Byee describe under SPECIAL PROVISIONS AND EXCLUDED? (WC STATU- I OTH- ER iOKY LIMITS E L. EACH ACCIDENT 1 E.L. DEF ASF - EA EMPLOYEE S E . DISEASE - POLICY LIMIT 1 bebw OTHER DESCRIPTION OF OPERATIONS / LOCATIONS I VEHICLES / EXCLUSIONS ADDED BY ENDORSEMENT I SPECIAL PROVISIONS Bossier Contracting, Inc. Is the contractor for Job: Drake Field Terminal Building Renovation © Fayetteville Municipal Airport, 4500 South School Street, Fayetteville, AR 72701 CERTIFICATE HOLDER CANCELLATION City of Fayetteville 113 West Mountain Street Fayetteville, AR 72701 - SHOULD ANY OF THE ABOVE DESCRIBED POUC€S BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF. THE ISSUING INSURER WILL ENDEAVOR TO MNL 10 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT. BUT FAJLURE TO DO SO SHALL MOROSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER. ITS AGENTS OR REPRESENTATIVES. AUTHORED REPRESENTATIVE ACORD 25 (2001/08) 0 ACORD CORPORATION 1988