HomeMy WebLinkAbout62-99 RESOLUTION•
•
RESOLUTION NO 62-99
A RESOLUTION AWARDING BID NO. 99-35 IN THE AMOUNT
OF $601,075.50, PLUS A PROJECT CONTINGENCY AMOUNT
OF $93,925, TO NORTHWEST EXCAVATION, A DIVISION OF
NABHOLZ CONSTRUCTION, CO., FOR HIGHWAY 16 WEST
WIDENING -WATER AND SEWER LINE RELOCATION
PROJECT; AND APPROVAL OF A BUDGET ADJUSTMENT.
BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF FAYETTEVILLE,
ARKANSAS'
Section 1 That the City Council hereby awards Bid No. 99-35 in the amount of
$601,075.50, plus a project contingency amount of $93,925, to Northwest Excavation, A Division
of Nabholz Construction, Co., for Highway 16 West Widening -Water and Sewer Line Relocation
Project. A copy of the bid tabulation is attached hereto marked Exhibit "A" and made a part hereof.
Section 7 The City Council hereby approves a budget adjustment in the amount of
$695,000 increasing Waterline Improvements, Acct. No. 5400 5600 5808 00, Project No. 99028 10
by decreasing Use of Fund Balance, Acct. No. 5400 0940 4999 99. A copy of the budget
adjustment is attached hereto marked Exhibit "B" and made a part hereof.
PASSED AND APPROVED this AL day of May , 1999.
•
ATTEST:
APPROVED:
Hanna,melf/44,
Mayor
Fre
FAYETTEVILLE
THE CITY OF FAYETTEVILLE. ARKANSAS
DEPARTMENTAL CORRESPONDENCE
To: Sid Norbash, Engineering
From: Heather Woodruff, City Clerk
Date: May 24, 1999
Attached is a copy of the resolution awarding the contract for the Hwy 16 widening project for
your records. The original will be microfilmed and filed with the city clerk.
cc. Internal Auditor
file
STAFF REVIEW FORM
X AGENDA REQUEST
X CONTRACT REVIEW
GRANT REVIEW
For the Fayetteville City Council meeting of May 4,1999
HwY 16 WIDEN
A.5.1
FROM: �/• /
Sid Norbash . Engineering Public Works
Name Division Department
ACTION REQUIRED: Approval of:
(1) The Construction Contract with Northwest Excavation, a Division of
Nabholz Construction Co., for Highway 16 W. Widening - Water & Sewer
Relocation Project in the amount of $601,075.50.
(2) A project contingency amount of $93,925.
(3) A budget adjustment in the amount of $695,000.
COST TO CITY:
$695,000 $450,000 Hwy 16 W. Widening -MS Reloc.
Cost of this Request Category/Project Budget Category/Project Name
5400-5600-5808-00
Account Number
99028-20
Project Number
14,000 Capital Water Mains
Funds Used To Date Program Name
$436,000 Water and Sewer
Remaining Balance Fund
BUDGET REVIEW: X Budgeted Item X Budget Adjustment Attached
��
Budge oordina or Administrative Services Director
CONTRACT/GRANT/LEASE REVIEW: GRANTING AGENCY:
,e -c-, 5 -99
Acco .r'.i$f7� Dat ADA Coordinator Date
City Attorn
Date Internal Auditor Date
Purchasing Officer Date
STAFF RECOMMENDATION: Approval of the contract, contingency, and the budget
adjustment.
s 3-1y
Date
Date
NO
Admi tr, iv Services Director D,a e -t
Ma or Date
Cross Reference
New Item: Yes X No
Prev Ord/Res #:
Orig Contract Date:
Orig Contract #
FAYETTEVILLE
THE CITY OF FAYETTEVILLE, ARKANSAS
DEPARTMENTAL CORRESPONDENCE
HWY 16 WIDEN
A.5.2
To: Fayetteville City Council
Thru: Fred Hanna, Mayor
Charles Venable, Public Works Director
Jim Beavers, City Engineer
From: Sid Norbash, Staff Engineer/
Date: May 3, 1999
Re: Highway 16 W. Widening (Meadowlands to 71 Bypass)
Water and Sewer Line Relocations
The above referenced project has been approved by the Council as a
CIP project and is budgeted for 1999. The Engineering for this
project has been performed by the Engineering Division, and the
construction management will also be done in house.
On 5-3-99 official bids were received for the construction
contract, and four bids were received. The low bidder is Northwest
Excavation , a Division of Nabholz Construction Co. of Rogers,
Arkansas in the amount of $601,075.50. A bid results sheet is
attached for your information.
The Staff requests that the City Council approve the following:
(1) Award of the construction contract to the low bidder, Northwest
Excavation, in the amount of $601,075.50.
(2) A total project contingency of $93,925 (approximately 15% of
the contract amount)
(3) A budget adjustment in the amount of $695,000.
The reason that a budget adjustment is needed for this project
is that several items were added to the design that were not part
of the original estimate for this project. These items are mostly
new highway crossings, due to the fact that the old crossings
either needed to be enlarged or could not be trusted under a brand
new highway, and there were more water line conflicts with the
highway work than anticipated.
Sn/sn
Attachments: Budget Adjustment
Vicinity Map
Bid Tabulation Sheet
Copy of Contract
•
1
1
1
1
1
•
w
z
3AV
S3110
o��
3N3801d y
1S383838rv11
w
m�
as D`l
dv31N33ao
DOROTHY J
.L0
)x18838
4>
AHOo 13
OOOMa3H1v3M
NI1 3NIla
OvOd 38w11
OcrW
Z
0
O
0
Z
N
cc
0
w
U
0
HWY I6 WIDEN
A.5.3
rv31VS
/
N IAa
0
Ir
Ju aO or Alija
W
w
ovoa
3lddna
z
J
0
- J
f
rc
ct z
_ w
U }
r
CHAPARRAL L
ao
J
33a1 rvnld)
%Svl
ONm00v3ry
a0 N33d3 3NId
3A180
W'
w
SAV 330vN01H0
AVM 39VIdaVO
=-1�nj
3Nv1 ASIVO
y l LAAa;
a0�
ONV1MOOV3W1
JQi
0
a0�
0
dG av1S
(33V1 5,3NNv
l N33n0
ONIZVl8
a'o
N
City Limits
O.
ale
VICINITY
HWY 16 WIDEN
A.5.4
CONTRACT
THIS AGREEMENT, made and entered into the 4th day of May
1999 , by and between the City of Fayetteville, County of
Washington, State of Arkansas, Party of the First Part, hereinafter
called the Owner, and Northwest Excavation, A Division of Nabholz Construction
of the City of Rogers, Arkansas of
the Second Part, hereinafter called the
WITNESSETH THAT:
Contractor.
, Party
WHEREAS, the Owner has called for bids for water system
improvements, as set out in the Plans and Specifications and
approved by the City of Fayetteville, Arkansas; and
WHEREAS, pursuant to the published calls for bids under said Plans
and Specifications, the Contractor is the lowest and best qualified
bidder for the construction of said Improvements;
NOW THEREFORE, the Contractor agrees with the Owner to commence and
complete the construction of:
Bid No. 99-35 which shall be Highway 16 W. Widening - Water and
Sewer Relocations, Fayetteville, Arkansas; including all Work
required for a complete and acceptable installation, for the unit
and lump sum prices bid in the Bid Proposal, all of which become
and are a part of this Contract, the total sum thus being
Six Hundred and One Thourand and Seventy -Five Dollars and Fifty Cents
dollars ($ 601,075.50 ), such sum being the agreed amount upon
which bonds and liabilities are based, and at his own cost and
expense furnish all materials, supplies, labor, machinery,
equipment, tools, supervision, bonds, insurance and other
accessories and services necessary to complete the said
construction in accordance with the conditions and prices stated in
the Bid attached hereto and made a part hereof, and in accordance
with the Technical Specifications, the General Conditions, the
Supplementary Conditions, and in accordance with the Plans, which
include all maps, plats, blueprints, and other drawings, and
written or printed explanatory matter thereof.
The Contractor agrees to commence work under this contract within
ten days of the issuance of the Notice to Proceed and totally
complete all work within ninety (90) calendar days.
The Owner agrees to pay the Contractor in current funds for the
performance of the contract in accordance with the accepted Bid
therefor, subject to additions and deductions, as provided in the
Specifications, and to make payment on account thereof as provided
below.
Co.
HWY 16 WIDEN
A.5.5
As soon as is practicable after the first of each calendar month,
and in accordance with the Contract Specifications, the Owner will
make partial payments to the Contractor for work performed during
the preceding calendar month, based upon the Engineer's estimate of
work completed, said estimate being certified by the Contractor and
accepted by the Owner. Retainage shall be withheld from the
partial payments as provided by Arkansas state laws by the Owner
until final completion and acceptance by the Owner and Engineer.
The Engineer shall then issue a Final Estimate of work done based
upon the original contract and subsequent changes made and agreed
upon, it any.
Time is hereby expressly declared to be of the essence of this
contract, and the time of beginning, manner of progress and time of
completion of the work hereunder shall be and are essential
conditions hereof.
The Contractor agrees to commence work within ten (10) calendar
days from the date of the Notice to Proceed and to proceed with the
construction of the work and to prosecute the work with an adequate
force and in a manner so as to complete the work within the time
stipulated herein. If the Contractor fails in completing the
contract within the time stipulated herein, the Contractor agrees
to pay the Owner, as liquidated damages the sum of three hundred
dollars ($300.00) per day for each calendar day of delay in
completion, said amounts being fixed and agreed upon by and between
the parties hereto. Because of the impracticability and extreme
difficulty in fixing and ascertaining the actual damages Owner
would in such event sustain, said amounts are to be presumed by the
parties to this contract to be the amounts of damage Owner would
sustain. Said amounts of liquidated damages shall be deductible
from any amount due Contractor under the Final Estimate of said
work, after the completion thereof, and Contractor shall be
entitled any to the Final Estimate less such amounts of liquidated
damages.
If the Contractor be delayed at any time in the progress of the
work by any act or neglect of the Owner or of the Owner's
employees, or by any other Contractor employed by the Owner, or by
changes ordered in the work, or by strikes, lockouts, fire, unusual
delay in transportation, unavoidable casualties or any causes
beyond the Contractor's control, or by delay authorized by the
Engineer pending arbitration, or by any cause which the Engineer
shall decide to justify the delay, then the time of completion
shall be extended for such reasonable time as the Engineer may
decide.
No such extension shall be made for delay occurring more than seven
days before claim therefor is made in writing to the Engineer. In
the case of a continuing cause for delay, only one claim is
necessary.
2
HWY 16 WIDEN .
A.5.6
In the event the Contractor abandons the work hereunder or tails,
neglects or refuses to continue the work after ten (10) days
written notice, given Contractor by the Owner or by the Engineer,
then the Owner shall have the option of 1) declaring this contract
at an end, in which event the Owner shall not be liable to the
Contractor for any work theretofore performed, or 2) requiring the
surety hereto, upon ten (10) days notice, to complete and carry out
the contract of Contractor; and in that event, should be surety
fail, neglect or refuse to carry out said contract, 3) said Owner
may complete the contract as its own expense and maintain an action
against the Contractor and the surety hereto for the actual cost of
same, together with any damages or other expense sustained or
incurred by Owner in completing this contract, less the total
amount provided for hereunder to be paid Contractor upon the
completion of this contract.
This contract shall be binding upon the heirs, representatives,
successors or assigns of the parties hereto, including the surety.
IN WITNESS WHEREOF, the Owner and Contractor have hereto set their
hands and seals, respectively.
4fitoe,Q4 Furse -Ain a d taw ion efilA
r� Name
By
Witnses* Y
*If corporation, secretary should attest.
CITY OF FAYETTEVILLE, ARKANSAS
Attest:
Fre
Hanna, Mayor
End of Contract
3
Bid Amounts for Highway 16 West
Widening from Meadowlands Dr.
to the Bypass
May 3, 1999
1. Northwest Excavation, a Division of
Nabholz Construction
2. Goodwin Company
3. Fayette Tree & Trench
4. Basic Construction Company
5. Kraus Construction Company
6. Seven Valley's Construction Company
HWY 16 WIDEN
A.5.7
$ 601,075.50
$ 613,985.00
NO BID
$ 834,742.50
$ 659,286.00
NO BID
City of Fayetteville, Arkansas
Budget Adjustment Form
❑w1 10 WLUC,V
A.5.Y
Budget Year
1999
Depanment: Public Works
Division:
Program: Capital Water Ntains
Date Requested
05/04/99
Adjustment 11
Project or Item Requested:
Rcbudgeting 1 ighway 16 West Water/Sewer Relocation
project from S les Tax Capital Improvement Fund to Water &
Sewer Fund.
Project or Item Deleted:
None. Use of Fund Balance is proposed for this adjusttnent.
Justification of this Increase:
The Highway 16 West Water/Sewer Relocation project
exceeded the funding available in Sales Tax Capital
Improvement Fund and can be funded with Water & Sewer
Fund cash & investments.
Justification of this Decrease:
Sufficient cash & investments exist in Water & Sewer
Fund to fund this request, meet programmed funding
requirements and comply with City policy.
Increase Expen. e (Decrease Revenue)
Account Name Amount
Waterline Improvements 695,000
Account Number Project Number
5400 5600
Decrease Expense (Increase Revenue)
Account Name Amount
Use of Fund Balance 695,000
5808 00 99028 10
Account Number
5400 0940 4999 99
Project Number
Approval Signatures
5 —3-q9
Requested By Date
560_ 5-3.99
Budget nagcr Date
Date
Department Director
Admin. Ser' ices Director
Date
�S/fes
Date
Blue Copy: Budget tt Research / Yellow Copy: Rrgnester
Budget Office Use Only
Type: A B C
Date of Approval
Posted to General Ledger
Posted to I'roject Accounting
Entered in Category Log
E
C:\APP\9913UDGEABUDGTADNIWY16..t.
STAFF REVIEW
AGENDA REQUEST
X CONTRACT REVIEW
GRANT REVIEW
For the Fayetteville City Council meeting
FROM:
Sid Norbash Engineering
RECEIVED
FORM
DEC 2 3 1999
CITY OF FAYETTEVILLE
CTTY CLERK QFFI E
a-99
Cfive, ()
W&.i Q'Ci9v,4744/
of _ MIC9MairiAtl , D
Public Works
Name Division
Department
ACTION REQUIRED: Approval of the Final Reconciliation and change Order #1
for Hwy 16 W. Widening- W/S Relocations Project
COST TO CITY:
S69.196.40 04,5, oats
Cost of this Request Category/Project
5400-5600-5808-00 G1C,351
..Hwy 16 W. Widening-W&S Reloc.
Budget Category/Project Name
Account Number Funds Used To Date
99028-20
Project Number
Remaining Balance
Capital Water
Mains
Program Name
Water
and Sewer
Fund
B ET REVIEW:
X
udget Coordinator
Budgeted Item
Budget Adjustment Attached
Administrative Services Director
CONTRACT/GRANT/LEASE REVIEW:
h
AcpountinMa ager
/n
ity Aotorn-y
Purchasing Officer
1)x/-99
Date A
1ZZIr11
Date
al 9
Date
GRANTING AGENCY:
Date
/a -ate -s5
Date
STAFF RECOMMENDATION: Approval of the Reconciliation Change Order.
D vision Head
De4mens Director
0 /
�1.. _ 1 strti -�•ervices Director
,i2 iI/
Ma or
Date
/L-2.2-'75
Date
Cross Reference
New Item: Yes
No X
Prev Ord/Res #:c.
z-99
Orig Contract Date: May 4,
1999
Orig Contract #
Staff Review Form
12-Zg-‘t1
SiJ Noficn sin *
Sol 4,,,J4- c IdS
Description/ Meeting Date Mav3,1999
Project Name:Hyw 16 W. Water and Sewer Reloc.
Comments: Reference Comments:
Budget Director
Accounting Manager
City Attorney
Purchasing Officer
ADA Coordinator
Internal Auditor
FAYETTEVI LLE
THE CITY OF FAYETTEVILLE. ARKANSAS
DEPARTMENTAL CORRESPONDENCE
To: Fred Hanna, Mayor
Thru: Charles Venable, Public Works Director
Jim Beavers, City Engineere;
From: Sid Norbash, Staff Engineer
Date: December 20, 1999
Re: Hwy 16 W. Widening - Water & Sewer Relocations
Final Payment & Reconciliation Change Order Number 1
The construction of the above referenced project is now complete, and a final reconciliation pay schedule has been
prepared for your approval.
Because of some major changes by the Highway Department certain modifications to our plans were necessitated.
Also, some unexpected field conditions necessitated changes, which resulted in an over -run of S69,196.40. This
amount is to be funded with the $93,925 contingency amount approved by the Council , under Resolution 62-99.
We request your approval of this change order, in order to close out this project.
SN/sn
attachments
12/20/99 17:46 FAX 501 621 8089 NC5/NWE ®002
12/20/1999 17:24 5015758316
AGREEMflrr WITH
CITY FAY 1ST FLOOR PAGE 02
ANEND iarr TO THS
Northwest Excavation, Inc.
AlumT /1 (one and Final Reconciliation).
This is an amendment to the Agreement for Hwy. 16 West Widening - W/S
Relocationfrom Meadowlands to By -Pass.
executed on the 4th day of .May
199 between the City of
Fayetteville, Arkansas and Northwedt Excavation, Inc.
Additional services required due to field changes either by field conditions
or change of plans by Highway Department.
The charge for the additional services shall not exceed
$ 69,196.40 (funded by contingency amount of $93,925.00)
CITY OF FAYETTEVILLE:
NoRTHWES"T- 6KCAVATIDN
company
•
Title
Date l:2°4
Date is -'o— 99
FOR OFFICE USE ONLY
Existing P.O. #
Contract #
1� —
RESOLUTION NO. 62-99
fel C EAVlE
MAY 2619
e;
A RESOLUTION AWARDING BID NO. 99-35 IN THE AMOUNT
OF $601,075.50, PLUS A PROJECT CONTINGENCY AMOUNT
OF $93,925, TO NORTHWEST EXCAVATION, A DIVISION OF
NABHOLZ CONSTRUCTION, CO., FOR HIGHWAY 16 WEST
WIDENING -WATER AND SEWER LINE RELOCATION
PROJECT; AND APPROVAL OF A BUDGET ADJUSTMENT.
BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF FAYETTEVILLE,
ARKANSAS:
Section 1. That the City Council hereby awards Bid No. 99-35 in the amount of
$601,075.50, plus a project contingency amount of $93,925, to Northwest Excavation, A Division
of Nabholz Construction, Co., for Highway 16 West Widening -Water and Sewer Line Relocation
Project. A copy of the bid tabulation is attached hereto marked Exhibit "A" and made a part hereof.
section 7. The City Council hereby approves a budget adjustment in the amount of
$695,000 increasing Waterline Improvements, Acct. No. 5400 5600 5808 00, Project No. 99028 10
by decreasing Use of Fund Balance, Acct. No. 5400 0940 4999 99. A copy of the budget
adjustment is attached hereto marked Exhibit "B" and made a part hereof.
•
�/, :aa •\ APPROVED:
Ytr,
PASSED AND APPROVED this -4L day of May_, 1999.
•ATTEST:'
B
Heather Woodruff, City' Icrk
Fred Hanna, Mayor
12/07/99 15:34 FAX 501 621 8089 NCS/NWE
1 NET CHANGES by ChangeOtda
o
i
F
I
Total changes *mond
in previous months by Owner
CHANGE ORDER SUMMARY
Qi
a
0
06Y86ISOIS
`o
U
00
W
O
S
^y�
G
N
W
U
J
o
0
W
to
Oyn
8
Q
b
0
SNOiLMQJG
b GO
9J
0
U P N
in
=8
2 v z e 0$ ro M
v y
E . pp g 8
U
M p W
v
R
O J
8
O
J
nn
n
t0
w
to
-
o»
r
N N
tO N
:nod 13d8wwo3
UOpofl4SUO3 IeJaUSO
Zoos
mat, Iry bgmAagafed
o°
z
xi
>0
CO
!? 0 0
:Ol G0183d
APPLICATION AND CERTIFICATION FOR PAYMENT
not 1N310V11300
0
12/07/99 15:35 FAX 501 621 8089
NC$/NWE . Ia1004
IW.1 = O V U VWON= O `O O J P w. w w1 ^ O V W J P w a
O, Y n r= A I� 0 [f r N N �a '-! T ? .T Q �I '_'1, ^� N N 0
cr� 3g� t, ' , g6 ^`'L i S O ' PF�pp b a~^ a g A jl9pfl
9• a b 9 ®$ J (f' o f R G N Y �b' l i •g S ni n G &F
zinit
IV I Pitt 0?
5'
__
P m V N m 4• N y- r O• �N.+ - N- J LI ti • u e_ a -- f u O V
r � .� W 4 - a' v - II
I
`€s2gox22M§E lgguAgggingg0gE 8Nxgg811
II
<82I
N
PU
R
w i p i1 u 3 w*lO J 5 w1)LOeeOjie e II
W it
--22a$-"--m-
V N u J J V G
Ny 88_ JJ 88 a 1Y1,,11 N y N fS t•Ny A p- N NGp pp J
0 0 M O S 8 0 N 7 0 O o O P 0 S e$ Y e e ;-3 Wei
O O II II
II
11 11
y11
i III
I
1
P a W N P = p O n. r a• O W Pt W' -'-e444394 14 P N O V II ; S II
�. w c P -- w J a s II O II
h o S S g o S p o o f a 0 0 0 0 0 e e .� w e $ r1 $ a Ii 4� y fI
82882888 222282282828288822222222222Pa 11
I I g II
4 E
ii II
77qq w r �1 ,�-NN�1tlr$�$�Igs _ 11
H 0 H
O e p O S p o pp.,. O e e uo u J o e po as o i u S �7 P o o g o p ,r. p o o II II
8 8 8$ 8$22222 o 8 0 0 0 0 0 0 0 0 8 8 8 8- 8 8 g g Oo 8 g g 8 �11� ;�
II 2 1
I g
11 H0
N
0 8 0$ 8 8 8 8 8 8 8 Ming; 8 8 8 8 8 0 8 8 8 8 8 Vii!
ii II
II GI II
ii s l
II fi
� `I
11
900
13 8 g
r b N a 0 A e O_ A 71 P' N 0 E P P 1 8 Ni 1 o A N 'o :. ,N Y Y
$ 8.8 8 8 8$ o g g o S 8 g g 0 8 8 0 g$ g g o 0 0 0 0 0 0 0 0 0 S 0
08Pg; 88e08e,eogo8g0000,0,0 ;PP 0PP; 00000880
$$151555155 555555geessg55555 11554°5
axr•�aarxarar:x�. 555 555 a.x
m
r
r �$TI
0000
o : n
iia
tOtra R.
Osl
p
e
m
m ogfl
w A
00
N - Z Z
13 .0zA
m
T
u
I 1
0 0 0 0 0 00 0 0 0 0 0 O O O O o o O P O 0 0 0 0 0 0 0 0 0 0 0 0 II N I
8g88gg0ggggg�gsggggaaogggog88s88oggn- 1,
II yyj u
uV".1 ... �,1 �N1 py �p 1N� p q y qW }y. —cojO� 8 i'. 11 II
A S O w O O O O O rl O a ,Ni, . L O O U .lJ. J. P O 1J.1 u O W O O w O O O I Z I1
!$ 8 8 8$ b 8$$$ >r 8$$$ 8 S S 8 S: 8 8 8 8 o Y$ b e S 0 0 II n
0/
u11E+8 it;
aI
e
II at
y a
O LmLi 1
r Y i
12/07/09 15:35 FAX 501 821 8089 NCS/NWE .
r
O 0 N- - O 0 M J O 4 P U N- S 4 Y J P II
I w - w i 1f i : 9 m II
Q Q 9 q
I
g OV a it E t W a k g . i 11
{q, le as-. tt"r®y II
y a S 8 v Z 0.^ 0. II J
8 R 4pE "EES a 4 9 u
m
R 3 a 11
�.11
2 J ' m I I 2
_ET E 0
0 w 0. 9 II 7C
pa ti g
g t 1I
o
11
e
o 0 0 0
0 0 0 0
0000 0 0000
N
o 0 o II
Il
®005
it
ll
I
II
Il
1 11
1411
u �a .. q u upp y up� p ap �p u II
0
m O U 4 U 0 0 0 0 O S O O it II
m I
Ca 9 I
1.
II 1 ii
II
11
P 4 I g ° 11
O o e e 88228828888
0. o C e e 0 0 0 0 e B o 0 0 0
0 0 8 8 O g 8 o g g o 8 0 0 0 S S S 0 a II In iI
PI O
A9,
11 z 11 ai
11
II p Ii z `a
II .�� UO °gg
0000 O O e e O o 0 o e e o 0 0 0 O II I cl y j j
8888 8 8 oO 8 0 0 8 0 8 8 8 S S 8 8 8 II 11 1 o 00
2 2
0
u L
to 4 N b d M O H O 4 O S O S S O Ii
II
II
u M a
% u u u y. r w N =" II
NoJoapL8 e0 II
• eee
4t• .
8883 8000088S008 8So201I
II
I
ll
2
m
r
gr
ti
ti
iIa1
ms b
a ad
s
t E�
qLL
K
Q2
u U O :si-erpn
$
O 0 0 0 a o N o 0e u g tzlg
0 0 0 o 0 . p I
8 0 ss 8 8 H 8 8 8 8 8 S S$ 8 8 8 8 8
I
1
o dea
8 e 0 a
t
M;;?,g0;2P 22828
o53otho $Wbo $0M
P PPP POPPPPPPOIPP o 0 0
8 0 0 8 8 2 8 8 8 8 8 2 8 8 8 0 0 8
990
228$
g 8
O 0 0 ....... 4 U [�I 1J Y�
I.l ;10°x
4 N J P O 4I :=P j P c P N
n 8288882848 8 8 8 8 8
1i R P
II g
1I
I
II
12/07/99 15:35 FAX 501 621 8089 NCS/NAE
City d WreeEeMOe • Prey 18 West Wldet ey Water & Sew Y Reiccabons
Nwlhwaf Emotion
®000
L joAty (:r<S Were locw4cal Ln ate Nrate1t. kthlm w41CY eke. ccw5in This at 05,4w1
C.e4 c c to+ (nwd ke, redo p; (0j
'EXTRA- DE - NOT ON BD SCHEDULE
PROJECTED CWWGES
ESTIMATED
UNrT
EXTENDED
DESCRIPTION
QUANTITY
UNIT
COST
COST
OUANTTTY
COST Cf
CHANCE
NEW TOTAL
COST
e
a., Da., Trench Bcnvallon.Y
0
it
51.00
SOLO
4500
$8,100.00
:910003
•
0
If
50.75
$0.00
sew
$4,245.00
$alam
3
16': , . 1 valve
0
a.
53.750.00
S0.0
1
53.75003
S3.750133
1 4
3• CwmtO (ftupb Road)
0
a.
$3,40.001 SOLO
1
$3,400 CO
53,400.00
5
Fla Nydranl Eldaslmta
0
co
$555.00
$003
10
15,550.0
5985o00
e
PIIc4 Hula (a- WalrO,. dam e4 Batty Jw)
0
If
$5730
5000
53
$5.173.00
$9175.00
7
Comedian d7 Service line (f Ewa)
0
--
ea
$3,200.00
1850.00
50.0
3000
1
1
$3,203 03
180003
53,20.0
181003
e
1F14.1 Plug
0
e
8'.00
0
If
a
51080
$710.0
5300
30.00
340
5
18.732.00
33,550.03$3950.03
58,732.00
10
I•Meter Salt
0
11
3N • D,4a, Warta One.)
0
8
51182
1000
403
$5,128.00
14,12800
$45310.00
Tdal
$070,271J10
L joAty (:r<S Were locw4cal Ln ate Nrate1t. kthlm w41CY eke. ccw5in This at 05,4w1
C.e4 c c to+ (nwd ke, redo p; (0j
12/07/99 15:36 FAX 501 621 8089
qty d P13attevaa - Hey 16 Wed Widening Wakf 4 Sera r Rekicalsens
NCS/NHE
0 007
mace q rvru•eerar coa.m..w,.
ORIDYYIL BID QUANTITIES
PROJECTED CHANGES
I;STWATED
UTCT 1
EJ(TENDEU
PROJECTED CHANGES
DESCRIPTION
QUANTITY
UNIT
UNTT COST
TOTAL COST
CHANGE IN
QUANTITY
COST OF
CINNOE
NEW TOTAL
CO6T
1
18 -Water Mukr
6640
V
$45.00
5251,600.00
20
$90000
5251,700.00
2
1 E Bd1arlly Vain nth Bar
5
a
' *4.00000
$20,000.00
0
Som
520.000.00
3
16Y16Ylr Tapping Tee B Vain
1
aa
$12,000.00
512000.00
0
5010
s12,o00.00
4
Conyap Dunk Iron Ptatrgc
0.350
9e
$500
$46,750.00
4289
$21,44500
$68.15510
5
CGale valve .elft Boa
2
ea
5788.00
$1$17-00
0
$0.00
$1,51210
6
V Gate Vain nth Bmf
10
n
1910.00
59,100.00
0
$000
0,100.00
7
C PVC Wer Main C-900 Own 200 SCR 14
45
11
520.00
190000
75
$1,500.00
12,40000
8
env Tapping Skew 5 Tapping Why
3
w
$2,045.00
16,136.00
0
$0.00
1613510
9
Fire Hydml Asaemefee with r Gate Valla
11
ea
$1,80000
119,600.00
6
*10±80.00
AO.W0J10
10
ReOonnaol 541n4e Line
5
at
12110.00
51075000
-2
04.300.
$8.45010
11
3I4- Copper Poly -Wrapped
500
8
513.65
• 56,19010
400
($5.460
$2,730.00
12
Top 9o975eedurp4Mkiring
1
Is
$5,600.
55.50010
0
$0.00
$5.600.00
13
Remora Prawn 6 Rain Engin Sod
5,500
aT
$215
111.375.00
-200! ($410
510,055.00
14
6' TMdaraa waren Porting Id Repair
75
Vf
133.00
$2175.00
-7 (1231 , .
12,244.00
15
Canadian d 2' Sandra Leve to Now Wear Maim
2
oe
11$80.00
53,160.00
1 $1,580.00
$4.740.00
16
Mitt. Patdlg Lam Strad Rape
465
a
536.00
517,450.00
-214 704 ..
W.756.00
17
1.411rifunion 8 Stcsage
1
Is
54400.00
54,40000
0 WOO
$4400/0
18
Titan Safety Rsgrkemenb
1
Is
52,100.00
$2,100.00
0 10.00
$2,100.00
16
Mending Carp L Guar Replr
150
6
$13.00
51.950.00
430 55,58000
57.540.00
20
Sidewalk Repair 4' Thkllen 5
57
57110
1112$0
96 52,160.00
$217250
21
Senna of Exerting rue Hydrant Basel & Trammel 10
se
1250.00
52500.00
-1 (1250.0 •
52250.00
$1.48900
22
8' CC00 Water Pipe DR14 CC 20) 180
If
11710
$3230.00
290 $42613.00
A
Seed Race Eww9on 100
oy
$1500
58.500.00
.100 (58500.•.
$000
24
Class 7 Aggregate Ikeda! 620
In
$1020
$10,04.00
332 $5,378.40
515.422.40
25
ClemAn&G.VhNng 1
Ie
$4.00040
$4,000.00
0 50.00
$4000.00
26
Erosion coobgl
1
b
51100.00
51,600.00
0 50.00
$1,800.00
27
Cap & Pkg Existing Wdor LC
8
n
1840.00
57,520.00
-4 (13.760. • •
$3.760.00
0
5150.00
$12,000.00
0 $0 00
512,000.00
21
Hay Bae 1S' Sled Eramamsnt Pip on Spedfkd Grad
W
29
8' D.IP. Wilk FWd Leek Gadaeb Sewer Pips
107
1
544.00
54.70800
0 $Om
14,706.00
30
Hwy Bae 10' Steel Emanated Pipe It K Water Lino
255
0
1130.00
$33,150.00
0 10.00
$33150 CO
31
Hwy Bow 12' Steel Encasement Pips fur 6- Wafer Uro
90
1
$90.00
:.10000
10 WW.130
$9,000.00
32
6' DJ.P. veli HON Lod Gaakeb Weser Pips
105
If
$2600
$2,73000
0 $0.00
$2,73000
II
1260.00
$33 800.00
0 50 00
133.00.00
33
Hwy 90 6 Sued 40' Boro 30' Steal Env.sreem Pipe
130
34
8' DIP. with field Lnk Gasket! Wash LMs
335
9
$3600
$6,710.00
0 $000
SS 710.00
35
1r DIP. w11h f•Tdd Lack Gcslmla Water Urn
112
8
052.00
56,9.4.00
0 SOW
$6.9400
36
Slrrdard Serer Man Ink Cast Ip Plans
14
4
1260.00
*4,06000
-06 (51. • ,
53,1T2010
37
Corvrdfon et New r SaMary Sear b Existing Walt
1
k
12$6000
$2,560.10
0 5000
52560.00
30
8' PVC Sower Pipe Cement In Plan
14
0
590.00
$13.00
0 $0.00
$1260.00
39
Special I10kids BsddllI MaWk1
480
ry
510.50
5504010
-460 ($5,040.00
SOLO
40
Naw 3l'h4etar Set Up Cafplete with Box &Ud
5
se
$500.00
$2,050.00
1 $690.00
$3540.00
5620,21110
I
I
I
I
I
I
1
1
ri
Construcf.iort�S,pgcCcRiOFI L.MED
Contract Documents
for
Highway 16 West Widening
Water and Sewer Relocations
From il Bypass to the Vicinity Of Meadowl ;nd Street
April 1999
lF lYF-lf'EV16.L.
Prepared by:
The Office of the City Engineer
City of Fayetteville
113 W. Mountain Street
Fayetteville, Arkansas 72701
/, ca- -qq
jAS
Advertisement for bids ................................
1-2
Instructions to bidders................................1-8
State Wage Determination ...............................1-4
Bid Proposal.........................................1-12
Statement of Bidder's Qualifications ....................
1
Contract Agreement......................................1-3
Performance Bond.......................................1-2
Payment Bond...........................................1-2
General Conditions .....................................
1-42
Supplement to the General Conditions ....................
1-9
Detailed Technical Specifications
Section
100
General Project requirements ...........
1-10
Section
110
Measurement and Payment ................1-3
Section
120
Testing ................................
1
Section
140
Schedules, Progress Meetings,
Public Notice ...........................
1
Section
300
Crushed Scone Base Course .............
1
Section
310
Pipe Bedding Material ...................
1
Section
400
Clearing Rights of way, Cutting
and repairing fences ...................1-3
Section
401
Surface Removal .........................1-3
Section
406
Pipe for water lines - General .........
1
Section
411
Ductile iron pipe and ductile iron
pipe fittings for water lines ...........
1-6
Section
412
Polyvinyl chloride (PVC) pipe and
fittings for water lines ...............1-6
Section
413
Polyethylene encasement ................
1
Section
414 Pipe detection tape ....................
1
Section
450 Gate valves and butterfly valves ........
4
Section
461 Placing pipe protection cover and
compacted backfill sewer and water ......
1-3
Section
462 Flushing, hydrostatic testing, disinfection
and dynamic testing of water lines ......
1-2
Section
472 Fire hydrants ...........................1-2
Section
487 Pipeline cleanup and seeding ............1-3
Section
502 Concrete ..............................1-2
Section
611 Pipe underdrains (a.k.a. "French drains").
1
Appendix A
- OSHA Safety requirements for excavation ......
218-256
Appendix B
- Special Provisions and Requirments ....................
1 - 4
Appendix C
- Procedures for Customer Notification for Water
Service Interruption
1-6
Appendix D
- Tree Preservation
Appendix E
- Special Easement Conditions
I
' City of Fayetteville
ADVERTISEMENT FOR BIDS
Highway 16 W. Widening
Water & Sewer Relocations
Bid Number 99-35
1
Sealed bids for the construction of water and sewer lines and appurtenances,
'
Fayetteville, Arkansas, will be received by the City of Fayetteville, Arkansas,
at the Purchasing Office, Room 306, City Administration Building, 113 West
Mountain Street, Fayetteville, Arkansas, 72701, until 10:00 A.M. local time
on Monday May 3, 1999, and then at said office publicly opened and read
aloud.
' The proposed Work generally consists of construction of approximately 5900 feet
of 18" water main including fittings and valves, service connections and fire
hydrants, two Highway Bores, installation of split encasement pipe for water and
sewer lines, in accordance with the contract documents.
' Plans and Specifications may be examined and obtained at the City of Fayetteville
Engineering Office, Room 004, City Administration Building, 113 West Mountain,
' Fayetteville, AR.
Each bid must be accompanied by a cashier's check or surety bond in an amount of
five percent (5%) of the total whole bid. In the event the successful bidder
' fails, neglects, or refuses to enter into the contract for the construction of
said work and furnish the necessary bonds in accordance with the Contract General
and Supplemental Conditions, the Owner shall retain said check or bond as
' liquidated damages.
The City of Fayetteville reserves the right to reject any and all bids, and to
waive any formalities as deemed to be in the best interest of the City of
Fayetteville.
I
' To: NWA Times
' Advertise once on April 18th and once on April 25th
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
BID PROPOSAL
Place
Date FJ9g9
Proposal of `n &iZhuJ 44�,�.�w�ft.�xA'��CL O.-1ic'' rp n
organized and existing under the laws of the State of
Q�2fli a partnership consisting of
an individual trading as /
To: City of Fayetteville
City Administration Building
113 West Mountain
Fayetteville, AR 72701
The undersigned hereby proposes to perform all work and
required to be furnished for the construction of Bid No
the Highway 16 W. (71 Bypass to Meadowlands)- Water and
Project, Fayetteville, Arkansas, in accordance with the
schedule, plan drawings and the contract documents incl,
specifications, for the basic lump sum of A
Dollars
furnish all materials
. 99-35 which shall be
Sewer Relocation
following bid
iding the project
It is understood that the lump sum proposals, in addition to all other work
includes all variable quantities listed in the proposal in the amounts so
listed. The variable quantities given in the proposal are for the purpose of
comparing bids only, and the basic lump sum proposal will be adjusted in the
final settlement for variation in the quantities at the following unit prices:
Bid Schedule
Unit Prices for Variable Quantities
Item Quantity Unit Amount
noand unit Description price of bid
1. 5,640 LF 18 inch Water Main
Bidder must circle one choice (a or b)
(a) 18" poly -wrapped D.I.P. Class 350
® 18" PVC $C Da.k w/tracing wire
C -9o5 Qg )6
$ ti5.00 $ 253800.00
(figures)
' (total - words) V V
* Unit price for all pipes will include bedding material
tracer wire for PVC pipe, poly wrap for D.I.P.
I
9
11
2. 5 Ea. 18" Butterfly Valve with Box
complete in place
$ y000.Uo $ 1u(000.00
(figures)
QcXkktKOcaW d.ad UL" WUDL vc - c2/u2Z
(total - wortls)
3. 1 Ea. 16x16x16" Tapping Tee and
Tapping Valve complete in place
$ 12 � 0Q 0 $ 1 A 1 000.00
(figures)
$. jnu_ .tu4�NId-aS�s�nti oyusl� *At cv.
(total - words)
4. 9350 lbs Compact ductile iron fittings.
>•ad $ 4S 7So, o u
(figures)
(total-Msords) Q/V.d. s'
5. 2 ea Six (6) inch gate valve with box.
s 7Sfo.00 s I S 12 .O o
(figures)
(total - words
6. 10 ea Eight(8) inch gate valve with box.
$ 9ly.00 $ y too. oo
(figures) -�/
$ gttj kL 649 LJ aoAd I kk C
(total - words)
7. 45 LF
8. 3 ea
6" PVC water main c-900 class
200 SDR 14
s 20.00 $ 9oo, O o
(figures)
Sf C .¼ckA dA-PAUnn. Quin &)& u Eo
(total - words)
8" x 8" Tapping sleeve
and tapping valve
UIlP1UWW11I/;*.
tang -
9. 11 ea Fire Hydrant Assemblies
includes 6" gate valves
s /goo.00s /q( SOO.o c
(figures(
(total - words)�t,r)j%A W
10. 5 ea Reconnect service lines by means of boring under the
Highway(including 2" PVC casing from R.O.W to R.O.W.))
s2t50•OO$ /p 750.0 U
(figures)
(total - words)CkAk& AA. '
11. 600 LF 3/4" copper poly -wrapped to connect the existing services
to new line (price will include all necessary fittings
for the complete service re -connection)
s13.foS $ PV10.00
Du
(figures)
s2/( A r4ul �� unU� Opt u �n l o�-ea^� al
(tote - words) t' C�
7
12. Lump Sum Top soil/seeding/mulching to match existing
lawns where sod is not applicable
5 j(000. o0 S Mlr" O .0 0
(figures)
Q) 4 --Black4 4tt1 qw cI ,A.c� aka
(total - words)
550O SY
13. Lu um Remove preserve and relay
existing sod / or lay new
matching sod
s2.oS S//21E 0v
(figures)
d 1 • I e
14. 75 SY 6" thickness Concrete Parking Lot Repair
maximum of 5' of trench width allowed for payment
s33.0O s2¼75,00
(figures)
u..LLk&JdA AX"ilii A -L
(total -
15. 2 EA Connection of 2" service line to new water mains
s 4SSO. 00 s 3.146O.64n,
(figures)
(total - words)
16. 485 SY Asphalt Parking Lot
or Asphalt Street Repair
s36.0o sl7 Vto0 0o
(figures)
(total - words) UML� h�0- (g •
r)
17. lump sum Mobilization,
and storage
$ H400.Oo S Al�YOO. 0 O
(figures)
(total - words)
18, lump sum Trench safety requirements.
52 IOO,OOS 1100,00
(figures)
satWwJ &L L B u. actwai c) �3SAnn,,. a4ual ✓'ai c t.
(total - words)
19. 150 LF Standard Curb and Gutter Repair
513.Oo $ )(9SO,00
(figures)
$ o*n. wa otnct.u:�..L . L w dAs 4Lat cA a al
(total - words)—�
20. 5 SY Sidewalk Repair - 4" thickness
(total - words)
21. 10 EA Salvage of existing fire hydrant barrel
and transport to City's
Operation Center on Cato Springs Rd.
52SO.OO $ 2ic n oa
(figures)
$ew � n �.V.li�l,,Q./`eQ(, dtQ eA24, anQ
(total - words)A,
5
22. 190 LF 8" C-900 water pipe DR14 Class 200
s iioo $ 3130.00
(figures)
satiri .$ Qn c uaw>.w.-c ..P�.,.d4sid .u:tt d Q-Q.Aa.�.,
(total - words) 0jvt3LMA/ UA r
23. 100 C.Y. Solid Rock Excavation
(totaV- words)-�J1.
24. 620 Tons Class 7 aggregate backfill
for driveways, street, and parking lot crossings
s/(O.2O $ /OIOMM.OO
(figures)
(total - words)
25. Lump Sum Clearing and Grubbing
s YOoo,00 s '/000.00
(figures)
S)t f9nn ytS-cQnloo
(total - words)
26. Lump Sum Erosion Control
/ .f'r• /4a&
(total - words)
6
I
1
1
1
i
1
1
1
1
1
1
i
1
1
1
1
1
1
1
27. 8 EA Cap and Plug existing water lines, which will be
abandoned, at all connection points to the new mains
r=•:
80 LF
29. 107 LF
30. 255 LF
$ 9'ID, Oo $ 752 O. n o
(figures)
(total - words)Q,AJ Q V
Highway Bore 16" Steel Encasement pipe on specified grade
for sanitary sewer crossing.
515O•Do s/.2 6o0-oa
(figures)
$ "" AkAt �.,ouJanvvdsa&o,n s OA&Ot V CQ.AAt
(total - words)
8" D.I.P. (with Field Lock Gaskets) Sewer Pipe for Highway
Crossing per specified grade
s J/l1. o a $ y7o f3 0 O
(figures)
(total - words)
Highway Bore 16" Steel Encasement Pipe for proposed 8"
water line crossings in three separate locations.
/sl�CE'�i_1Cs..
(
$13Q.OO s 33(15n.00
(figures)
7
31. 90 LF Highway Bore 12" Steel Encasement Pipe for proposed 6"
water line crossing
I
1
1
1
1
1
1
1
1
1
s9O.OO s8.1oO.00
qq (figures)
(total - words)
32. 105 LF 6" D.I.P.
(with
Field Lock Gaskets)
water pipe for Highway
crossing
33. 130 LF
34. 335 LF
s 2(0,0o s 273O.OO
(figures)
(total - words)9tV.d` VNJ'
Highway (90') and Street (40') Bore 30" Steel Encasement
pipe for proposed 18" water line crossings
s24o.00 s33pO.00
(figures)
(total - wor{js) aflAJS' C-
8" D.I.P. (with Field Lock Gaskets) Water Line for Highway
Crossings per specified grade
f
(rota!
(figures)
words) J riO, C.tMZl
U
35. 112 LF 18" D.I.P. (with Field Lock Gaskets) Water Line for Highway
crossing per specified grade
$62.O° S 9a•/oo
(figures)
(total - words)QjUd•, n,Q.. c_Q/Vi
36. 14 V.F. Standard Sewer Man Hole cast in place
s290.0O $ 'Y,OtO.ov
(figures) �e
r
(total - words)
37. Lump Sum
Connection
of
new 8"
sanitary sewer to
the existing man hole
by means
of
core
drilling and water
proof repair
s 2S&O.OJs 21fny. o0
(figures)
(total - wordsb f . Dk V y' ,'CLAA.*
38. 14 LF 8" PVC sewer Pipe complete in place on specified grade
s90,00 $ / 12,0, 0 0
(figures)
(total - words)
E
I
' 39. 480 CI
I
I
(total - words) ' V
1
40 5 EA New 3/4" Meter Set up Complete with box and Lid and meter
yoke and all necessary fittings
s390.ao s?.9SO.Oo
(figures)y1y�� °�Q $ (total - words)_,.v--,� � _. _ .--1 V
•
Total basic contract price $ 6 O/ Q % S. so
(figures)
�—�
1 9� o g
(total -words)
Bidders must bid the schedule in its entirety including all items, The City of
Fayetteville reserves the right to reject any and all bids and waive any
' formalities as deemed in the best interest of the City of Fayetteville.
The undersigned hereby declares: That he has examined the Plans and the
Specifications with the related documents and the site of the proposed work
and being familiar with all conditions surrounding construction of the
proposed project, including availability of material and labor, hereby
proposes to furnish all equipment, labor, material, plant and supplies, within
the time set forth herein and at the prices stated above. These prices are to
cover all expenses incurred in performing the work required under the Contract
Documents, of which this proposal is a part.
The undersigned further agrees, if awarded the contract, the Contractor shall
begin work within ten (10) calendar days from a Notice to Proceed and will
' fully complete all work within ninety (90) consecutive calendar days after the
date of the Notice to Proceed. Should the Contractor fail to complete the
work within the stated time, he shall pay the Owner as fixed, agreed, and
liquidated damages $300.00 per day for each consecutive calendar day of delay
until the work is completed or accepted.
The undersigned submits the following subcontractors for use if the contract
' 10
Special Hillside Backfill Material (Compacted 95% Standard)
for any work within the Highway R.O.W.
$/O, SO sSo•/O. a o
(f igur.$)
I
I
I
I
I
L1
I
I'
1J
r
I
I
I
I
I
I
is awarded. The owner shall have the authority to reject the use of any
subcontractor.
Subcontractors
Name Address Contractor's license no.
Additional time is allowed for delays as stipulated in the Contract Documents.
The undersigned acknowledges the receipt of the following Addendum:
For changing quantities of work items from those indicated by the contract
Documents, upon written instructions from the Engineer, the above unit prices
as given in the proposal shall prevail. The above unit prices shall include
all labor, materials, plant, bailing, shoring, overhead, profit, insurance,
bonds, etc., as necessary to cover the finished work of the various kinds
called for. The bidder understands that the City of Fayetteville reserves the
right to reject any or all bids and waive any formalities as deemed in the
best interest of the City of Fayetteville.
The bidder
does
agree that
this bid shall be good and
may
not be
withdrawn for
a period of
60
days after
the scheduled closing time
for
receipt
of bids.
Further the undersigned agrees to fully and completely submit the detailed
"STATEMENT OF BIDDER'S QUALIFICATIONS" as found on the page immediately
following the proposal. The undersigned agrees that failure to complete
and/or provide the "STATEMENT OF BIDDER'S QUALIFICATIONS n shall be cause for
the Owner and/or Engineer t2onsi r the bid non -responsive and to reject
such bid.
ByNL
-U,Llc VAk/a. J
Title
3301 -'). a,vd,dam± gCnt,o O7'x175to
Business Address
601)1,036-77O 5
Telephone
000cO40&99
Arkansas License Number
STATEMENT OF BIDDER'S QUALIFICATIONS
All questions must be answered and the data given must be clear and
comprehensive. This statement must be notarized. If necessary, questions may
' be answered on separate sheets and then attached to this statement. The
Bidder may submit any additional information that he desires. trU�'pyI
' 1 . Name of wf B idder . `%10cLk) WAAJd GCOJ ' acm� "
2. Permanent main office ad re s and telephone number. 3,30 ) olr-s'
(fo') & 3e-779 6
3. When organized. (9 )39
9
4. If a corporation, where incorporated.
1 5. Contractor's License number. OOo00 ao(o99
' 6. How many years have you been engaged in the contracting business under
your present firm or trade name? under other names? 5O
7. Contracts on hand. (Schedule these, showing the amount of each contract
'
and the appropriate anticipated dates of completions, and a point of contact
for references. ),& . Q*tnchnnitM ,4
' 8. Have you ever failed to complete any work awarded to you? `✓t4-
9. Have you ever defaulted on a contract? If so, where and why? �'
' 10. Experience in construction similar in size and scope to th's roject,
g
along with the project owners and engineers.4t QO 6
Iii. List of major equipment available for this
12. Will you, upon request, fill out a detailed financial statement,
including credit worthiness, and furnish any other information that may be
required by the Owner?
Dated ate ouuM. this 3rcl day of
' N9 49^z'h a Gil/ y1 t�
Name of Organization:
' by
State of _________"'-'^�`�
County of X61 ._'_
OAM., being duly sworn deposes
and s that (she) is the A:4w /tza.c
' of ntractor s), and
that answers to the foregoing questions and all sta menu therein contained
are true and correct. rO'
Subscribed and sworn before me this day of 1999
C2 3tary Public My commission expires ��( �1 , r0ON
(seal)
I
I
J
I
I
I
L
C
I
I
I
I
I
0
L
0
U
C
.le
U
O
O
z
O
C
5
C
z
O
U
oC
a
z
I
I
I
I
[1
I
INSTRUCTIONS FOR BIDDERS:
1. Defined Terms. Terms used in these Instructions to Bidders which are
defined in the Standard General Conditions of the Construction Contract shall
have the meanings assigned to them in the General and Supplementary
Conditions. The term "Bidder" means one who submits a Bid directly to the
Owner, as distinct from a sub -bidder who submits a bid to a Bidder. The term
"Successful Bidder" shall mean the lowest, qualified, responsible and
responsive Bidder to whom Owner (on the basis of Owner's evaluation as
hereinafter provided) makes an award. The term "Bidding Documents" includes
the Advertisement or Invitation to Bid, Instructions to Bidders, the Bid
Proposal Form, and the proposed Specifications and Contract Documents
(including all Addenda issued prior to the receipt of Bids).
2.
Copies
of the Bidding
Documents.
Complete sets of the Bidding Documents
in
the
number and amount,
in any, stated in the Advertisement to invitation to
Bid
may
be obtained from
the Engineer
upon request.
H
I
I
I
I
CI
1
I
I
I
I
Complete sets of Bidding Documents must be used in preparing Bids; neither
the Owner nor Engineer assumes any responsibility for error or
misunderstandings resulting from the use of incomplete sets of Bidding
Documents.
Owner and Engineer in making copies of Bidding Documents available on the
above terms do so only for the purpose of obtaining Bids on the Work and do
not confer a license or grant for any other use.
3•: Qualifications of Bidders. When included with, and made a part of the
Bid Proposal, the Bidder must submit a completed "Statement of Bidder's
Qualifications" an part of the Bid Proposal. The "Statement of Bidder's
Qualifications" is required to demonstrate qualifications to perform the Work
and will be used in evaluating all bids as a basis for award.
4. Examination of Contract Documents and Site.
4.1. It is the responsibility of each Bidder before submitting a Bid, to :
(a) examine the Contract Documents thoroughly,
(b) visit the site to become familiar with local and specific conditions which
may affect cost, progress, safety, performance or furnishing of the Work,
(c) consider all Local, State and Federal Regulations and Laws which may
affect cost, progress, safety, performance or furnishing of the Work,
(d) study and carefully correlate Bidder's observations with the Contract
Documents and
(e) notify Engineer of any and all conflicts, errors or discrepancies in the
Contract Documents.
4.2 Information and data reflected in the Contract Documents with respect to
Underground Facilities at or contiguous to the site is based upon information
and data furnished to the Owner and Engineer by owners of such Underground
Facilities or others, and Owner nor Engineer does not assume responsibility
for the accuracy or completeness thereof unless it is expressly provided
otherwise in the Supplementary Conditions.
4.3 Provisions concerning responsibilities for the adequacy of data
furnished to prospective Bidders on subsurface conditions, Underground
Facilities and other physical conditions, and possible changes in the Contract
Documents due to differing site conditions appear in Article 4 of the General
Conditions and any associated Supplementary Conditions.
I
I
4.4 Before submitting a Bid, each Bidder will, at Bidder's own expense, make
or obtain any additional information, examinations, explorations, tests and
studies which pertain to the physical conditions of the surface and subsurface
at, or contiguous to the site or other wise which may affect cost, progress,
safety, performance or furnishing of the Work and which the Bidder deems
necessary to determine the Bid for performing and furnishing the Work in
accordance with the time, price and other terms and conditions of the Contract
Documents.
4.,5 Upon request in advance, the Owner will provide each Bidder access to the
site to conduct any observations, explorations and tests as each Bidder deems
necessary for submission of a Bid. Bidder shall be required to fill in all
holes and to restore all property to its former condition.
4!6 The lands upon the Work is to be performed, rights -of -way and easements
for access thereto and other lands designated for use by the Contractor in
performing the Work are identified in the Contract Documents. All additional
lands and access thereto required for temporary facilities or storage of
materials and equipment are to be provided by the Contractor. . Easements for..
permanent structures or permanent changes in existing structures are to be
obtained in advance by the Owner unless specifically noted otherwise in the
Contract Documents.
4.17 The Bidder must satisfy themselves of the accuracy to the estimated
quantities in the Bid schedule by examination of the site and a review of the
drawings and specifications including any Addenda. After bids have been
submitted, the Bidder shall not assert that there was any misunderstanding
concerning the quantities of Work or the nature of Work to be performed. ..
The submission of a Bid will constitute an irrevocable representation by
Bidder that Bidder has complied with every provision and requirement of this
paragraph 4, that without exception the Bid is premised upon performing and
furnishing the Work required by the Contract Documents and such means,
methods, techniques, sequences or procedures of construction as may be
indicated in or required by the Contract Documents, and that the Contract
Documents are sufficient in scope and detail to indicate and convey
understanding of all terms and conditions for performance and furnishing the
Work.
5.� Interpretations and Addenda.
All questions about the meaning or intent of the Contract Documents are to be
directed to the Engineer. Interpretations or clarifications considered
necessary by the Engineer in response to such questions, and/or any --
information deemed necessary by the Owner or Engineer, will be issued by
Addenda mailed or delivered to all parties recorded by the Engineer as having
received the Bidding Documents. Only questions answered and/or other
information furnished by formal written Addenda will be binding.
The Point of Contact for questions and clarifications for this specific
project is Sid IJormbas 5fv{F 6..yisete/ Engineering (501) 575-8206.
6.. Bid security.
Each Bid must be accompanied by Bid security made payable to the Owner in an
amount od five percent (5%) of the Bidder's total maximum bid price and in the
form of a certified or bank check or a Bid Bond (on form attached, if a form
is prescribed and included) issued by a surety meeting the requirements of the
General and Supplementary Conditions.
2
1
C
' The Bid security of the Successful Bidder will be retained until such Bidder
has executed the Agreement and furnished the required contract security,
whereupon the Bid security will be returned. If the Successful Bidder fails
to execute and deliver the Agreement and furnish the required contract
' security within 15 days after the Notice of Award, Owner may annul the Notice
of Award and the Bid security of that Bidder will be forfeited. The Bid
security of other Bidders whom the Owner believes to have a reasonable chance
of receiving award may be retained by Owner until the earlier of the seventh
' day after the Effective Date of Agreement or the 61st day after the Bid
opening, whereupon the Bid security furnished by such Bidders will be
returned. Bid security with Bids which are not competitive will be returned
within 10 days of Bid opening.
' 7. Contract Time.
' The number of days within which, or the dates by which, the Work is to be
substantially completed and also completed and ready for final payment (The
Contract Time) are as set forth in the Bid Proposal, Contract Agreement and
Technical Specification 100 - General Project Requirements.
' 8. Liquidated Damages.
' Provisions for liquidated damages, if any, are set forth in the Bid Proposal
and/or the Contract Agreement.
' 9. Substitute or "Or -equal" items.
The Contract, if awarded, will be on the basis of materials and equipment
described in the Drawings or specified in the Specifications without
'• consideration of possible substitute or "or -equal" items. Substitute or ''or -
equal" .tams of materials or equipment, unless it is specified that no
substitute will be allowed, may be furnished or used by the Contractor if
acceptable to the Engineer. Application for acceptance for possible
' substitute or "or -equal" items will not be considered by the Engineer until
after the effective date of the Contract Agreement. The procedure for
submission of any such application is set forth in Article 6.7 of the General
Conditions and any associated Supplementary Conditions.
A 10. Subcontractors, suppliers and others.
' The Contractor shall not assign or sublet all or any part of this Contract
without the prior written approval of the Owner and Engineer. Nor shall the
Contractor allow any subcontractor to commence work until he has provided and
obtained approval of such compensation and public liability insurance as
' required by the Contract Documents. The approval of each subcontract by the
Owner will in no manner release the Contractor from any of his obligations as
set forth in the Contract Documents including the Plans, Specifications,
Contract and Bond(s).
11. Bid Proposal Form.
11.1 All bids must be made on the required Bid Proposal form contained in the
Bidding Documents. Additional copies may be requested from the Engineer.
11.2 All blank spaces for Bid prices must be filled in, in ink or type
written, and the Bid form must be fully completed and executed when submitted.
Only one (1) copy of the Bid form is required.
[l
C1
11.3 Bids by corporations must be executed in the corporate name by the .,
president or vice-president (or other corporate officer accompanied by
evidence of authority to sign) and the corporate seal must be affixed and
attested by the secretary or an assistant secretary. The corporate address
and state of incorporation must be shown below the signature.
11.4 Bids by partnerships must be executed in the partnership name and signed
by'a partner, whose title must appear under the signature and the official
address of the partnership must also be shown below the signature.
11'.5 All names must be typed or clearly printed in ink below the signature.
11.6. The Bid shall contain an acknowledgement of receipt of all Addenda (the
numbers of which must be filled in on the Bid form).
11.7. The address and telephone number for communications regarding the Bid
must be shown. ._
12. Submission of Bids.
Bids shall be submitted at the time and place indicated int eh Advertisement
or;Invitation to Bid and shall be enclosed in an opaque sealed envelope,
marked in the lower left portion with the Project Title, Bid Number, Date of
the bid opening, time of the bid opening, bidding contractor's name and
license number. The Bid shall be accompanied with the Bid Security and other
required forms and documents.
If the Bid is sent through the mail or other delivery system, the sealed
envelope shall be enclosed in a separate sealed envelope wit the notation "Bid
Enclosed" on the face of the outer envelope.
THE BID PROPOSAL FORM SHALL NOT BE REMOVED FROM THE BOUND SPECIFICATIONS AND
CONTRACT DOCUMENTS.
13: Modification and Withdrawal of Bids.
Bids may be withdrawn or modified by an appropriate duly executed document (in
the manner that a Bid must be executed) and delivered to the place where Bids
are to be submitted at any time prior to the opening of Bids.
If, within 24 hours after the opening of Bids, any Bidder files a duly signed,
written notice with Owner and promptly thereafter demonstrates to the
satisfaction of Owner that there is a material and substantial mistake in the
preparation of its Bid, that Bidder may withdraw its Bid and the Bid security
will be returned. Thereafter, that Bidder shall be disqualified from further
Bidding on the Work provided under the Contract Documents.
14J Opening of Bids.
Bids will be opened and publicly read aloud at the time and location as
specified in the advertisement of invitation for bids. A tabulation of the
amounts of the Bids will be made available to the Bidders after preparation by
the Engineer.
1
4,
1
I
I
I
L
I
H
H
H
I
H
I
I
H
H
H
[I
15. Bids to remain subiect to acceptance.
All Bids shall remain subject to acceptance for 60 days after the day of the
Bid opening, but Owner may, at its sole discretion, release any Bid and return
the Bid security prior to that date. Additionally, if deemed necessary by the
Owner, the Owner and the apparent Successful Bidder may enter negotiations to
extend the time of acceptance beyond the 60 days, with no changes in the Bid
Proposal or Contract Documents.
16. Award of Contract.
16.1 Owner reserves the right to reject any and all Bids, to waive any and
all informalities not involving price, time or changes to the Work, to
negotiate contract terms with the Successful Bidder, and the right to
disregard all nonconforming, nonresponsive, unbalanced or conditional bids.
The Owner further reserves the right to reject the Bid of any Bidder if the
Owner believes that if would not be in the best interest of the Project or
Owner to make award to that Bidder, whether because the Bid is not responsive
or the Bidder is unqualified or of doubtful financial ability, or of doubtful
past performance, or fails to meet any other pertinent standard or criteria
established by the Owner. Discrepancies in the multiplication of units of
Work and unit prices will be resolved in the favor of the unit prices.
Discrepancies between the indicated sum of any column of figures and the
correct sum thereof will be resolved in favor of the correct sum.
16.2 In evaluating the Bids, Owner will consider the qualifications of
Bidders, whether or not Bids comply with the prescribed requirements, and such
alternates, unit prices, and other data, as may be requested in the Bid
Proposal Form or prior to Notice of Award.
16.3 Owner may consider the qualifications and experience of the
subcontractors, suppliers and other persons and organizations proposed for
those portions of the Work as to which the identity of subcontractors,
suppliers and other persons and organizations must be submitted as provided
for in the Contract Documents. Owner may also consider the operating costs,
maintenance requirements, performance data and guarantees of major items of
material and equipment proposed for incorporation in the Work when such data
is required to be submitted prior to the Notice o2 Award.
16.4 Owner may conduct such investigations as Owner deems necessary to assist
in the evaluation of any Bid and to establish the responsibility,
qualifications and financial ability if Bidders, proposed subcontractors,
suppliers and other persons and organizations to perform and furnish the Work
in accordance with the Contract Documents to Owner's satisfaction within the
prescribed time.
16.5 If the contract is to be awarded, it will be awarded to the lowest
responsive, responsible, qualified Bidder whose evaluation by Engineer
indicates to Owner that the award will be in the best interests of the Project
and Owner.
16.6 If the contract is to be awarded, Owner will give the Successful Bidder
a Notice of Award within 60 days after the date of the Bid opening. If deemed
necessary by the Owner, the Owner and the apparent Successful Bidder may enter
negotiations to extend the time of acceptance beyond the 60 days, with no
changes in the Bid Proposal or Contract Documents.
5
1]
I
17. Contract Security. _ . - -
Aiticle 5 of the General Conditions, and the associated Supplementary
Conditions set forth the Owner's requirements as to Performance and Payment
Bonds. When the Successful Bidder delivers the executed Agreement to Owner,
it must be accompanied by the required Performance and Payment Bonds.
18. Signing of Agreement.
i
When Owner gives Notice of Award to the Successful Bidder, it will be
accompanied by the required number of unsigned counterparts of the Agreement
with all other Contract Documents attached. Within 15 days thereafter,
Contractor shall sign, execute and deliver the required number of counterparts
of the Agreement and attached documents to the Owner with the required Bonds.
Within ten (10) days thereafter Owner shall deliver one fully signed and
executed to Contractor.
19. Compliance with State Licensing Law.
Contractors must be licensed in accordance with the requirements of ACT 150,
Arkansas Acts of 1965, the "Arkansas State Licensing Law for Contractors."
Bidder who submit Bids in excess of $20,000.00 must submit evidence of their
having a contractor's license before their Bids will be considered, and shall
note their license number on the outside of their Bid.
i
20. Labor Laws.
The Contractor shall abide by all Federal, State and Local Laws and ..
Regulations governing labor. The Contractor shall further agree to hold and
save the Owner harmless from the payment of any contribution under the State
Unemployment Compensation Act, and the Contractor agrees that if he is subject
to the Arkansas State Unemployment Act, he will make whatever contributions
are required under and by virtue of the provisions of said Act.
21.. Wages and Labor. ,
Minimum wage rates shall be equal to the basic rates as established by common
usage in the city and adjacent community for the various types of labor and
skills performed. In cases where wage rate determinations are specified in
the Contract Documents, the rates as specified shall be the minimum rates
which apply to the Project. Whenever available, the Contractor shall make use
of local common and/or skilled labor as is practical.
The Contractor and each subcontractor, where the amount exceeds $75,000.00
shall comply with the provisions of Act 74, as amended by Act 275 of 1969
(Arkansas Stat. 14-630). The provisions are summarized below.
The Contractor and Subcontractor shall:
1) pay the minimum prevailing wage rates for each craft or
type of workman and the.prevailing wage rate for holiday
and overtime work, as determined by the Arkansas Department
of Labor,
2) post the scale of wages in a prominent and easily
accessible place at the site of the Work,
1
61
I
Li
3) keep an accurate record showing the names and occupation and
'
hours worked of all workmen employed by them, and the
actual wages paid to each of the workmen, which records
shall be open at all reasonable hours to the inspection
of
the Department of Labor or the Owner, its officers and
'
agents.
A copy of the prevailing wage rates for this specific project,
as established
by the Arkansas Department of Labor, is attached in the Contract
Documents
'
immediately following the Instructions to Bidders.
The Owner shall have the right to withhold from amounts due the
Contractor so
much of accrued payments as may be considered necessary to pay
the workmen
'
employed by the Contractor or any subcontractor, the difference
between the
rates of wages required by this Contract and the rates of wages
received by
such workmen.
H
1
I
1
1
I
H
H
If it is found that any workmen employed by the Contractor or subcontractor
has been, or is being paid a rate of wages less that the rate of wages
required by this Contract, the Owner may by written notice to the Contractor,
terminate the Contractor's right to proceed with the Work or such part of the
Work as to which there has been a failure to pay the required wages and to
prosecute the Work to completion by Contract or otherwise, and the Contractor
and his sureties shall be liable for any costs occasioned thereby.
22. Compliance with Act 125, Arkansas Acts of 1965.
The attention of Bidders is called to the provisions of Act 125, Arkansas Acts
of 1965. This act provides for the payment of certain taxes on materials and
equipment brought into the State. It further provides for methods of
collecting such taxes. All provisions of Act 125, Arkansas Acts of 1965 shall
be complied with under this Contract.
23. Withholding State Income Taxes.
The Contractor shall deduct and withhold Arkansas income taxes, as required by
Arkansas law, from wages paid employees, whether such employees are residents
or nonresidents of Arkansas.
24. Compliance with Rules and Regulations for the Enforcement and
Administration of Act 162, Arkansas Acts of 1987.
The attention of all nonresident Bidders is called to the provisions of Act
162, Arkansas Acts of 1987. This act provides for nonresident Contractors and
subcontractors notice and bond regulations by the Commissioner of Revenues,
Dept. of Finance and Administration, P.O.Box 1272, Little Rock, Arkansas
72203 prior to commencing work or undertaking to perform any duties under
contract within the State of Arkansas.
25. Subcontractors Bonds - Act 190, Arkansas Acts of 1993.
The attention of Bidders is called to the provisions of Act 190, Arkansas Acts
of 1993. In general, this act provides for the subcontractors to provide to
the General Contractor performance and payment bonds, with certain regulations
on form and time, when the subcontractor's bid is in excess of $50,000.00.
6
I
26. Excavation Safety.
The attention all Bidders is called to the requirements of Act 291, Arkansas
Acts of 1993 - Excavation and Trench Safety.. The current edition of
Occupational Safety and Health Administration Standard for Excavation and
Trench Safety Systems, 29 CPR 1926, Subpart P, is specifically incorporated
and made a part of these specifications and contract documents as required by
Arkansas Act 291 of the 79th General Assembly of 1993. The Contractor shall be
solely responsible for the implementation of these requirements.
Alcopy of the OSHA regulations is included in this set of specifications as
Appendix A.
27. Special conditions in the specifications.
Please carefully read section 100 GENERAL PROJECT REQUIREMENTS, 110
MEASUREMENT AND PAYMENT and all of the specifications, for the conditions
unique to this project. The special conditions include, among others:
aJ No area of City streets or City right-of-way can be used for material
storage.
bl Open trenches shall not be allowed overnight. The contractor shall limit
the trenching and pipe laying to the work which can be installed and inspected
during the working day.
c. A minimum of one lane of traffic shall be safely maintained at all times.
End of the Instructions to Bidders
11
1
1
•1
1
1
I.
1
1
03/15/1999 13:28
1
1 Mike Hutkabeo
0a+.o
1
5016824508
ARDEPTLABOR
STATE OF ARKANSAS
ARKANSAS DEPARTMENT OF LABOR
10421 WEST MARKHAM • LITTLE ROCK, ARKANSAS 72205-2190
(501) 682-4500 • FAX (501) 682-4535 • TDD: (500) 285-1131
PAGE 01
James L. Sa!keld
U•.o.,
March 15, 1999
Peggy Vice, Purchasing Manager
1 City of Fayetteville
113 West Mountain
Fayetteville, AR 72701
1
Re: Highway 16 West
1 Water & Sewer Relocations
Fayetteville, Arkansas
Washington County
1 s
Dear Ms. Vice:
Please be advised that the Arkansas Prevailing Wage Law shall not be construed to apply
to or affect highway, road, street, or bridge construction and maintenance or related work
1 contracted for or performed by incorporated towns, cities, counties, or the Arkansas State
Highway and Transportation Department. Ark. Code Ann. §22-9-303(b)(1987).
The Prevailing Wage Law excludes the above -referenced project from coverage and you
are under no obligation to obtain a wage determination from this department.
1 I have enclosed the required form to be used in requesting wage rates. Please fax your
requests to (501) 682-4508.
1 If you have any questions, or if I can be of further assistance, please contact me at the
above address or call (501) 682-4536.
Sincerely,
1 Don Cash
Prevailing Wage Division
PWL-12A
I
I
L
CONTRACT
' THIS AGREEMENT, made and entered into the 4th day of May
1999 by and between the City of Fayetteville, County of
Washington, State of Arkansas, Party of the First Part, hereinafter
called the Owner, and Northwest Excavation, a Division of Nabholz Construc-
' tion Corporation, of the City of Rogers, Arkansas, Party of
the Second Part, hereinafter called the Contractor.
' WITNESSETH THAT:
WHEREAS, the Owner has called for bids for water system
improvements, as set out in the Plans and Specifications and
approved by the City of Fayetteville, Arkansas; and
WHEREAS, pursuant to the published calls for bids under said Plans
'
and Specifications, the Contractor is the lowest and best qualified
bidder for the construction of said Improvements;
I
I
I
I
I
I
I
J
NOW THEREFORE, the Contractor agrees with the Owner to commence and
complete the construction of:
Bid No. 99-35 which shall be Highway 16 W. Widening - Water and
Sewer Relocations, Fayetteville, Arkansas; including all Work
required for a complete and acceptable installation, for the unit
and lump sum prices bid in the Bid Proposal, all of which become
and are a part of this Contract, the total sum thus being
Six Hundred One Thousand Seventy-five Dollars and 50/100
dollars ($ 601,075.50 ),. such sum being the agreed amount upon
which bonds and liabilities are based, and at his own cost and
expense furnish all materials, supplies, labor, machinery,
equipment, tools, supervision, bonds, insurance and other
accessories and services necessary to complete the said
construction in accordance with the conditions and prices stated in
the Bid attached hereto and made a part hereof, and in accordance
with the Technical Specifications, the General Conditions, the
Supplementary Conditions, and in accordance with the Plans, which
include all maps, plats, blueprints, and other drawings, and
written or printed explanatory matter thereof.
The Contractor agrees to commence work under this contract within
ten days of the issuance of the Notice to Proceed and totally
complete all work within ninety (90) calendar days.
The Owner agrees to pay the Contractor in current funds for the
performance of the contract in accordance with the accepted Bid
therefor, subject to additions and deductions, as provided in the
Specifications, and to make payment on account thereof as provided
below.
1
J
I
L
I
I
H
H
I
I
I
C
I
I
IH
I
I
I
I
As soon as is practicable after the first of each calendar month,
and in accordance with the Contract Specifications, the Owner will
make partial payments to the Contractor for work performed during
the preceding calendar month, based upon the Engineer's estimate of
work completed, said estimate being certified by the Contractor and
accepted by the Owner. Retainage shall be withheld from the
partial payments as provided by Arkansas state laws by the Owner
until final completion and acceptance by the Owner and Engineer.
The Engineer shall then issue a Final Estimate of work done based
upon the original contract and subsequent changes made and agreed
upon, it any.
Time is hereby expressly declared to be of the essence of this
contract, and the time of beginning, manner of progress and time of
completion of the work hereunder shall be and are essential
conditions hereof.
The Contractor agrees to commence work within ten (10) calendar
days from the date of the Notice to Proceed and to proceed with the
construction of the work and to prosecute the work with an adequate
force and in a manner so as to complete the work within the time
stipulated herein. If the Contractor fails in completing the
contract within the time stipulated herein, the Contractor agrees
to pay the Owner, as liquidated damages the sum of three hundred
dollars ($300.00) per day for each calendar day of delay in
completion, said amounts being fixed and agreed upon by and between
the parties hereto. Because of the impracticability and extreme
difficulty in fixing and ascertaining the actual damages Owner
would in such event sustain, said amounts are to be presumed by the
parties to this contract to be the amounts of damage Owner would
sustain. Said amounts of liquidated damages shall be deductible
from any amount due Contractor under the Final Estimate of said
work, after the completion thereof, and Contractor shall be
entitled any to the Final Estimate less such amounts of liquidated
damages.
If the Contractor be delayed at any time in the progress of the
work by any act or neglect of the Owner or of the Owner's
employees, or by any other Contractor employed by the Owner, or by
changes ordered in the work, or by strikes, lockouts, fire, unusual
delay in transportation, unavoidable casualties or any causes
beyond the Contractor's control, or by delay authorized by the
Engineer pending arbitration, or by any cause which the Engineer
shall decide to justify the delay, then the time of completion
shall be extended for such reasonable time as the Engineer may
decide.
No such extension shall be made for delay occurring more than seven
days before claim therefor is made in writing to the Engineer. In
the case of a continuing cause for delay, only one claim is
necessary.
H
I
C
L
H
H
H
H
H
n
I
I
Ti
I
In the event the Contractor abandons the work hereunder or fails,
neglects or refuses to continue the work after ten (10) days
written notice, given Contractor by the Owner or by the Engineer,
then the Owner shall have the option of 1) declaring this contract
at an end, in which event the Owner shall not be liable to the
Contractor for any work theretofore performed, or 2) requiring the
surety hereto, upon ten (10) days notice, to complete and carry out
the contract of Contractor; and in that event, should be surety
fail, neglect or refuse to carry out said contract, 3) said Owner
may complete the contract as its own expense and maintain an action
against the Contractor and the surety hereto for the actual cost of
same, together with any damages or other expense sustained or
incurred by Owner in completing this contract, less the total
amount provided for hereunder to be paid Contractor upon the
completion of this contract.
This contract shall be binding upon the heirs, representatives,
successors or assigns of the parties hereto, including the surety.
IN WITNESS WHEREOF, the Owner and Contractor have hereto set their
hands and seals. respectively.
F rm
By Zle
1
Witnesses*
*If corporation, secretary should attest.
Attest:
CITY OF FAYETTEVILLE, ARKANSAS
Fr Hanna, Mayor
End of Contract
ACORD CERTIFICATE OF
LIABILITY INSURANCE 05/05/1 9
(501)666-6653 FAX (501)666-7168
ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
rst Arkansas Insurance
HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
JP,RIODUCER
Box 251956
ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
01 Mart Drive
COMPANIES AFFORDING COVERAGE
ttle Rock, AR 72225-1956
COMPANY St. Paul Mercury Insurance Company
n: Marylea Gazette Ext: A
uRED
COMPANY Transcontinental Insurance Co.
Northwest Excavation
B
P0 Box 277
3301 N. 2nd St.
COMPANY
C
Rogers, AR 72757-0277
COMPANY
D
OVERAGE5 - . .
. - - -.
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED
BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN. THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS.
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
0 TYPE OF INSURANCE POLICY NUMBER
LTA
POLICY EFFECTIVE POLICY EXPIRATION. LIMITS
DATE (MM/DDIYY) DATE (MWDDMy)
GENERAL LUBILITY
GENERAL AGGREGATE f 2,000,QQQ
X COMMERCIAL GENERAL LIABILITY
PRODUCTS-COMPOPAGG $ 2,000,OOO
CLAIMS MADE X OCCUR
A KK09100834
PERSONAL & ADV INJURY $ 1,090.999
04/01/1999 04/01/2000
OWNERS & CONTRACTOR'S PROT
. . EACH OCCURRENCE $ 1,000,000
_ - FIRE DAMAGE(My WeFve) $100,000
... ... .10
__.
MED EXP (My We persm) $ 000
AUTOMOBILE LIABILITY
COMBINED SINGLE LIMIT $
X ANY AUTO
1,000,000
ALL OWNED AUTOS
BODILY INJURY
SCHEDULED AUTOS
(Pe,pMson)
A KK09100834
04/01/1999 04/01/2000
X HIREDAUTOs
BooavlNJURv &
X NON -OWNED AUTOS
(Per acade4'J)
- -
PROPERTY DAMAGE S
GARAGE LIABILITY
AUTO ONLY - EA ACCIDENT S
ANY AUTO
OTHER THAN AUTO ONLY-
EACH ACCIDENT $
AGGREGATE S
EXCESS UABILT' _
EACH OCCURRENCE S 20,090,000
A UMBRELLA FORM KK09100834
04/01/1999 04/01/2000 AGGREGATE s 20,000,000
OTHER THAN UMBRELLA FORM
$
WORKERS COMPENSATION AND
X TORY LIMITS ER
EMPLOYERS'LIABILITY
EL EACH ACCIDENT S 5QO OOO
B WCB176784816
04/01/1999 04/01/2000
THE PROPRIETOR/ X INCL
EL DISEASE. POLICY LIMIT $ 500, OOO
PARTNERSIEXECUTIVE
OFFICERS ARE'. EXCL
. EL DISEASE- EA EMPLOYEE $ 500 000
OTHER
ESCRIPTION OF OPERATION&LOCATIONSNEIUCLE&SPECIAL ITEMS
roject:Highway 16W Widening - Water & Sewer
Relocations
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE
EXPIRATION DATE THEREOF. THE ISSUING COMPANY WALL ENDEAVOR TO MAIL
30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT.
City of Fayetteville
BUT FAILURE TO MAIL SUCH NOTICESHALL IMPOSE NOOBUGATION OR UABILITY
113 West Mountain
OF ANY KIND UPON THE CO . ITS AGENTS ORREP SENTATIVES,
Fayetteville, AR 72701
AUTHORIZED REPRESEN A
C
Steven Russell -
CORD 383 (U9S) - .. . .
- - . CORD CORPORATION 19
J
' ST. PA[iL FIRE AND MARINE INSURANCE COMPANY
St. Paul, Minnesota
S i•I ST PAUL GUARDIAN INSURANCE COMPANY
' FYI YY■ St. Paul, Minnesota
ST PAUL MERCURY INSURANCE COMPANY
St. Paul, Minnesota
' Capital Stock Companies
ARKANSAS STATUTORY PERFORMANCE AND PAYMENT BOND
Class 2
' This Bond executed pursuant to the terms of Act 351 of the Arkansas State Legislature, as amended.
We, NORTHWEST EXCAVATION, A DIVISION OF NABHOLZ CONSTRUCTION CORPORATION, as Principal,
hereinafter called Principal, and ST. PAUL FIRE & MARINE INSURANCE COMPANY as Surety, hereinafter called Surety, are
held and firmly bound unto CITY OF FAYETTEVILLE as Obligee, hereinafter called Owner, in the amount of SIX HUNDRED
AND ONE THOUSAND AND SEVENTY FIVE DOLLARS AND FIFTY CENTS Dollars ($601,075.50), for the payment whereof
Principal and Surety bind themselves, their heirs, personal representatives, successors and assigns, jointly and severally, firmly by the
' presents.
Principal has by written agreement dated MAY 10, 1999 entered into a contract with Owner for HIGHWAY 16W
'WIDENING - WATER & SEWER RELOCATIONS which contract is by reference made a part hereof, and is hereinafter referred to
as the Contract.
The condition of this obligation is such that if the Principal shall faithfully perform the Contract and shall fully indemnify
'and save harmless the Owner from all cost and damage which Owner may suffer by reason of failure so to do and shall fully
reimburse and repay the Owner all outlay and expense which the Owner may incur in making good any such default, and, further,
that if the Principal shall pay all persons all indebtedness for labor or materials furnished or performed under said contract failing
'which such persons shall have a direct right of action against the Principal and Surety jointly and severally under this obligation,
subject to the Owner's priority, then this obligation shall be null and void; otherwise it shall remain in full force and effect.
No suit, action or proceeding shall be brought on this bond outside of the State of Arkansas. No suit, action or proceeding
'
shall be brought on this bond except by the Owner after twelve months for contracts subject to A.C.A § 18-44-503, otherwise six
months, from the date final payment is approved on the Contract, not shall any suit, action or proceeding be brought by the Owner
after two years from the date on which the final payment under the Contract falls due.
1 Any alterations which may be made in the terms of the Contract, or in the work to be done under it, or the giving by the
Owner of any extension of time for the performance of the Contract, or any other forbearance on the part of either the Owner or the
'Principal to the other shall not in any way release the Principal and the Surety or Sureties, or either or any of them, their heirs,
personal representatives, successors or assigns from their liability hereunder, notice to the Surety or Sureties of any such alteration,
extension or forbearance being hereby waived.
' In no event shall the aggregate liability of the Surety exceed the sum set out herein.
Executed on this I0TH day of MAY, 1999.
I
I
H
By
NORTHWEST EXCAVATION, A DIVISION OF NABHOLZ
CONSTRUCTION CORPORATION
Principal
I.
PAUL FIRE & MARINE INSURANCE COMPANY
' Surety
By
I
STEVEN C. RUSSELL, Anomey-in-fact
TheSt ul ST'. PAUL FIRE AND MARINE INSURANCE COMPANY CERTIFICATE OF
Surety 385 Washington Street, St. Paul, Minnesota 55102 AUTHORITY NO.
CERTIFIED For verification of the authenticity of this Power of Attorney, you may telephone toll free I -800-121-3880 and ask for
COPY NO. the Power of Auumcy Clerk. Please refer to the Certificate of Authority No. and the named individual(s).
F-15536 GENERAL POWER OF ATTORNEY - CERTIFIED COPY 2098941
(Original on File at Home Office of Company. See Certification.)
KNOW ALL MEN BY THESE PRESENTS: That St. Paul Fin and Marine Insurance Company, a corporation organized and existing under the laws of the State
of Minnesota, having its principal office in the City of St. Paul. Minnesota. does hereby constitute and appoint:
Steven C. Russell, Marylea I. Gazette, Robert C. Watkins, Christopher M. Triggs Jr.,
individually, Little Rock, Arkansas
1
its true and lawful attorney(s)-in-tact to execute, seal and deliver for and on its behalf as surety. any and all bonds and undertakings. recognizances, contracts of
indemnity and other writings obligatory in the nature thereof, which are or may be allowed, required or permitted by law, statute, role, regulation, contract or
otherwise,
NOT TO EXCEED IN PENALTY THE SUM OF TWENTY-FIVE MILLION DOLLARS($25,000,000)EACH
and the execution of all such msirument(s) in pursuance of these presents. shall be as binding upon said SL Paul Fire and Marine Insurance Company, as fully and
amply, to all intents and purposes, as if the same had been duly executed and acknowledged by its regularly elected officers at its principal office.
' This Power of Attorney is executed, and may be certified to mid may be revoked, pursuant to and by authority of Article V, -Section 6(C). of the By -Laws adopted by
the Shareholders of ST. PAUL. FIRE AND MARINE INSURANCE COMPANY at a meeting called and held on the 28th day of April, 1978, of which the following
is a true transcnpt of said Section 6 (C):
"The President or any Vice President. Assistant Vice President, Secretary or Service Center General Manager shall have power and authority
(1) 'to appoint Attorneys -in -fact, and to authonre them to execute on behalf of the Company, and attach the Seal of the Company thereto, bonds and
undertakings. recognirances. contracts of indemnity and other writings obligatory in the nature thereof, and
(2) To appoint special Attorneys -in -fact, who are hereby authorized to certify to copies of any power -of -attorney issued in pursuance of this section
and/or any of the By -Laws of the Company, and
(3) To remove, at any time, any such Attorney -in -tact or Special Attorney -in -fact and revoke the authority given him."
' Further, this Power of Attorney is signed and scaled by facsimile pursuant to resolution of the Board of Directors of said Company adopted at a meeting duly called and
held on the 5th day of May. 1959. of which the following is a true excerpt:
"Now therefore the signatures of such officers and the seal of the Company may be affixed to any such power of attorney or any certificate relating thereto by
facsimile, and any such power of attorney or certificate hearing such facsimile signatures or facsimile seal shall he valid and binding upon the Company and
any such power so executed and certified by facsimile signatures and facsimile seal shall be valid and binding upon the Company in the future with respect to
any bond or undertaking to which it is attached."
IN TESTIMONY WHEREOF. St. Paul Fire and Marine Insurance Company has caused this instrument to he signed and its corporate
J` xtaE S 4 seal to be affixed by its authorized officer, this Sth day of January, A.D. 1998.
' ���- ST. PAUL FIRE AND MARINE. INSURANCE COMPANY
Q.�--.-�
^
�o STATE OF NEW JERSEY l ss. ley
vxAN County' of Somerset 1J
BRIAN P. CORNY, Secretary
On this 10th day of March , 19 98 . before me came the individual who executed the preceding instrument, to fire
personally known, and being by me duly sworn, said that he/she is the therein described and authorized officer of St. Paul Fire and Marine Insurance Company;
that the sea] affixed to said instrument is the Corporate Seat of said Company: that the said Corporate Seal and his/her signature were duly affixed by order of the
Board of Directors of said Company.
IN TESTIMONY WHEREOF. I have hereunto set my hand and affixed my Official Seal, at the township of Bedminster, New Jersey. the
%aaer day and year first above written.
• a0ixar� �
3 0.�
�o k
1
Y.TNUA SMETI{ERS, Ndary Public
My Commission Expires December 16, 2001
CERTIFICATION
I, the undersigned officer of SL Paul Fire and Marine Insurance Company, do hereby certify that I have compared the foregoing copy of the Power of Attorney and
affidavit, and the copy of the Section of the By -Laws of said Company as set forth in said Power of Attorney, with the ORIGINALS ON FILE IN THE HOME
OFFICE OF SAID COMPANY, and that the same are correct transcripts thereof, and of the whole of the said originals, and that the said Power of Attorney has not
been revoke) and is now in full force and effect.
ape • '1b�1.`^"^' _ _ _
a` r
' ��- '•_ IN TESTIMONY µ'HEREOF. I have hereunto ua my hand this �
10th __day of May _.-_...-..19 99 . MARY E.STAWICKI.Secretary
' Only a certified copy of Power of Attorney bearing the Certificate of Authority No. punted in red on the upper right comer is binding. Photocopies, carbon copies or
other reproductions of this document are invalid and not binding upon the Company.
'ANY INSTRUMENT ISSUED IN EXCESS OF THE PENALTY AMOUNT STATED ABOVE IS TOTALLY VOID AND WITHOUT ANY VALIDITY.
29550 Rev. 7-98 Printed in U.S.A.
I
C
Li
n
1
n
I
I
1..
Thi> document has important legal consequences: consultation with an attorney is encouraged with
respect to its completion or modification.
6*111 ►`I1:: 1
GENERAL CONDITIONS
OF THE
CONSTRUCTION CONTRACT
Prepared by
Engineers Joint Contract Documents Committee
l
Issued and Published Jointly By
t
A
MERICAN
SOCIETY
A
`ouNc `
PROFESSIONAL ENGINEERS IN PRIVATE PRACTICE
A- practice division of the
NATIONAL SOCIETY OF PROFESSIONAL ENGINEERS
AMERICAN CONSULTING ENGINEERS COUNCIL
AMERICAN SOCIETY OF CIVIL ENGINEERS
CONSTRUCTION SPECIFICATIONS INSTITUTE
This document has been approved and endorsed by
The Associated General Contractors of America
These General Conditions have been prepared for use with the Owner -Contractor Agreements (No. 1910 -8 -A -I or
1910-8-A-2) (1990 Editions). Their provisions are interrelated and a change in one may necessitate a change in the
others. Comments concerning their usage are contained in the Commentary on Agreements for Engineering
Services and Contract Documents (No. 1910-9) (1986 Edition). For guidance in the preparation of Supplementary
Conditions, see Guide to the Preparation of Supplementary Conditions (No. 1910-17) (1990 Edition). When
bidding is involved, the Standard Form of Instructions to Bidders (No. 1910-12) (1990 Edition) may be used.
O 1990 National Society of Professional Engineers
1420 King Street, Alexandria, VA 22314
American Consulting Engineers Council
1015 15th Street, N.W., Washington, DC 20005
American Society of Civil Engineers
345 East 47th Street, New York, NY 10017
Construction Specifications Institute
601 Madison St., Alexandria, VA 22314
1
1
1
1
1
1
1
1
F
C
TABLE OF CONTENTS OF GENERAL CONDITIONS
' Article or Paragraph Page Article or Paragraph Page
Number & Title Number Number & Title .Vrtmber
I. DEFINITIONS ................................... 13 2.5-2.7 Before Starting Construction:
da 13 CONTRACTOR'S Responsibility to
' 1.1 Adden
1.2 Agreement 13 Report: Preliminary Schedules:
1.3 Application for Payment .............. 13 Delivery of Certificates of
1.4 Asbestos 13 Insurance .......................... IS
' 1.5 Bid ................................... 13 2.8 Preconstruction Conference ........... 15
1.6 Bidding Documents ................... 13 2.9 Initially Acceptable Schedules ......... 16
I.7 Bidding Requirements ................ 13
1.8 Bonds ................................ 13 3. CONTRACT DOCUMENTS: INTENT.
' 1.9 Change Order ........................13 AMENDING. REUSE•• 16
1.10 Contract Documents ...................3 3.1-3.2 Intent 16
1.11 Contract Price _ . 13 3.3 Reference to Standards and
' 1.12 Contract Times ....................... 13 Specifications of Technical Societies:
1.13 CONTRACTOR 13 Reporting and Resolving
1.14 defective 13 Discrepancies 16
Intent of Certain Terms or Adjectives . I7
1,15 Drawings .............................I) 3.4 .
...... 13 3.5 Amending Contract Documents ....... I7
' 1.16 Effective Date of the Agreement
1.17 ENGINEER .......................... 13 3.6 Supplementing Contract Documents ... 17
3.7 Reuse of Documents .................. 17
1:18 ENGINEER's Consultant ....... _.... 13
' 1.19 Field Order ........................... 13 4. AVAILABILITY OF LANDS: SUBSURFACE AND
1.20 General Requirements 14 PKY17I SICALCONDONS:REFERENCEPOINTS . 17
_ 1:21 Hazardous Waste 14 4.1 Availability of Lands .................. 17
1.22 Laws and Regulations: Laws or 4,2 Subsurface and Physical Conditions ... 17
' Regulations ........................ 14 4.2.1 Reports and Drawings 1.23 Liens.............................14 Po g ................ 17
4.2.2 Limited Reliance by CONTRACTOR
1.24 Milestone ............................. 14 Authorized: Technical Data .........IS
1.25 Notice of Award ...................... 14 4 2 3 Notice of Differing Subsurface or
' 1.26 Notice to Proceed . ......... .......... 14 ....
1.27 OWNER ............................14 GINE R's Review
............... 18
1.28 Partial Utilization ..................... 14 4.'-.5 PNGINEERtr ct Documents . t. Chan 18
4.2.5 Possible Contract Change IS
1.29 PCBs ................................. 14 4.'_.6 Possible Price and Times Adjustments . 18
1.30 Petroleum 14 4.3 Physical Conditions —Underground
1.31 Project 14 Facilities
1.32 Radioactive Materialdie • t � - .... • ... 18
.................. 14 4.3.1 Shown or Indicated ...................IS
I1.33 Resident Project Representative ...... 14 4 32 Not Shown or Indicated .............. 19
1.34 Samples .............................. 14 4.4 Reference Points ...........
1.35 Shop Drawings 14 19
B "' �' �' �"""� �""�" 4.5 Asbestos. PCBs, Petroleum, Hazardous
1.36 Specifications ......................... 14 Waste or Radioactive Material ...... 19
' 1.37 Subcontractor ........................ 14
1.38 Substantial Completion ............... 14 5. BONDS AND INSURANCE 20
1.39 Supplementary Conditions 14 """"""""-""
p �Y . • "" ...... 5.1-5.2 Pcrformarice. Payment and Other Bonds . 20
0
' 1.40 Supplier ..............................14
1.41 Underground Facilities 14 5.3 Licensed atesS.trof Insurancees and Insurers:
................
1.42 Unit Puce Work 14 Certificates of Insurance
...... 2
1.43 Work.................................1$ 5.4 C0NTRACIOR's Liability Insurance . 20
1.44 Work Change Directive ............... IS 5.5 OWNER's Liability Insurance ........ 21
1.45 Written Amendment 15 5.6 Property Insurance ......... .... '_1
"" 5.7 Boiler and Machinery or Additional
2. PRELIMINARY MATTERS ...................... 15 Property Insurance ................. 21
' 2.1 Delivery of Bonds .................... 15 5.8 Notice of Cancellation Provisions .....• 21
2.2 Copies of Documents IS 5.9 CONTRACTOR's Responsibdity for
2.3 Commencement of Contract Times: Deductible Amounts ................ 22
Notice to Proceed .................. IS 5.10 Other Special Insurance ............... 22
2.4 Starting the Work ..................... IS 5.11 Waiver of Rights ...................... 22
Article or Paragraph Page
Number & Title Number
5.12-5.13 Receipt and -Application of Insurance
Proceeds ........................... 22
5.14 Acceptance of Bonds and Insurance;
Option to Replace ................. 22
5.15 Partial Utilization —Property
Insurance .......................... 23
6. CONTRACTOR'S RESPONSIBILITIES ..........
6.1.6.21
Supervision and Superintendence ......
6.3-6.5,
Labor, Materials and Equipment ......
6.6
Progress Schedule ....................
6.7
Substitutes and "Or -Equal" Items;
CONTRACTOR's Expense;
Substitute Construction
Methods or Procedures;
ENGINEER's Evaluation ..........
6.8-6.11
Concerning Subcontractors, Suppliers
and Others; Waiver of Rights .......
6.12
1
Patent Fees and Royalties .............
6.13
I
Permits ...............................
6.14
Laws and Regulations ................
6.15
Taxes ................................
6.16
u
'v
Use of Premises ......................
6.l7.'
Site Cleanliness .......................
6.18
°
Safe Structural Loading ...............
6.19
NJ
Record Documents ...................
6.20
I
Safety and Protection .................
6.21
1
Safety Representative .................
6.22
Hazard Communication Programs .....
6.23
!
Emergencies ..........................
6.24
Shop Drawings and Samples ..........
6.25
Submittal Procedures:
CONTRACTOR's Review Prior to
Shop Drawing or Sample Submittal
6.26
Shop Drawing & Sample Submittals
Review by ENGINEER ............
6.27
Responsibility for Variation From
Contract Documents ................
6.28
!
Related Work Performed Prior to
ENGINEER's Review and Approval
of Required Submittals .............
6.29
Continuing the Work ..................
6.30
I
CONTRACTOR's General
Warranty and Guarantee ............
6.31-6.33
Indemnification .......................
6.34
Survival of Obligations ................
7. OTHER
WORK ..................................
7.1-7.31
Related Work at Site ..................
7.4
j
Coordination
8. OWNER'S RESPONSIBILITIES .................
8.1
Communications to Contractor ........
8.2
I
Replacement of ENGINEER ..........
8.3
Furnish Data and Pay Promptly When
Due ................................
8.4
Lands and Easements: Reports and
Tests
8.5
Insurance .............................
23
23
23
23
23
24
25
25
25
25
26
26
26
26
26
26
27
27
27
Article or Paragraph Page
Number & Title Number
8.6 Change Orders ....................... 29
8.7 Inspections, Tests and Approvals ...... 29
8.8 Stop or Suspend Work; Terminate
CONTRACTOR's Services .........
8.9 Limitations on OWNER's
Responsibilities .....................
8.10 Asbestos, PCBs, Petroleum, Hazardous
Waste or Radioactive Material ......
8.11 Evidence of Financial Arrangements . .
9. ENGINEER'S STATUS DURING
CONSTRUCTION ...............................
9.1
OWNER's Representative ............
9.2
Visits to Site ..........................
9.3
Project Representative ................
9.4
Clarifications and Interpretations ......
9.5
Authorized Variations in Work ........
9.6
Rejecting Defective Work .............
9.7-9.9
Shop Drawings, Change Orders and
Payments ..........................
9.10
Determinations for Unit Prices ........
.9.11-9.12
Decisions on Disputes; ENGINEER as
Initial Interpreter ...................
9.13
Limitations on ENGINEER's
Authority and Responsibilities ......
10. CHANGES IN THE WORK .....................
10.1 OWNER Ordered Change ............
10.2 Claim for Adjustment .................
10.3 Work Not Required by Contract
Documents .........................
10.4 Change Orders
10.5 Notification of Surety .................
27 11. CHANGE OF CONTRACT PRICE ..............
11.1-11.3 Contract Price; Claim for Adjustment;
27 Value of the Work ..................
11.4 Cost of the Work .....................
27 11.5 Exclusions to Cost of the Work .......
11.6 CONTRACTOR's Fee ................
11.7 Cost Records .........................
27 11.8 Cash Allowances .....................
28 11.9 Unit Price Work ......................
28 12. CHANGE OF CONTRACT TIMES ..............
28 12.1 Claim for Adjustment .................
28 12.2 Time of the Essence ..................
12.3 Delays Beyond CONTRACTOR's
29 Control ............................
29 12.4 Delays Beyond OWNER's and
CONTRACTOR's Control ..........
r
IT
PS
I
30 ,
30
30 '30
30
30 '
31
31
31
31
32
32
32 I
32
32
33
34
34
34
35
35
35
35
35
35 '
35
29 '
29 13. TESTS AND INSPECTIONS; CORRECTION,
29 REMOVAL OR ACCEPTANCE OF DEFECTIVE
WORK.......................................... 36 '
29 13.1 Notice of Defects ..................... 36
13.2 Access to the Work ................... 36
29 13.3 Tests and Inspections; Contractor's
29 Cooperation ........................ 36
2
I
' Article or Paragraph Page Article or Paragraph Page
Number & Title Number Number & Title Number
13.4 OWNER's Responsibilities: 14.12 Final Application for Payment ......... 40
1 Independent Testing Laboratory .... 36 14.13-14.14 Final Payment and Acceptance 40
13.5 CONT'RACTOR's Responsibilities ..... 36 14.15 Waiver of Claims .....................40
13.6-13.7 CoveringWork Prior to Inspection. 15. SUSPENSION OF WORK AND
Testing or Approval ................ 36
Work at ENGINEERS IJ.B-13.9 Uncovering 15.1 OWNER May Suspend Work ......... 40
RNER 36
13.10 OWNER May Stop the Work ......... 36 I5t15,4 OWNER May Terminate .............. 40
13.11 Correction or Removal of Defective 15.5 CONTRACTOR May Stop Work or
1 Work ............................... 37 Terminate .......................... 41
17.12 Correction Period .. 16. DISPUTE RESOLUTION ...................
13.13 Acceptance of Defective Work ........ 37... 41
1 13.14 OWNER May Correct Defective
Work ............................... 37 17. MISCELLANEOUS .............................42
17.1 Giving Notice ........................ 4'_
17.2 Computation of Times ................ 4'_
1 14. PAYMENTS TO CONTRACTOR AND 17.3 Notice of Claim ....................... 42
COMPLETION 37 17.4 Cumulative Remedies .................42
14.1 Schedule of Values .................... 37 17.5 Professional Fees and Court Costs
14.2 Application for Progress Payment ..... 38 Included ........................... 42
'• 14.3 CONTRACTOR's Warranty of Title ... 38
14.4-14.7 Review of Applications for EXHIBIT GC -A (Optional):
Progress Payments ................. 38 Dispute Resolution Agreement (Optional) ..... GC -Al
1 14.8-14.9 Substantial Completion ............... 39 16.1.16.6 Arbitration ....................GC -AI
14.10 Partial Utilization .....................39 16.7 Mediation ..................... GC -A2
-14.11 Final Inspection 39
1
I
I
LII
1 3
INDEX TO GENERAL CONDITIONS
Article or Paragraph
Number
Acceptance of —
Bonds and Insurance ................................5.14
defective Work ....................... 10.4.1,
13.13. 13.15
final payment.................................9.12.
14.15
insurance...........................................5.14
other Work, by CONTRACTOR ......................
7.3
Substitutes and "Or -Equal" Items ..................
6.7.1
Work by OWNER ........................
2.5. 6.30. 6.34
Access to the —
Lands. OWNER and CONTRACTOR
responsibilities .....................................
4.1
site, related work....................................7.2
Work . ..................................
13.2, 13.14, 14.9
Acts or Omissions—, Acts and Omissions —
CONTRACTOR ............................
6.9.1, 9.13.3
ENGINEER
6.20. 9.13.3
................................
OWNER .......................................
6.20. 8.9
Addenda —definition of (also see
definition of Specifications) ........... (1.6.
1.10. 6.19) I.
Additional Property Insurances .........................
5.7
Adjustments
Contract Price or Contract
Times ......... 1.5. 3.5, 4.1. 4.3.2. 4.5.2,
4.5.3. 9.4. 9.5,
10.2-10.4.
II. 12. 14.8, 15.1
progress schedule....................................6.6
Agreement— .
definition of..........................................1.2
All risk Insurance, policy form ........................56.2
Allowances. Cash .....................................
11.8
Amending Contract Documents .........................
3.5
Amendment. Written —
in general .... 1.10, 1.45. 3.5. 5.10. 5.12. 6.6.2. 6.8._. 6.19.
10.1. 10.4. 11.2_, 12.1,
13.12.'_. 14.7.2
Appeal., OWNER or CONTRACTOR
intent to ...................... 9.10. 9.11.
10.4. 16.2. 16.5
Application for Payment —
definition of..........................................1.3
ENGINEER's Responsibility .........................
9.9
final payment .................. 9.13.4, 9.13.5.
14.12-14.15
in general ......................._.8, 2.9.
5.6.4, 9.10, 15.5
progress payment ...............................4.1.
14.7
review of......................................14.4-14.7
Arbitration (Optional) .............................
16.1-16.6
Asbestos —
claims pursuant thereto .......................
4.5.2. 4.5.3
CONTRACTOR authorized to stop Work
........... 4.5.2
definition of ..........................................
1.4
OWNER responsibility for ....................
4.5.1. 8.10
possible price and times change .....................
4.5.2
Authorized. Variations in Work 3.6.
6.25, 6.27, 9.5
...........
Availability of Lands .... ............... ............
4.1. 8.4
Award. Notice of —defined ............................
1.25
Before Starting Construction ........................2.5-2.8
Bid —definition of ......................................
1.5
(1.1. 1.10,2_.3. 3.3, 4.2.6.4. 6.13. 11.4.3. 11.9.1)
'
Article or Paragraph
Number
Bidding Documents definition of ................ 1.6 (6.8.2)
Bidding Requirements —definitions of ...... 1.7 (1.1. 4.2.6.2)
Bonds —
acceptance of.......................................5.14
additional bonds ........................... 10.5. 11.4.5.9
Cost of the Work .................................. 11.5.4
definition of .......................................... 1.8
deliveryof ......................................2.1.5.1
final application for payment .................14.12-14.14
general ...............1.10. 5.1-5.3. 5.13, 9.13,10.5, 14.7.6
performance. Payment and Other .................5.1-5.2
Bonds and Insurance —in general ......................... 5
Builder's risk "all risk" policy form ................... 5.6.2
Cancellation Provisions. Insurance ........ 5.4.1 I.. 5.8. 5.15
Cash Allowances ...................................... 11.8
Certificate of Substantial Completion ......... 1.38. 6.30.2.3.
14.8, 14.10
Certificates of Inspection ................ 9.13.4. 13.5. 14.12
Certificates of Insurance .. 2.7, 5.3, 5.4.11, 5.4.13. 5.6.5. 5.8.
....................................... 5.14, 9.13.4. 14.12
Change in Contract Price —
Cash Allowances...................................11.8
claim for price adjustment ..... 4.1, 4.2.6. 4.5, 5.15, 6.8.2,
9.4. 9.5, 9.11, 10.2. 10.5, 11.2. 13.9,
13.13. 13.14, 15.1. 15.5
CONTRACIOR's fee ............................... 11.6
Cost of the Work
general......................................11.4-11.7
Exclusions to ....................................... 11.5
Cost Records.......................................11.7
in general .............. 1.19, 1.44. 9.11. 10.4.2, 10.4.3, II
Lump Sum Pricing ................................ 11.3.2
Notification of Surety ............................... 10.5
Scope of.......................................10.3-10.4
Testing and Inspection, Uncovering the Work ........ 13.9
Unit Price Work .................................... 11.9
Value of Work......................................11.3
Change in Contract Times —
Claim for times adjustment .... 4.1. 4.2.6, 4.5. 5.15, 6.8.2.
9.4, 9.5, 9.11, 10.2, 10.5. 12.1, 13.9. 13.13.
13.14, 14.7, 15.1. 15.5
Contractual time limits .............................. 12.2
Delays beyond CONTRACTOR's control ............ 12.3
Delays beyond OWNER's and CONTRACTOR's con-
trol...............................................12.4
Notification of surety ............................... 10.5
Scope of change ............................... 10.3-10.4
Change Orders—
Acceptance of Defective Work ..................... 13.13
Amending Contract Documents ...................... 3.5
Cash Allowances...................................11.8
Change of Contract Price ............................. I I
Change of Contract Times ............................ 12
Changes in the Work..................................10
CONTRACTOR's fee ............................... 11.6
Cost of the Work ...............................11.4-11.7
4 1
I
' Article or Paragraph Article or Paragraph
Number Number
Cost Records.............................11,7 general .................................... 6.2_. 6.9.2. 8.1
•' definition of .................................... .. 1.9 Hazard Communication Programs ...................6.22
emergencies ..._.._ ...............................623 Completion—
ENGINEER's responsibility .........9.8. 10.4. 11.2. 12.1 Final Application for Payment ...................... 14.12
e se:ution of....................................10.4 Final Inspection...................................14.11
' Indemnification ..................... 6.12. 6.16.6.31. 6.33 Final Payment and Acceptance ............... 14.13-14.14
Insurance. Bonds and 5.10. 5.13. 10.5 Partial Utilization .. .. 14.10
OWNER may terminate ........................ 15.2-15.4 Substantial Completion ................... 1.38. 14.8.14.9
' OWNER', Responsibility ....................... 8.6. 10.4 Waiver of Claims ................ 14.15
Phy'icul Conditions— Computation of Times ........................ .... 17.2.1-17.2.2
Subsurface and. .... 42 Concerning Subcontractors.
Underground Facilities .......................... 4.32 Suppliers and Others ............................6.8-6.11
' Record Documents ................................. 6.19 Conferences —
Scope of Change ..............................10.3-10,4 initially acceptable schedules ...........................9
Substitutes ................................... 6.7.3. 6.8.2 preconstruction......................................2.8
Unit Pnce Work....................................11.9 Conflict. Error. Ambiguity. Discrepancy—
' value of Work, covered by ............ ... ..... .. 11.3 CONTRACTOR to Report ..................... 2.5. 3.3.2
Changes in the Work ................................... 10 Construction, before starting by CONTRACTOR .... 2.5-2.7
Notification of surety ............................... 10.5 Construction Machinery. Equipment. etc. ............... 6.4
' OWNER'. and CONTRACTOR'. responsibilities . _,, 10.4 Continuing the Work .......... .: ....: .... . 6.29. 10.4
Right Io an adjustment ..............................10.2 Contract Documents—
...Scupe of change .. 10.3-10.4 Amending .. 3.5
Claims— Bonds...............................................5.1
' ,against CONTRACTOR .............................6.16 Cash Allowances ................................... 11.8
.against ENGINEER ...............................6.32 Change of Contract Price .. I I
'agamat OWNER ..... _........................ _... 6.32 Change of Contract Times .. 12
Change of Contract Price ..................9.4. 11_2 Changes in the Work ...........................10,4-10.5
Chance of Contract Times ..................... 9.4. 12.1 check and verify ........................................
CONTRACTOR'. 4. 7.1. 9.4. 9.5. 9.11. 10 2. 11.2. 11.9. Clarifications and Interpretations ....... 3.2, 3.6. 9.4. 9.11
C.I. 14.8. 15.1. 15.5. 17.3 definition of ........................................ 1.10
' CONTRACTOR'. Fee ..... _ . 1 L6 ENGINEER as initial interpreter of 9,11
CONTRACTOR' lability ..... 5.4. 6.12. 6 16. 6.31 ENGINEER as OWNER's representative ............9.1
Cast of the Work .. .. I L4. 11.5 general ................................................3
Decisions on Disputes ......... 9.11. 9.13 Insurance............................................5.3
Dispute Resolution .................................. 16.1 Intent..........:...............................'..3.1-3.4
Dispute Resolution Agreement .................. 16.1.16.6 minor variations in the Work .........................3.6
ENGINEER as initial interpreter ....... _........... 9.11 OWNER's responsibility to furnish data .. .. 8.3
Lump Sum Pricing ............................. 11.3.2 OWNER's responsibility to make
' Notic' of ............. ............................ 17.3 prompt payment........................ 8.3. 14.4. 14.13
UWNER's .. 9.4. rt.5. 9.1 I. 10.2. 112, 11.9. 12.1. precedence .. 3.1. 3.3.3
13.9. 11.13. 13.14. 17.) Record Documents.................................6.19
' O11'NER's Iiah,l,t. ............... _.................. 5.5 Reference to Standards and Specifications
OWNER man refuse to make payment ......... ... 14.7 of Technical Societies ..............................3.3
.
Professional Fees and Court Costs Included ......... 17.5 Related Work 72 ........................................
request for formal decision on ................... _.. 9.11 Reporting and Resolving Discrepancies ........... 2.5. 3.3
' Substitute items .. 6.7.12 Reuse of ........... 3.7
Time E.tem,on ... .. 12.1 Supplementing .......................................3.6
Time requirements ............................ 9.11. 12.1 Termination of ENGINEER's Employment ........... 8.2
L'nit Price Work ................................. 11.9.3 Unit Price Work .................................... 11.9
' Value of ............................................ 11.3 variations.................................3.6. 6.23. 6.27
11;uner af—on Final Payment ......... _..... 14.14. 14,15 Visits to Site. ENGINEER's ......................... 9.2
Work Chance Directive ................ _..... _.... 10.2 Contract Price—
' written notice required .................9.11. 11.2. 12.1 adjustment of ................ 3.5. 4.1 . 9.4. 10.3. 11.2.11.3
Clarifications and Interpretations .. 3.6.3. 9.4.9 11 Change of .. .. I1
Clean Site .... ........... ........ ........... . 6.17 Decision on Disputes .... .............. 9.11
Codes of Technical Soc,etc. Organization or definition of ........................................ 1.11
' Association .. _.................................. 3.3.3 Contract Times —
Commencement of Contract Times ..................... 2.3 adjustment of ...................... 3.5. 4.1. 9.4. 10.3. 12
Communications— Change of......................................12,1-12.4
5
Article or Paragraph
Number
Commencement of...................................2.3
definition of ........................................
1.12
CONTRACTOR —
Acceptance of Insurance ............................
5.14
LimitedIReliance on Technical Data Authorized
..... 4.2.2
Communications ...............................6.2
6.9.2
Continue Work................................6.29,
10.4
coordination and scheduling .........................
6.9.2
definition of ........................................
1.13
May Stop Work or Terminate .......................
15.5
provide 'site access to others ....................
7.2, 13.2
Safety and Protection ....... 4.3.1.2, 6.16, 6.18,
6.21-6.23.
7.2, 13.2
Shop Drawing and Sample Review Prior to Submittal . 6.25
Stop Work requirements ...........................
4.5.2
CONTRACTOR's—
Compensation..................................
11.1-11.2
Continuing Obligation ..............................
14.15
Defective Work .......................... 9.6,
13.1013.14
Duty tojcorrect defective Work .....................
13.11
Duty tolReport—
Changes in the Work caused by
Emergency.......................................6.23
Defects in Work of Others .........................
7.3
Differing conditions ..............................
4.2.3
Discrepancy in Documents ........... 2.5, 3.3.2.
6.14.2
Unded'ground Facilities not indicated ..............
4.3.2
Emergencies........................................6.23
Equipment and Machinery Rental. Cost
of the Work ...................................
11.4.5.3
Fee —Cost -Plus 11.4.5.6.
11.5.1, 11.6
.....................
General Warranty and Guarantee
6.30
Hazard Communication Programs ...................
6.22
Indemnification ...................... 6.12. 6.16, 6.31-6.33
Inspection of the Work .........................
7.3, 13.4.
1
Labor, Materials and Equipment ..................
6.3-6.5
Laws and Regulations. Compliance by .............
6.14.1
Liability Insurance...................................5.4
Notice of Intent to Appeal .....................
9.10. 10.4
obligation to perform and complete the Work ........
6.30
Patent Fees and Royalties, paid for by ...............
6.12
Performance and Other Bonds ........................
5.1
Permits obtained and paid for by ....................6.33
Progress Schedule ..... 2.6. 2.8. 2.9, 6.6. 6.29.
10.4. 15.2.1
Request' for formal decision on disputes .............
9.1 I
Responsibilities —
Changes in the Work ..............................
10.1
Concerning Subcontractors. Suppliers and Others . 6.8-
6.11
Continuing the Work ........................
6 29. 10.4
CONTRACTOR's expense ....................... 6.7.1
CONTRACTOR's General Warranty and Guaran-
tee..........:...:................................. 6.30
CONTRACTOR's review prior to Shop Drawing or Sam-
ple submittal.....................................6.25
)ordination of Work .............................. 6.9.2
Emergencies.....................................6.23
ENGINEER's evaluation. Substitutes
or 'Or -Equal' Items .......................... 6.7.3
Article or Paragraph
Number
For Acts and Omissions of Others ..... 6.9.1-6.9.2. 9.13
for deductible amounts, insurance ..................
5.9
general ................................. 6, 7.2,
7.3. 8.9
Hazardous Communication Programs .............
6.22
Indemnification ..............................6.31-6.33
Labor, Materials and Equipment ................6.3-6.5
Laws and Regulations ............................
6.14
Liability Insurance.................................5.4
Notice of variation from Contract Documents .....
6.27
Patent Fees and Royalties .........................
6.12
Permits...........................................6.13
Progress Schedule.................................6.6
Record Documents ...............................
6.19
related Work performed prior to ENGINEER's
approval of required submittals .................
6.28
safe structural loading ............................
6.18
Safety and Protection ................... 6.20.
7.2. 13.2
Safety Representative .............................
6.21
Scheduling the Work .............................
6.9.2
Shop Drawings and Samples ......................
6.24
Shop Drawings and Samples Review
by ENGINEER................................6.26
Site Cleanliness...................................6.17
Submittal Procedures ..............................
6.25
Substitute Construction Methods and '
Procedures....................................6.7.2
Substitutes and "Or -Equal" Items ................
6.7.1
Superintendence...................................6.2
Supervision........................................6.1
Survival of Obligations ............................6.3.4
Taxes............................................6.35
Tests and Inspections .............................
13.5
ToReport .........................................2.5
Use of Premises .................... 6.16-6.18.
6.30.2.4
Review Prior to Shop Drawing or Sample Submittal
.. 6.25
Right to adjustment for changes in the Work .........
10.2
right to claim .. 4. 7.1.9.4, 9.5. 9.11. 10.2. 11.2, 11.9,
12.1,
13.9, 14.8. 15.1.
15.5. 17.3
Safety and Protection .................6.2Q-6.22.
7.2. 13.2
Safety Representative ...............................
6.21
Shop Drawings and Samples Submittals .........
6.24-6.28
Special Consultants ...............................
11.4.4
Substitute Construction Methods and Procedures
:.... 6.7
Substitutes and "Or -Equal" Items. Expense .. 6.7.1,
6.7.2
Subcontractors. Suppliers and Others ............6.8-6.11
Supervision and Supenntendence ...........6.!.
6.2. 6.21
Taxes, Payment by ..................................6.15
Use of Premises................................6.16-6.18
Warranties and guarantees ......................6.30.
6.5
Warranty of Title ...................................
14.3
Written Notice Required —
CONTRACTOR stop Work or terminate ...........
15.5
Reports of Differing Subsurface and Physical
Condi-
tions.............................................4.2.3
Substantial Completion ...........................
14.8
CONTRACTORS—other
.................................7
Contractual Liability Insurance ......................
5.4.10
Contractual Time Limits ..............................
12.2
Coordination
I
I
I
I
J
I
Li
I
I
I
I
I
I
.1
L
G
I
Article or Paragraph
Number
CONTRACTOR's responsibility ............... _ ... 6.9.2
' Copies of Documents..................................._.2
Correction Period ....................................1312
Correction. Removal or Acceptance of
Defective Work
'
in general .............................104.1. 13.14 13.10-
Acceptance of Defective Work ........
Correction or Removal of Defective Work ..... 6.30. 13.11
I
Correction Period ....................... .. 13.12
OWNER May Correct Defective Work .. - .. 13.14
OWNER May Stop Work .......................... 13.10
Cost—
, of Tests and Inspections ............................. 13.4
Records ............................................ 11.7
Cost of the Work —
Bonds and insurance. additional ................. 11.4.5.9
Cash Discounts ........ . 11.4.2
CONTRACTOR's Fee .. 11.6
Employee Expenses ............................. 11.4.5.1
Exclusions to ............. _...... ..11.5
General .. .. 1 1.4-1 1.5
Home office and overhead expenses .. .. 11.5
Losses and damages ............................. 11.4.5.6
' Materials and equipment .......................... 11.4.2
Minor expenses .. 11.4.5.8
Kayroll costs on changes .......................... 11.4.1
performed by Subcontractors ...................... 11.4.3
Records ............................................ 11.7
Rentals of cons:ruction equipment and machinery . 11.4.5.3
Royalty payments, permits and license fees ...... I1,4,5,5
Site office and temporary facilities ......... .... .. 11.4.5.2_
Special Consultants. CONTRACTOR's .. 11.4.4
Supplemental .. 11.4.5
Taxes related to the Work ....................... 11.4.5.4
Tests and Inspection ................................ 13.4
Trade Discounts .. 11.4.2
Utilities, fuel and sanitary facilities ..... _........ i 1.4.5.7
Work after regular hours .......................... 11.4.1
' Covering Work ........ .. 13.6-13.7
Cumulative Remedies - .. 17.4-17.5
Cutting. fitting and patching ............................ 7.2
Data, to be furnished by OWNER ...................... 8.3
Day —definition of...................................17.2.2
Decisions on Disputes ..........................9.11. 9.12
defective —definition of ................................ 1.14
defective Work— Acceptance of ............................ .. 10.4.1. 13.13
Correction or Removal of ...................10.4.1. 13.11
Correction Period .................................. 13.12
in general ................................. 13. 14.7, 14.11
Observation by ENGINEER ......................... 9.2
OWNER May Stop Work .......................... 13.10
' Prompt Notice of Defects - . 13.1
Rejecting -.9.6
Uncovering the Work ............................... 13.8
Definitions ............................................... I
' Delays.................................4.1. 6.29. 12.3.12.4
Delivery of Bonds .............................. 2.1
Delivery of certificates of insurance ..................... 2.7
Article or Paragraph
Number
Determinations for Unit Prices ........................
9.10
Differing Subsurface or
Physical Conditions
Notice of ..........................................
4.2.3
ENGINEER's Review ..............'...............
4.2.4
Possible Contract Documents Change ...............
4.2.5
Possible Price and Times Adjustments ..............
4.2.6
Discrepancies -Reporting and Resolving .... 2.5.
3.3.2. 6.14.2
Dispute Resolution —
Agreement .....................................
16.1-16.6
Arbitration.....................................16.1-16.5
general...............................................16
Mediation..........................................16.6
Dispute Resolution Agreement ....................
16.1-16.6
Disputes. Decisions by ENGINEER ..............9.11-9.12
Documents —
Copies of ,,,,,.,,,,.
' '
Record....................:........................
6.19
Reuseof .............................................
3.7
Drawings —definition of ...............................
1.15
Easements .............................................
4.1
Effective date of Agreement —definition of .............
1.16
Emergencies..........................................6.23
ENGINEER —
as initial interpreter on disputes .................
9.11-9.12
definition of ........................................
1.17
Limitations on authority and
responsibilities .................................
9.13
Replacement of......................................8.2
Resident Project Representative ......................9.3
ENGINEER's Consultant —definition of ...............
1.18
ENGINEER's—
authority and responsibility, limitations on
........... 9.13
Authorized Variations in the Work ....................
9.5
Change Orders, responsibility for ..........
9.7. 10. I I . 12
Clarifications and Interpretations ...............
3.6.3. 9.4
Decisions on Disputes ..........................
9.11.9.12
defective Work. notice of ...........................
13.1
Evaluation of Substitute Items . . . . . . ................
6.7.3
Liability .......................................
6.32. 9.122
Notice Work is Acceptable .........................
14.13
Observations.................................6.30.2.
9.2
OWNER's Representative ...........................
9.1
Payments to the CONTRACTOR.
Responsibility for ..............................
9.9. 14
Recommendation of Payment .................
14.4, 14.13
Responsibilities —
Limitations on ...............................911913
Review of Reports on Differing Subsurface
and Physical Conditions ..........................
4.2.4
Shop Drawings and Samples. review
responsibility .....................................
6.26
Status During Construction —
authorized variations in the Work ........
... 9.5
Clarifications and Interpretations ...................
9.4
Decisions on Disputes ........................9.11-9.12
Determinations on Unit Price .... ......... .. 9.10
ENGINEER as Initial Interpreter .............9.11-9.12
ENGINEER's Responsibilities ................ 9.1-9.12
I
Article or Paragraph
Number
Limitations on ENGINEER's Authority
and
Responsibilities...................................9.13
OWNER's Representative .........................
9.1
Project Representative .............................
9.3
Rejecting Defective Work ..........................
9.6
Shop'lDrawings, Change Orders
and
Payments....................................9.7-9.9
Visits to Site......................................9.2
Unit Price Determinations ...........................
9.10
Visits to Site.........................................9.2
Written consent required .........................
7.2, 9.1
Equipment, Labor, Materials and ...................
6.3-6.5
Equipment rental. Cost of the Work
................ 11.4.5.3
Equivalent Materials and Equipment
.................... 6.7
Errorsor omissions...................................6.33
Evidence of Financial Arrangements
................... 8.11
Explorations of physical conditions
................... 4.2.1
Fee. CONTRACTOR's--Costs-Plus
................... 11.6
Field Order -
definition of........................................1.19
issued ey ENGINEER .........................
3.6.1. 9.5
Final Application for Payment ........................
14.12
Final Inspection......................................14.11
Final Pay'ment-
and Acceptance ..............................
14.13-14.14
Prior tot for cash allowances ........................
11.8
General Provisions ...............................17.3-17.4
General Requirements-
defintion of.........................................3.20
principal references to ..............2.6.
6.4, 6.6-6.7. 6.24
Giving Notice ........' :................................
17.1
Guarantee of Work -by
CONTRACTOR ..............................
6.30, 14.12
Hazard Communication Programs .....................
6.22
Hazardous Waste -
definition of ........................................
1.21
generalI
..............................................
4.5
OWNER's responsibility for ........................
8.10
Indemnification ........................
6.12. 6.16. 6.31-6.33
Initially Acceptable Schedules ..........................
2.9
Inspection -
Certificates of .........................9.13.4.
13.5, 14.12
Final ..............................................
14.11
Special,! required by ENGINEER
.................... 9.6
Tests and Approval ........................
8.7, 13.3-13.4
Insurance'
Acceptance of, by OWNER .........................5.34
Additional. required by changes
in the Work.................................11.4.5.9
Before starting the Work .............................
2.7
Bonds and -in general.................................5
Cancellation Provisions ..............................
5.8
Certificates of .. 2.7, 5, 5.3. 5.4.11,
5.4.13. 5.6.5, 5.8, 5.14.
.1
9.13.4, 14.12
completed operations ..............................
5.4.13
CONTRACTOR's Liability ...........................
5.4
CONTRACTOR's objection to coverage
............. 5.14
Contractual Liability ..............................
5.4.10
_ _ Article or Paragraph
Number
deductible amounts. CONTRACTOR's
responsibility ....................................
5.9
Final Application for Payment ......................
14.12
Licensed Insurers ....................................5.3
Notice requirements, material
changes..................................5.8,
10.5O
Option to Replace..................................3.14
other special insurances .............................
5.10
OWNER as fiduciaryfor insureds ..............
5.12-5.13
OWNER's Liability..................................5.5
OWNER's Responsibility ............................
8.5
Partial Utilization, Property Insurance ...............5.35
Property ........................................
5.6-5.10
Receipt and Application of Insurance Proceeds
.. 5.12-5.13
Special Insurance ...................................5.10
Waiver of Rights ....................................5.11
Intent of Contract Documents .......................3.1-3.4
Interpretations and Clarifications .................
3.6.3, 9.4
Investigations of physical conditions ....................4.2
Labor, Materials and Equipment ....................
6.3-6.5
Lands -
and Easements......................................8.4
Availability of...................................4.1,
8.4
Reports & Tests.....................................8.4
Laws and Regulations -Laws or Regulations
Bonds...........................................5.1-5.2
Changes in the Work ................................
10.4
Contract Documents .................................
3.1
CONTRACTOR's Responsibilities ...................
6.14
Correction Period, defective Work ..................
13.12
Cost of the Work, taxes .........................
11.4.5.4
definition of........................................1.22
general.............................................6.14
Indemnification................................6.31-6.33
Insurance............................................5.3
Precedence ....................................
3.1, 3.3.3
Reference to.......................................3.3.1
Safety and Protection ..........................
6.20, 13.2
Subcontractors. Suppliers and Others ............6.8-6.33
Tests and Inspections ...............................
13.5
Use of Premises....................................6.16
Visits to Site.........................................9.2
Liability Insurance—
CONTRACTOR's....................................
5.4
OWNER's...........................................
5.5
Licensed Sureties and Insurers .........................
5.3
Liens —
Application for Progress Payment ...................
14.2
Contractor's Warranty of Title .......................
14.3
Final Application for Payment ......................14.I2
definition of........................................1.23
Waiver of Claims
14.15
..................................
Limitations on ENGINEER's authority and
responsibilities.....................................9.13
Limited Reliance by CONTRACTOR Authorized
...... 4.2.2
Maintenance and Operating Manuals —
Final Application for Payment ......................
14.12
Manuals (of others)—
Precedence
.......................................3.3.3.)
I
I
I
H
I
I
I
I
I
I
I
I
I
I
I
H
I
Hi
I
' Article or Paragraph Article or Paragraph
Number Number
' Reference to in Contract Documents ................ 3.3.1 Inspections, tests and approvals ................. 8.7, 13.4
Materials and equipment— Liability Insurance.........................5.5
furnished by CONTRACTOR ........ ....... 6.3 Notice of Defects................................13.1
not incorporated in Work ............................ 14.2 Representative —During Construction.
' Materials or equipment —equivalent ..................... 6.7 ENGINEER's Status ............................ 9.1
Mediation (Optional)...............................16.7 Responsibilities —
Milestones —definition of ............................1.24 Asbestos. PCB's. Petroleum. Hazardous
Miscellaneous— Waste on Radioactive Material .................. 8.10
' Computation of Times ..........................17.2 Change Orders.............................8.6
....
Cumulative Remedies ............................... 17.4 Changes in the Work .............................. 10.1
Giving Notice...............................17,1 communications.................................8.1
Notice of Claim..................................17,3 C0NTRACTOR's responsibilities .................. 8.9
' Professional Fees and Court Costs Included .......... 17.5 evidence of financial arrangements ................ 8.11
Multi -prime contracts .................................... 7 inspections, tests and approvals .................... 8.7
Not Shown or Indicated .............................. 4.3.2 Insurance....................8.5
' Notice of- lands and easements ............................8.4
Acceptability of Project ............................ 14.13 prompt payment by ................................ 8.3
Award, definition of ................................. 1.25 replacement of ENGINEER ....................... 8.2
Claim...............................17.3 reports and tests.............................8.4
'Defects.......................... .................. 13.1 stop or suspend Work .................. 8.8. 13.10. 15.1
Differing Subsurface or Physical Conditions ..........4.2.3 terminate CONTRACTOR's services .......... 8.8. 15.2
Giving.....................................17.1 separate representative at site ........................93
Tests and Inspections .................... 13.3 independent testing .................................¶3.4
' Variation. Shop Drawing and Sample 6.27 use or occupancy of the
Notice to Proceed- Work..................................5.15. 14.10
definition of....................................1.26 written consent or approval
' giving of .................... 2.3 required .................... .......9.1.6.3. 11.4
Notification to Surely ........................... 10.5 written notice
Observations. by ENGINEER .................... 6.30. 9.2 required .......... 7.1, 9.4, 9.11. I 1.2. 11.9. 14.7, 15.4
Occupancy of the Work ................ 5.15. 6.30.2_.4. 14,10 PCBs-
' Omissions or acts by CONTRACTOR ...........6 .9,9.13 9.13 definition of . ... • . 1.29
"Open peril" policy form. Insurance ...................5.6.2 general .. 4.5
Option to Replace ....... _ ............................5.14 OWNER's responsibility for ........................ 8.10
"Or Equal" Items ....................................6,7 6.7 Partial Utilization-
' Other work ..................................... .. 7 definition of ........................................ 1.28
.......
Overtime Work -prohibition of 6.3 general ................................... 6.30.2.4, 14.10
OWNER- Property Insurance.................................5.15
' Acceptance of defective Work ...................... 13.13 Patent Fees and Royalties ............................. 6.12
appoint an ENGINEER ............... .. 8.2 Payment Bonds ..................................... 5.1-5.2
as fiduciary .................................... 5.12-5.13 Payments. Recommendation of ............. 14 4-14.7. 14.13
Availability of Lands. responsibility ................... 4.1 Payments to CONTRACTOR and Completion-
' definition of ....................................... ....... ........ .... 1.27 Application for Progress Payments ..................14.2
data, furnish .. .. 8.3 CONTRACTOR's Warranty of Title .................14.3
May Correct Detective Work ....................... 13.14 Final Application for Payment ......................14.12
' May refuse to make payment ........................ 14.7 Final Inspection ................................... 14.11
May Stop the Work................................13.10 Final Payment and Acceptance ............... 14.13-14.14
may suspend work. general...........................................8.3. 14
terminate .......................8.8. 13.10. 15.1.15.4 Partial Utilization .................................. 14,10
' Payment, make prompt ...................8.3. 14,4. 14.13 Retainage...........................................14.2
performance of other Work ............ ... .. 7.1 Review of Applications for Progress
permits and licenses. requirements .................. 6.13 Payments..................................14,4-14,7
purchased insurance requirements ............... 5.6-5.10 prompt payment.....................................8.3
' OWNER's— Schedule of Values .................................. 14.1
Acceptance of the Work ......................... 6.30.2.5 Substantial Completion ......................... 14.8-14.9
Change Orders. obligation to Waiver of Claims .................................. 14.15
' execute .................................... 8.6. 10.4 when payments due 14.4. 14.13
Communications .. .. 8.1 withholding payment .. .. 14.7
Coordination of the Work ............................ 7,4 Performance Bonds .. .. .. 5.1-5.2
Disputes. request for decision ....................... 9.11 Permits...............................................6.13
1 9
Article or
Paragraph
Number
Petroleum— -
definition of ........................................
1.30
general..............................................4.5
OWNER's responsibility for ........................
8.10
Physical Conditions—
Drawings of, in or relating to .....................
4.2.1.2
ENGINEER's review ..............................
4.2.4
existing structures..................................4.2.2
general...........................................4.2.1.2
Subsurface and.......................................4.2
Underground Facilities ...............................
4.3
Possible Contract Documents Change ...............
4.2.5
Possible Price and Times Adjustments ..............
4.2.6
Reports and Drawings ..............................
4.2.1
Notice of Differing Subsurface or ...................4,2.3
..................
4.2.3
Subsurface and
......................................4.2
Subsurface Conditions ............................
4.2.1.1
Technical Data, Limited Reliance by
CONTRACTOR Authorized ....................
4.2.2
Underground Facilities—
general..........................................4.3
Not Shown or Indicated .......................
4.3.2
,Protection of ...............................
4.3, 6.20
'Shown or Indicated ............................
4.3.1
Technical Data .....................................4.2.2
Precongtruction Conference ............................7.8
Preliminary Matters ......................................2
PreliminarySchedules..................................2.6
Premises. Use of.................................6.16-6.18
Price, Change of Contract ...............................
II
Price, Contract —definition of ..........................
1.11
Progress Payment, Applications for ....................
14.2
Progress payment—retainage ..........................
14.2
Progress; schedule. CONTRACTOR's .....2.6.2_.8,
2.9. 6.6.
6.29.
10.4, 15.2.1
Project definition.of....................................3!
Project Representative—
ENGINEER's Status During Construction
............ 9.3
Project Representative. Resident
—definition of ......................................
1.33
prompt payment by OWNER ...........................8.3
Property Insurance
Additional...........................................5.7
general..........................................5.6.5.10
Partial Utilization ...........................5.15.
14.10.2
receipt and application of
- proceeds ..................................
5.12-5.13
Protection. Safety and .......................
6.20-6.21, 13.2
Punch list............................................14.11
Radioactive Material—
definition...........................................
1.32
general..............................................4.5
OWNER's responsibility for ........................
8.10
Recommendation of Payment ..............
14.4. 14.5, 14.13
Record Documents .............................6.19.
14.12
Records, procedures for maintaining ....................
2.8
Reference Points.......................................4.4
R e to Standards and Specifications
of Technical Societies................................13
i
i
10
Article or Paragraph
Number
Regulations. Laws and (or) ............................6.14
Rejecting Defective Work ...............................
9.6
Related Work —
at Site...........................................7.1-7.3
Performed prior to Shop Drawings
and Samples submittals review ..................
6.28
Remedies, cumulative ............................
17.4, 17.5
Removal or Correction of
Defective Work .................... 1...............
13.11
rental agreements, OWNER approval
required ......................................
11.4.5.3
replacement of ENGINEER, by OWNER ..............
8.2
Reporting and Resolving Discrepancies ....
2.5, 3.3.2, 6.14.2
Reports —
and Drawings......................................4.2_I
and Tests. OWNER's responsibility ..................
8.4
Resident Project Representative —
definition of ........................................
1.33
provision for.........................................9.3
Resident Superintendent, CONTRACTOR's
............. 6.2
Responsibilities—
CONTRACTOR's-in general ...........................
6
ENGINEER's-in general ...............................
9
Limitations on....................................9.13
OWNER's-in general..................................8
Retainage.............................................
14.2
Reuse of Documents...................................3.7
Review by CONTRACTOR: Shop Drawings
and Samples Prior to Submittal ......................
6.25
Review of Applications for Progress
Payments ......................................
14.4-14.7
Right to an adjustment ................................
10.2
Rights of Way..........................................4.1
Royalties. Patent Fees and .............................
6.12
Safe Structural Loading ...............................
6.18
Safety —
and Protection .......4.3.2. 6.16. 6.18, 6.20-6.21,
7.2. 13.2
general .........................................6.20-6.23
Representative. CONTRACTOR's ...................
6.21
Samples —
definition of ........................................
1.34
general ........................................
6.24-6.28
Review by CONTRACTOR .........................
6.25
Review by ENGINEER .......................
6.26, 6.27
related Work........................................6.28
submittal of.......................................6.24.2
submittal procedures................................6.25
Schedule of progress ..... 2.6, 2.8-2.9. 6.6,
6.29, 10.4, 15.2.1
Schedule of Shop Drawing and Sample
Submittals ....................... 2.6.
2.8-2.9.6.24-6.28
Schedule of Values ........................2.6.
2.8-2.9, 14.1
Schedules —
Adherence to.....................................15.2.1
Adjusting............................................6.6
Change of Contract Times ..........................
10.4
Initially Acceptable ...............................2.8-2.9
Preliminary..........................................2.6
Scope of Changes ....... .... ................
10.3-10.4
Subsurface Conditions ..............................
4.2.1.1
I
I
I
I
I
I
I
I
I
I
I
I
I
I
CJ
I
Article or Paragraph
Number
Article or Paragraph
Number
' Shop Drawings— Substitute Items .................................. 6.7.1.2
and Samples. general ...........................6,24-6.28 Subsurface and Physical Conditions —
Change Orders & Applications for Drawings of. in or relating to .....................4,2,1.2
Payments, and ...............................9.7-9.9 ENGINEER's Review .............................4.2.4
' definition of 1.35 general
ENGINEER's approval of ......................... 3.6.2 Limited Reliance by CONTRACTOR
ENGINEER's responsibility Authorized....................................4.2.2
for review ............................... 9.7. 6.24-6.28 Notice of Differing Subsurface or
' related Work........................................6.28 Physical Conditions................................4.2.3
review procedures ......................... _.8. 6._44.28 Physical Conditions ................................. 4.2.1.2_
submittal required ................................. 6.24.1 Possible Contract Documents Change ................. 4.2.5
Submittal Procedures ............................... 6.25 Possible Price and Times Adjustments ................ 4.2.6
use to approve substitutions ........................6.7.3 Reports and Drawings ................................ 4.2_. 1
Shown or Indicated ........ ......... ........... 4.3.1 Subsurface and . . 4.22
Site Access ....................................... 7.2. 13.2 Subsurface Conditions at the Site ................. 4.2.1.1
' Site Cleanliness ....................................... 6.17 Technical Data ..................................... 4._'.2_
Site. Visits to— Supervision —
by ENGINEER................................9.2. 13.2 CONTRkSORsresponsibility ...................... 6.1
by others .........................................13.2 OWNER shall not supervise ......................... 8.9
' "Special causes of loss'• policy form, insurance ....... 5.6.2 ENGINEER shall not supervise ............... 9._. 9.13.2_
Specifications— Superintendence.......................................6.2
definition of........................................1.36 Superintendent. CONTRACTOR's resident ........... 6.2
' of Technical Societies, reference to .. 3.3.1 Supplemental costs • 11.4.5
precedence .......................................3.3.3 Supplementary Conditions—
Staridards and Specifications of Technical definition of ........................................1.39
Societies..........................................3.3 principal reference to .... 1.10. 1.18. 2.2_. 2.7. 4.2_. 4.3. 5.1.
' Stating Construction. Before ....................... 2.5-2.8 5.3. 5.4. 5.6-5.9. 5.11.6.8. 6.13. 7.4. 8.11. 9.3. 9.10
Starting the Work........................................4 Supplementing Contract Documents .................... 3.6
Stop or Suspend Work— Supplier —
by CONTRACTOR ................................. 15.5 definition of ........................................ 1.40
' by OWNER ............................. 8.8. 13.10. 15.1 principal references to .................. 3.7. 6.5. 6.8-6.11.
Storage of materials and equipment ................. 4.1. 7.2 6.20. 6.2_4. 9.13. 14.12
Structural Loading, Safety ............................. 6.18 Waiver of Rights....................................6.11
' Subcontractor — ... Surety —
Concerning ...................................... 6.8-6.II consent to final payment ..................... 14.1.. 14.14
definition of .................................. .. 1.37 ENGINEER has no duty to ......................... 9.13
delays..............................................12.3 Notification of ........................... 10.1. 10.5. 15.2
' waiver of rights ..................................... 6.11 qualification of ......... 5.1-5.3
Subcontractors —in general ........................6.8-6.11 Survival of Obligations ................................ 6.34
Subcontracts —required provisions ........ 5.11. 6.11. 11.4.3 Suspend Work. OWNER May .................. 13.10. 15.1
Submittals— Suspension of Work and Termination— .................. IS
' Applications for Payment ........................... 14.2 CONTRACTOR May Stop Work or
Maintenance and Operation Manuals ............... 14.12 Terminate ........................................ 15.5
Procedures ......................................... 6.25 OWNER May Suspend Work ....................... IS.)
Progress Schedules 2.6. 2.9 OWNER May Terminate .......................15.2-15.4
Samples ....................................... 6.24-6.28 Taxes -Payment by CONTRACTOR .................... 6.15
Schedule of Values ............................. 2.6. 14.1 Technical Data
- Schedule of Shop Drawings and Limited Reliance by CONTRACTOR ............... 4.2.2
' Samples Submissions .................... 2.6. 2.8-2.9 Possible Price and Times Adjustments .............. 4.2.6
Shop Drawings ................................. 6.24-6.28 Reports of Differing Subsurface and
Substantial Completion— Physical Conditions .............................. 4.2.3
certification of ........................ 6.30.2.3. 14.8-14.9 Temporary construction facilities ........................4-I
definition of ........................................ 1.38 Termination —
Substitute Construction Methods or Procedures ....... 6.7.2 by CONTRACTOR ................................. 15.5
• Substitutes and 'Or Equal'' Items ...................... 6.7 by OWNER ............................... 8.8. 15.1-15.4
C0NTRACTOR's Expense ...................... 6.7.1.3 of ENGINEER's employment ........................ 8.2
ENGINEER's Evaluation .. ... 6.7,3 Suspension of Work-in general ........................IS
• "Or -Equal ........................................ 6.7.1 Terms and Adjectives..................................3.4
Substitute Construction Methods of Procedures ..... 6.7.2 Tests and Inspections —
II
I
Article
or Paragraph
_ Number
Access� to the Work, by others ..................
.. 13.2
CONTRACTOR's responsibilities ....................
13.5
costofI..............................................
13.4
covering Work prior to .........................13.6-13.7
Laws and Regulations (or) ..........................
13.5
Noticebf Defects ...................................
13.1
OWNER May Stop Work ..........................
13.10
OWNER's independent testing ......................
13.4
special: required by ENGINEER .....................
9.6
timely notice required ...............................
13.4
Uncovering the Work, at ENGINEER's
request....................................13.8-13.9
Times—
Adjusting............................................6.6
Change!of Contract...................................12
Adjusting............................................6.6
Computation of .....................................
17.2
Contract Times definition of .......................
1.12
day..) .....................:.......................17.72
Milestones...........................................12
Requirements—
appeals
....16
clarifications, claims and
,disputes .............................9.11.
11.2, 12
commencement of contract times ...................
2.3
to I
preconstrucuon conference .........................
2.8
schedules..................................2.6.
2.9, 6.6
starting the Work..................................2.4
Title. Warranty of.....................................14.3
Uncovering Work ................................
13.8-13.9
Underground Facilities. Physical Conditions —
definition of ............. ....................
1.41
Not Shown or Indicated ............................
4.3.2
protection of...................................4.3.
6.20
Shown or indicated................................4.3.1
Unit Price Work—
claims............................................11.9.3
definition of.........................................1.42
general .................................. 11.9.
14.1. 14.5
Unit Prices—
generall...........................................
11.3.1
Determination for ...................................
9.10
Use of Premises ........................ 6.16,
6.18, 6.30.2.4
Utility owners ...................... 6.13, 6.20.
1
7.1-7.3. 13.2
Article or Paragraph
Number
Utilization. Partial ............... 1.28, 5.15,
6.30, 2.4, 14.10
Value of the Work .....................................
11.3
Values, Schedule of ....................... 2.6,
2.8-2.9, 14.1
Variations in Work —Minor
Authorized ................................
6.25, 6.27, 9.5
Visits of Site —by ENGINEER .........................
9.2
Waiver of Claims -on Final
Payment ........................... ................
14.15
Waiver of Rights by insured parties ...............
5.11, 6.11
Warranty and Guarantee, General —by
CONTRACTOR....................................6.30
Warranty of Title, CONTRACTOR's ...................
14.3
Work —
Access to...........................................13.2
byothers ..............................................
7
Changes in the.......................................10
Continuing the . ......................................
6.29
CONTRACTOR May Stop Work
or Te'rr finate ''
' —'
........ IS.5
Coordination of......................................7.4
Cost of the ......................................
11.4-11.5
definition of........................................1.43
neglected by CONTRACTOR ......................
13.14
other Work ............................................
7
OWNER May Stop Work ..........................
13.10
OWNER May Suspend Work .................
13.10. 15.1
Related, Work at Site ..............................7.1-7.3
Starting the..........................................2.4
Stopping by CONTRACTOR ........................
15.5
Stopping by OWNER ..........................15.1-15.4
.Variation and deviation authorized,
minor...........................................3.6
Work Change Directive —
claims pursuant to..................................10.2
definition of ........................................
1.44
principal references to ....................3.5.3.
10.1.10.2
Written Amendment —
definition of ........................................
1.45
principal references to ... 1.10, 3.5, 5.10,5.12.66'
6.8.2.
6.19. 10.1. 10.4, 11.2, 12.1,
13.12.2. 14.7.2
Written Clarifications and
Interpretations ...........................3.6.3.
9.4, 9.11
Written Notice Required —
by CONTRACTOR ........ 7.1. 9.10-9.11,
10.4, 11.2, 12.1
by OWNER ....................9.10-9.1I,
10.4, 11.2. 13.14
I
I
I
I
I
I
I
r
r
I
I
I
I
I
12
I
I
11
H
I
I
I
I
I
I
I
I
I
I
I
GENERAL CONDITIONS
ARTICLE I —DEFINITIONS Additions SC 1
Wherever used in these General Conditions or in the other
Contract Documents the following terms have the meanings
indicated which arc applicable to both the singular and plural
thereof:
I.I. Addenda —Written or graphic instruments issued prior
to the opening of Bids which clarify, correct or change the
Bidding Requirements or the Contract Documents.
1.2. Agreement —The written contract between OWNER
and CONTRACTOR covering the Work to be performed; other
Contract Documents are attached to the Agreement and made
a part thereof as provided therein.
1.3. Application for Payment —The form accepted by EN-
GINEER which is to be used by CONTRACTOR in requesting
progress or final payments and which is to be accompanied by
such' supporting documentation as is required by the Contract
Documents.
1`.a. Asbestos —Any material that contains more than one
percent asbestos and is friable or is releasing asbestos fibers
into the air above current action levels established by the
United States Occupational Safety and Health Administration.
1.5. Bid —The offer or proposal of the bidder submitted on
the prescribed form setting forth the prices for the Work to be
performed.
1.6. Bidding Documents —The advertisement or invitation
to Bid, instructions to bidders. the Bid form, and the proposed
Contract Documents (including all Addenda issued prior to
receipt of Bids).
1.7. Bidding Requirements —The advertisement or invita-
tion to Bid, instructions to bidders. and the Bid form.
1.8. Bonds —Performance and Payment bonds and other
instruments of security.
1.9. Change Order —A document recommended by ENGI-
NEER, which is signed by CONTRACTOR and OWNER and
authorizes an addition, deletion or revision in the Work, or an
adjustment in the Contract Price or the Contract Times. issued
on or after the Effective Date of the Agreement.
1.10. Contract Documents —The Agreement. Addenda
(which pertain to the Contract Documents). C0NTRACTOR's
Bid (including documentation accompanying the Bid and any
post Bid documentation submitted prior to the Notice of
Award) when attached as an exhibit to the Agreement, the
Notice to Proceed, the Bonds. these General Conditions, the
Supplementary Conditions, the Specifications and the Draw-
ings as the same are more specifically identified in the Agree-
ment. together with all Written Amendments. Change Orders.
Work Change Directives. Field Orders and ENGINEER's
written interpretations and clarifications issued pursuant to
paragraphs 3.5. 3.6.1. and 3.6.3 on or after the Effective Date
of the Agreement. Shop Drawing submittals approved pursu-
ant to paragraphs 6.26 and 6.27 and the reports and drawings
referred to in paragraphs 4.2.1.1 and 4.2.22.22 are not Contract
Documents,
III. Contract Price —The moneys payable by OWNER to
CONTRACTOR for completion of the Work in accordance
with the Contract Documents as stated in the Agreement
(subject to the provisions of paragraph 11.9.1 in the case of
Unit Price Work),
1.12. Contract Times —The numbers of days or the dates
stated in the Agreement: (i) to achieve Substantial Completion.
and (ii) to complete the Work so that it is ready for final
payment as evidenced by ENGINEER's written recommenda-
tion of final payment in accordance with paragraph 14.13.
1.13. CONTRACTOR —The person, firm or corporation
with whom OWNER has entered into the Agreement.
1.14. defective —An adjective which when modifying the
word Work refers to Work that is unsatisfactory. faulty or
deficient in that it does not conform to the Contract Docu-
ments, or does not meet the requirements of any inspection.
reference standard. test or approval referred to in the
Contract Documents, or has been damaged prior to ENGI.
NEER's recommendation of final payment (unless responsi-
bility for the protection thereof has been assumed by OWNER
at Substantial Completion in accordance with paragraph 14.8
or 14.10).
1.15. Drawings —The drawings which show the scope.
extent and character of the Work to be furnished and per-
formed by CONTRACTOR and which have been prepared or
approved by ENGINEER and are referred to in the Contract
Documents. Shop drawings are not Drawings as so defined.
1.16. Effective Date of the Agreement —The date indicated
in the Agreement on which it becomes effective, but if no such
date is indicated it means the date on which the Agreement is
signed and delivered by the last of the two panes to sign and
deliver.
1.17. ENGINEER -The person. firm or corporation named
as such in the Agreement.
1.18. ENGINEER's Consultant —A person, fire or corpo-
ration having a contract with ENGINEER to furnish services
as ENGINEER's independent professional associate or con -
sultan( with respect to the Project and who is identified as such
in the Supplementary Conditions.
1.19. Field Order —A written order issued by ENGINEER
which orders minor changes in the Work in accordance with
paragraph 9.5 but which does not involve a change in the
Contract Pace or the Contract Times.
' I3
I
1.20. General Requirements —Sections of Division I of the
Specifications.
1.21. I Hazardous Waste The term Hazardous Waste shall
have the meaning provided in Section 1004 of the Solid Waste
Disposal Act (42 USC Section 6903) as amended from time to
time.
1.22. Laws and Regulations: Laws or Regulations —Any
and all applicable laws, rules, regulations, ordinances, codes
and orders of any and all governmental bodies, agencies.
authorities and courts having jurisdiction.
1.23. Liens —Liens, charges, security interests or encum-
brances upon real property or personal property.
1.24. Milestone —A principal event specified in the Con-
tract Documents relating to an intermediate completion date or
time prior to Substantial Completion of all the Work.
1.25. Notice ofAward—The written notice by OWNER to
the apparent successful bidder stating that upon compliance by
the apparent successful bidder with the conditions precedent
enumerated therein, within the time specified. OWNER will
sign and ,deliver the Agreement.
1.26. Notice to Proceed —A written notice given by OWNER
to CONTRACTOR (with a copy to ENGINEER) fixing the
date on which the Contract Times will commence to run and on
which CONTRACTOR shall start to perform CONTRAC-
TOR's obligations under the Contract Documents.
1.27. OWNER —The public body or authority, corpora-
tion. association- firm or person with whom CONTRACTOR
has entered into the Agreement and for whom the Work is to be
provided.
1.28. Partial Utilization —Use by OWNER of a substan-
tially completed part of the Work for the purpose for which it is
intended (or a related purpose) prior to Substantial Completion
of all the Work. .
29. 'PCBs —Polychlorinated biphenyls
1.30. Petroleum —Petroleum, including crude oil or any
fraction thereof which is liquid at standard conditions of
temperature and pressure (60 degrees Fahrenheit and 14.7
pounds per square inch absolute), such as oil. petroleum. fuel
oil, oil sludge, oil refuse. gasoline, kerosene, and oil mixed with
other non -Hazardous Wastes and crude oils.
1.31. I Project —The total construction of which the Work to
be provided under the Contract Documents may be the whole.
or a part as indicated elsewhere in the Contract Documents.
1.32. I Radioactive Material —Source. special nuclear, or
byproduct material as defined by the Atomic Energy Act of
1954 (42 USC Section 2011 et seq.) as amended from time to
time. 1
1.33. Resident Project Representative— The authorized
representative of ENGINEER who may be assigned to the site
or any part thereof.
1.34. Samples—Physicalexamplesofmaterials. equipment.
or workmanship that are representative of some portion of the
Work and which establish the standards by which such portion
of the Work will be judged.
1.35. Shop Drawings —All drawings. diagrams. illustra-
tions, schedules and other data or information which are
specifically prepared or assembled by or for CONTRACTOR
and submitted by CONTRACTOR to illustrate some portion of
the Work.
1.36. Specifications —Those portions of the Contract Doc-
uments consisting of written technical descriptions of materi-
als, equipment. construction systems. standards and workman-
ship as applied to the Work and certain administrative details
applicable thereto.
1.37. Subcontractor —An individual, firm or corporation
having a direct contract with CONTRACTOR or with any
other Subcontractor for the performance of a part of the Work
at the site. :
1.38. Substantial Completion —The Work (or a specified
pan thereof) has progressed to the point where, in the opinion
of ENGINEER as evidenced by ENGINEER's definitive
certificate of Substantial Completion, it is sufficiently com-
plete. in accordance with the Contract Documents, so that the
Work (or specified part) can be utilized for the purposes for
which it is intended: or if no such certificate is issued, when the
Work is complete and ready for final payment as evidenced by
ENGINEER's written recommendation of final payment in
accordance with paragraph 14.13. The terms "substantially
complete" and "substantially completed" as applied to all or
part of the Work refer to Substantial Completion thereof.
1.39. Supplementan• Conditions —The part of the Contract
Documents which amends or supplements these General Con-
ditions.
1.40. Supplier —A manufacturer, fabricator, supplier, dis-
tributor. materialman or vendor having a direct contract with
CONTRACTOR or with any Subcontractor to furnish materi-
als or equipment to be incorporated in the Work by CON-
TRACTOR or any Subcontractor.
• 1.41. Underground Facilities —All pipelines, conduits, ducts,
cables, wires, manholes, vaults, tanks, tunnels or other such
facilities or attachments. and any encasements containing such
facilities which have been installed underground to furnish any
of the following services or materials: electricity, gases, steam,
liquid petroleum products, telephone or other communica-
tions, cable television, sewage and drainage removal, traffic or
other control systems or water.
1.42. Unit Price Work —Work to be paid for on the basis of
unit prices.
I
I
I
[1
I
I
I
H
I
I
I
H
H
14
I
I
I
I
I
L
I
Li
I
I
u
1.43. Work —The entire completed construction or the var-
ious separately identifiable pans thereof required to be fur-
nished under the Contract Documents. Work includes and is
the result of performing or furnishing labor and furnishing and
incorporating materials and equipment into the construction.
and performing or furnishing services and furnishing docu-
ments, all as required by the Contract Documents,
1.44, Work Change Directive —A written directive to CON-
TRACTOR. issued on or after the Effective Date of the
Agreement and signed by OWNER and recommended by
ENGINEER. ordering an addition, deletion or revision in the
Work, or responding to differing or unforeseen physical condi-
tions under which the Work is to be performed as provided in
paragraph 4.2 or 4.3 or to emergencies under paragraph 6.23. A
Work Change Directive will not change the Contract Price or
the Contract Times, but is evidence that the panics expect that
the change directed or documented by a Work Change Direc-
tive will be incorporated in a subsequently issued Change
Order following negotiations by the parties as to its effect, if
any, on the Contract Price or Contract Times as provided in
paragraph 10._.
1.45. Written Amendment —A written amendment of the
Contract Documents, signed by OWNER and CONTRACTOR
on or after the Effective Date of the Agreement and normally
dealing with the nonengineering or nontechnical rather than
strictly construction -related aspects of the Contract Docu-
ments.
ARTICLE 2 —PRELIMINARY MATTERS
IDelivery of Bonds:
L
I
I
L
L
L
2_.I. When CONTRACTOR delivers the executed Agree-
ments to OWNER. CONTRACTOR shall also deliver to
OWNER such Bonds as CONTRACTOR may be required to
furnish in accordance with paragraph s.l.
Copies of Documents:
Addition see SC2.2
2.2. OWNER shall furnish to CONTRACTOR up to ten
copies (unless otherwise specified in the Supplementary Con-
ditions) of the Contract Documents as are reasonably neces-
sary for the execution of (he Work. Additional copies will be
furnished, upon request. at the cost of reproduction.
Commencement of Contact Timer; Notice to Proceed'
2.3. The Contract Times will commence to run on the thirti-
eth day after the Effective Date of the Agreement. or. if a Notice
to Proceed is given, on the day indicated in the Notice to Proceed.
A Notice to Proceed may oc given at any time within thirty days
after the Effective Date of the Agreement. In no event will the
Contract Times commence to run later than the sixtieth day after
the day of Bid opening or the thirtieth day after the Effective Date
of the Agreement. whichever date is earlier.
Starting the Work:
2.4. CONTRACTOR shall start to perform the Work on the
date when the Contract Times commence to run. but no Work
shall be done at the site prior to the date on which the Contract
Times commence to run.
Before Starting Conravction:
2.5. Before undertaking each part of the Work. CON-
TRACTOR shall carefully study and compare the Contract
Documents and check and verify pertinent figures shown
thereon and all applicable field measurements. CONTRAC-
TOR shall promptly report in writing to ENGINEER any
conflict, error, ambiguity or discrepancy which CONTRAC-
TOR may discover and shall obtain a written interpretation or
clarification from ENGINEER before proceeding with any
Work affected thereby: however. CONTRACTOR shall not be
liable to OWNER or ENGINEER for failure to report any
conflict, error, ambiguity or discrepancy in the Contract Doc-
umcnts. unless CONTRACTOR knew or reasonably should
have known thereof.
2.6. Within ten days after the Effective Date of the Agree-
ment (unless otherwise specified in the General Requirements).
CONTRACTOR shall submit to ENGINEER for review:
2.6.1. a preliminary progress schedule indicating the
times (numbers of days or dates) for starting and completing
the various stages of the Work, including any Milestones
specified in the Contract Documents:
2.6.2. a preliminary schedule of Shop Drawing and Sam -
plc submittals which will list each required submittal and the
times for submitting, reviewing and processing such submit-
tal:
2.6.3. a preliminary schedule of values for all of the
Work which will include quantities and prices of items
aggregating the Contract Price and will subdivide the Work
into component pans in sufficient detail to serve as the basis
for progress payments during construction. Such prices will
include an appropriate amount of overhead and profit appli-
cable to each item of Work.
2.7. Before any Work at the site is started. CONTRACTOR
and OWNER shall each deliver to the other, with copies to
each additional insured identified in the Supplementary Condi-
tions. certificates of insurance (and other evidence of insurance
which either of them or any additional insured may reasonably
request) which CONTRACTOR and OWNER respectively arc
required to purchase and maintain in accordance with para-
graphs5.4.5.6and 5.7. Addition see Sc 2.7
Prrconrtnzction Conference:
2.8.
Within
twenty days after
the
Corte c: Tir..e: start to
run,
but
before
any Work at the
site
is started, a conference
' 15
I
attended by CONTRACTOR. ENGINEER and others as ap-
propriate will be held to establish a working understanding
among thle parties as to the -Work and to discuss the schedules
referred to in paragraph 2.6, procedures for handling Shop
Drawings and other submittals, processing Applications for
Payment'and maintaining required records.
lwrtially Acceptable Schedules:
2.9. Unless otherwise provided in the Contract Docu-
ments, at;least ten days before submission of the first Applica-
tion for Payment a conference attended by CONTRACTOR.
ENGINEER and others as appropriate will be held to review
for acceptability to ENGINEER as provided below the sched-
ules submitted in accordance with paragraph 2.6. CONTRAC-
TOR shall have an additional ten days to make corrections and
adjustments and to complete and resubmit the schedules. No
progress payment shall be made to CONTRACTOR until the
schedulesare submitted to and acceptable to ENGINEER as
provided below. The progress schedule will be acceptable to
ENGINEER as providing an orderly progression of the Work
to completion within any specified Milestones and the Contract
Times,.but such acceptance will neither impose on ENGI-
NEER responsibility for the sequencing, scheduling or progress
of the Wo,ic nor interfere with or relieve CONTRACTOR from
C0NTRACTOR's full responsibility therefor. CONTRACTOR's
schedule` Hof Shop Drawing and Sample submissions will be
acceptable to ENGINEER as providing a workable arrange-
ment for reviewing and processing the required submittals.
C0NTRACTOR's schedule of values will be acceptable to
ENGINEER as to form and substance.
I -
ARTICLE 3 —CONTRACT DOCUMENTS: INTENT,
I AMENDING. REUSE
Intent:
3.1. The Contract Documents comprise the entire agree-
ment between OWNER and CONTRACTOR concerning the
Work. The Contract Documents are complementary; what is
called for by one is as binding as if called for by all. The
Contract Documents will be construed in accordance with the
law of theiplace of the Project.
3.2. It lis the intent of the Contract Documents to describe
a functionally complete Project (or part thereof) to be con-
structed in accordance with the Contract Documents. Any
Work, materials or equipment that may reasonably be inferred
from the Contract Documents or from prevailing custom or
trade usage as being required to produce the intended result
will be furnished and performed whether or not specifically
called for.IWhen words or phrases which have a well- known
technical or construction industry or trade meaning are used to
describe Work, materials or equipment, such•words or phrases
shall be interpreted in accordance with that meaning. Clarifi-
cations and interpretations of the Contract Documents shall be
issued by ENGINEER as provided in paragraph 9.4.
3.3. Reference to Standards and Specifications of Technical
Societies; Reporting and Resolving Discrepancies:
3.3.1. Reference to standards, specifications, manuals or
codes of any technical society. organization or association,
or to the Laws or Regulations of any governmental authority,
whether such reference be specific or by implication, shall
mean the latest standard, specification, manual, code or
Laws or Regulations in effect at the time of opening of Bids
(or, on the Effective Date of the Agreement if there were no
Bids), except as may be otherwise specifically stated in the
Contract Documents.
3.3.2. If, during the performance of the Work. CON-
TRACTOR discovers any conflict, error, ambiguity or dis-
crepancy within the Contract Documents or between the
Contract Documents and any provision of any such Law or
Regulation applicable to the performance of the Work or of
any such standard. specification, manual or code or of any
instruction of any Supplier referred to in paragraph 6.5,
CONTRACTOR shall report it to ENGINEER in writing at
once, and, CONTRACTOR shall not proceed with the Work
affected thereby (except in an emergency as authorized by
paragraph 6.23) until an amendment or supplement to the
Contract Documents has been issued by one of the methods
indicated in paragraph 3.5 or 3.6; provided, however, that
CONTRACTOR shall not be liable to OWNER or ENGI-
NEER for failure to report any such conflict, error, ambigu-
ity or discrepancy unless CONTRACTOR knew or reason-
ably should have known thereof.
3.3.3. Except as otherwise specifically stated in the
Contract Documents or as may be provided by amendment
or supplement thereto issued by one of the methods indi-
cated in paragraph 3.5 or 3.6. the provisions of the Contract
Documents shall take precedence in resolving any conflict.
error, ambiguity or discrepancy between the provisions of
the Contract Documents and:
I
I
Li
I
I
I
:4
L
3.3.3.1. the provisions of any such standard, speci-
fication, manual, code or instruction (whether or not
specifically incorporated by reference in the Contract
Documents); or
3.3.3.2. the provisions of any such Laws or Regu-
lations
applicable to the performance of the Work
(unless such an interpretation of the provisions of the
Contract Documents would result in violation of such
Law or Regulation).
No provision of any such standard, specification, manual,
code or instruction shall be effective to change the duties and
responsibiliticsofOWNER. CONTRACTOR or ENGINEER.
or any of their subcontractors, consultants, agents, or em-
ployees from those set forth in the Contract Documents, nor
shall it be effective to assign to OWNER. ENGINEER or
any of ENGINEER's Consultants, agents or employees any
duty or authority to supervise or direct the furnishing or
16 '
F
I
I
I
I
I
I
I
I
I
I
I
performance of the Work or any duty or authority to under-
take responsibility inconsistent with the provisions of para-
graph 9.13 or any other provision of the Contract Docu-
ments.
3.4. Whenever in the Contract Documents the terms "as
ordered. ' "as directed; ' ''as required." "as allowed." "as
approved" or terms of like effect or import are used, or the
adjectives "reasonable." ''suitable. "'acceptable. 'proper"
or "satisfactory" or adjectives of like effect or import arc
used to describe a requirement. direction, review or judg-
ment of ENGINEER as to the Work, it is intended that such
requirement. direction, review or judgment will be solely to
evaluate. in general, the completed Work for compliance
with the requirements of and information in the Contract
Documents and conformance with the design concept of the
completed Project as a functioning whole as shown or
indicated in the Contract Documents (unless there is a
specific statement indicating otherwise). The use of any such
term or adjective shall not be effective to assign to ENGI-
NEER any duty or authority to supervise or direct the
furnishing or performance of the Work or any duty or
authority to undertake responsibility contrary to the provi-
sions of paragraph 9.13 or any other provision of the
Contract Documents.
r5
Amending and Supplementing Contract Documents:
3.5. The Contract Documents may be amended to provide
for additions, deletions and revisions in tic Work or to modify
the terms and conditions thereof in one or more of the following
ways:
3.3.1. a formal Written Amendment.
3.5.2. a Change Order (pursuant to paragraph 10.4), or
3.5.3.
a Work
Change
Directive (pursuant to
paragraph
10.1).
3.6. In addition. the requirements of the Contract Docu-
ments may be supplemented. and minor variations and devia-
tions in the Work may be authorized. in one or more of the
following ways:
3.6.1. a Field Order (pursuant to paragraph 9.5),
3.6.2.
ENGINEER's approval of a
Shop
Drawing or
Sample
(pursuant to paragraphs 6.26 and
6.27).
or
3.6.3. ENGINEER's written interpretation or clarifica-
tion (pursuant to paragraph 9.4).
Reuse of Doeunnenn:
3.7. CONTRACTOR, and any Subcontractor or Supplier
or other person or organization performing or furnishing any of
the Work under a direct or indirect contract with OWNER (i)
shall not have or acquire any title to or ownership rights in any
of the Drawings. Specifications or other documents (or copies
of any thereof) prepared by or bearing the seal of ENGINEER
or ENGINEER's Consultant, and (ii) shall not reuse any of
such Drawings, Specifications. other documents or copies on
extensions of the Project or any other project without written
consent of OWNER and ENGINEER and specific written
verification or adaption by ENGINEER.
ARTICLE 4 —AVAILABILITY OF LANDS;
SUBSURFACE AND PHYSICAL
CONDITIONS: REFERENCE POINTS
A.mlabil y of lards:
4.1. OWNER shall furnish, as indicated in the Contract
Documents, the lands upon which the Work is to be performed.
rights -of -way and easements for access thereto, and such other
lands which am designated for the use of CONTRACTOR.
Upon reasonable written request. OWN ER shall furnish CON-
TRACTOR with a correct statement of record legal title and
legal description of the lands upon which the Work is to be
performed and OWNER's interest therein as necessary for
giving notice of or filing a mechanic's lien against such lands in
accordance with applicable Laws and Regulations. OWNER
shall identify any encumbrances or restrictions not of general
application but specifically related to use of lands so furnished
with which CONTRACTOR will have to comply in performing
the Work. Easements for permanent structures or permanent
changes in existing facilities will be obtained and paid for by
OWNER, unless otherwise provided in (he Contract Docu-
ments. If CONTRACTOR and OWNER arc unable to agree on
entitlement to or the amount or extent of any adjustments in the
Contract Price or the Contract Times as a result of any delay in
OWNER's furnishing these lands, rights -of -way or easements.
CONTRACTOR may make a claim therefor as provided in
Articles II and 12. CONTRACTOR shall provide for all
additional lands and access thereto that may be required for
temporary construction facilities or storage of materials and
equipment.
4.2. Subsurface and Physical Condidowr:
4.2.1. Reports and Drawings: Reference is made to the
Supplementary Conditions for identification of:
4.2.1.1. Subsurface Conditions: Those reports of explo-
rations and tests of subsurface conditions at or contiguous to
the site that have been utilized by ENGINEER in preparing
the Contract Documents: and
4.2.1.2. Physical Conditions: Those drawings of physical
conditions in or relating to existing surface or subsurface
structure::-' or c;.:::iet ous to the site (except Underground
Facilities) that have been utilized by ENGINEER in prepar-
ing the Contract Documents.
I
17
L
4.2.2. Limited Reliance by CONTRACTOR Authorized:
Technical Data: CONTRACTOR may rely upon the general
accuracyof the "technical data" contained in such reports and
drawings; but such reports and drawings are not Contract
Documents. Such "technical data" is identified in the Supple-
mentary Conditions. Except for such reliance on such "tech-
nical data;" CONTRACTOR may not rely upon or make any
claim against OWNER. ENGINEER or any of ENGINEER's
Consultants with respect to:
I
4.2.2:1. the completeness of such reports and drawings
for CONTRACTOR's purposes, including, but not limited
to, any aspects of the means, methods, techniques. se-
quences and procedures of construction to be employed by
CONTRACTOR and safety precautions and programs inci-
dent thereto, or
1
4.2.2,2. other data, interpretations, opinions and infor-
mation contained in such reports or shown or indicated in
such drawings, or
4.2.2,3. any CONTRACTOR interpretation of or conclu-
sion drawn from any "technical data" or any such data.
interpRtations, opinions or information.
4.2.3.'' Notice of Differing Subsurface or Physical Condi-
lions: If CONTRACTOR believes that any subsurface or
physical "condition at or contiguous to the site that is uncovered
or revealed either:
4.2.3.11. is of such a nature as to establish that any
"technical data" on which CONTRACTOR is entitled to
rely as provided in paragraphs 4.2.1 and 4.2.2 is materially
inaccurate, or
i
4.2.3.2. is of such a nature as to require a change in the
Contract Documents, or
4.2.3.3. differs materially from that shown or indicated in
the Contract Documents, or
4.2.3.4. is of an unusual nature, and differs materially
from conditions ordinarily encountered and generally recog-
nized as'inherent in work of the character provided for in the
Contract Documents; then
CONTRACTOR shall, promptly after becoming aware thereof
and before further disturbing conditions affected thereby or
performing any Work in connection therewith (except in an
emergency as permitted by paragraph 6.23). notify OWNER
and ENGINEER in writing about such condition. CONTRAC-
TOR shall not further disturb such conditions or perform any
Work in connection therewith (except as aforesaid) until re-
ceipt of written order to do so.
4.2.4. ENGINEER's Review: ENGINEER will promptly
review the pertinent conditions, determine the necessity of
OWNER's.obtaining additional exploration or tests with re-
spect thereto and advise OWNER in writing (with a copy to
CONTRACTOR) of ENGINEER's findings and conclusions.
4.2.5. Possible Contract Documents Change: If ENGI-
NEER concludes that a change in the Contract Documents is
required as a result of a condition that meets one or more of the
categories in paragraph 4.2.3., a Work Change Directive or a
Change Order will be issued as provided in Article 10 to reflect
and document the consequences of such change.
4.2.6. Possible Price and Times Adjustments: An equitable
adjustment in the Contract Price or in the Contract Times, or
both, will be allowed to the extent that the existence of such
uncovered or revealed condition causes an increase or de-
crease in CONTRACTOR's cost of. or time required for
performance of, the Work; subject, however, to the following:
4.2.6.1. such condition must meet any one or more of the
categories described in paragraphs 4.2.3.1 through 4.2.3.4,
inclusive;
4.2.6.2. a change in the Contract Documents pursuant to
paragraph 4.2.5 will not be an automatic authorization of nor
a condition precedent to entitlement to any such adjustment;
4.2.6.3. with respect to Work that is paid for on a Unit
Price Basis, any adjustment in Contract Price will be subject
to the provisions of paragraphs 9.10 and 11.9; and
4.2.6.4. CONTRACTOR shall not be entitled to any
adjustment in the Contract Price or Times if;
4.2.6.4.1. CONTRACTOR knew of the existence of
such conditions at the time CONTRACTOR made a final
commitment to OWNER in respect of Contract Price and
Contract Times by the submission of a bid or becoming
bound under a negotiated contract; or
4.2.6.4.2. the existence of such condition could rea-
sonably have been discovcred or revealed as a result of
any examination, investigation, exploration, test or study
of the site and contiguous arras required by the Bidding
Requirements or Contract Documents to be conducted by
or for CONTRACTOR prior to CONTRACTOR's making
such final commitment; or
I
I
I
I
I
I
Li
I
4.2.6.4.3. CONTRACTOR failed to give the written
notice within the time and as required by paragraph 4.2.3.
If OWNER and CONTRACTOR are unable to agree on
entitlement to or as to the amount or length of any such
equitable adjustment in the Contract Price or Contract Times,
a claim may be made therefor as provided in Articles II and 12.
However, OWNER, ENGINEER and ENGINEER's Consult-
ants shall not be liable to CONTRACTOR for any claims,
costs, losses or damages sustained by CONTRACTOR on or in
connection with any other project or anticipated project.
4.3. Physical Condiaions—Undergrvund Faciities:
4.3.1. Shown or Indicated: The information and data shown
or indicated in the Contract Documents with respect to existing
Underground Facilities at or contiguous to the site is based on
I
I
I
I
18
I
I
I
I
I
C
I
I
I
C
I
I
I
I
I
I
I
El
information and data furnished to OWNER or ENGINEER by
the owners of such Underground Facilities or by others. Unless it
is otherwise expressly provided in the Supplementary Conditions:
4.3.1.1. OWNER and ENGINEER shall not be respon-
sible for the accuracy or completeness of any such informa-
tion or data: and
4.3.1.2_. The cost of all of the following will be included in
the Contract Price and CONTRACTOR shall have full respon-
sibility for. (i) reviewing and checking all such information and
data. (ii) locating all Underground Facilities shown or indicated
in the Contract Documents. (iii) coordination of the Work with
the owners of such Underground Facilities during construction.
and (iv) the safety and protection of all such Underground
Facilities as provided in paragraph 6.20 and repairing any
damage thereto resulting from the Work.
4.3.2. Not Shown or Indicated: If an Underground Facility
is uncovered or revealed at or contiguous to the site which was
not shown or indicated in the Contract Documents. CON-
TRACTOR shall, promptly after becoming aware thereof and
before further disturbing conditions affected thereby or per-
forming any Work in connection therewith (except in an
emergency as required by paragraph 6.23). identify the owner
of such Underground Facility and give written notice to that
owner and to OWNER and ENGINEER. ENGINEER will
promptly review the Underground Facility and determine the
extent, if any. to which a change is required in the Contract
Documents to reflect and document the consequences of the
existence of the Underground Facility. If ENGINEER con-
cludes that a change in the Contract Documents is required. a
Work Change Directive or a Change Order will be issued as
provided in Article 10 to reflect and document such conse-
quences. During such time. CONTRACTOR shall be respon-
sible for the safety and protection of such Underground Facility
as provided in paragraph 6.20. CONTRACTOR shall be al-
lowed an increase in the Contract Price or an extension of the
Contract Times, or both, to the extent that they are attributable
to the existence of any Underground Facility that was not
shown or indicated in the Contract Documents and that CON-
TRACTOR did not know of and could not reasonably have
been expected to be aware of or to have anticipated. If
OWNER and CONTRACTOR are unable to agree on entitle-
ment to or the amount or length of any such adjustment in
Contract Price or Contract Times. CONTRACTOR may make
a claim therefor as provided in Articles II and 12. However,
OWNER. ENGINEER and ENGINEER's Consultants shall
not be liable to CONTRACTOR for any claims, costs, losses or
damages incurred or sustained by CONTRACTOR on or in
connection with any other project or anticipated project.
Reference Points:
4.4. OWNER shall provide engineering surveys to estab-
lish reference points for construction which in ENGINEER's
judgment are necessary to enable CONTRACTOR to proceed
with the Work. CONTRACTOR shall be responsible for laving
out the Work, shall protect and preserve the established
reference points and shall make no changes or relocations
without the prior written approval of OWNER. CONTRAC.
TOR shall report to ENGINEER whenever any reference
point is lost or destroyed or requires relocation because of
necessary changes in grades or locations, and shall be respon-
sible for the accurate replacement or relocation of such refer-
ence points by professionally qualified personnel.
4.5. Asbestos. PCBs, Prtrroleum. Hazardous Waste or Radio-
active Material:
4.5.1. OWNER shall be responsible for any Asbestos.
PCBs. Petroleum, Hazardous Waste or Radioactive Material
uncovered or revealed at the site which was not shown or
indicated in Drawings or Specifications or identified in the
Contract Documents to be within the scope of the Work and
which may present a substantial danger to persons or property
exposed thereto in connection with the Work at the site.
OWNER shall not be responsible for any such materials
brought to the site by CONTRACTOR. Subcontractor. Suppli-
ers or anyone else for whom CONTRACTOR is responsible.
4.5.2. CONTRACTOR shall immediately: ti) stop all
Work in connection with such hazardous condition and in
any area affected thereby (except in an emergency as re-.
quired by paragraph 6.23). and (ii) notify OWNER and
ENGINEER (and thereafter confirm such notice in writing).
OWNER shall promptly consult with ENGINEER concern-
ing the necessity for OWNER to retain a qualified expert to
evaluate such hazardous condition or take corrective action,
if any. CONTRACTOR shall not be required to resume Work
in connection with such hazardous condition or in any such
affected area until after OWNER has obtained any required
permits related thereto and delivered to CONTRACTOR
special written notice: (i) specifying that such condition and
any affected area is or has been rendered safe for the
resumption of Work. or (ii) specifying any special cor:litions
under which such Work may be resumed safely. If OWNER
and CONTRACTOR cannot agree as to entitlement to or the
amount or extent of an adjustment. if any. in Contract Price
or Contract Times as a result of such Work stoppage or such
special conditions under which Work is agreed by CON-
TRACTOR to be resumed, either party may make a claim
therefor as provided in Articles II and 12.
4.5.3. If after receipt of such special written notice
CONTRACTOR does not agree to resume such Work based
on a reasonable belief it is unsafe, or does not agree to
resume such Work under such special conditions, then
OWNER may order such portion of the Work that is in
connection with such hazardous condition or in such af-
fected area to be deleted from the Work. If OWNER and
CONTRACTOR cannot agree as to entitlement to or the
amount or extent of an adjustment, if any. in Contract Price
or Contract Times as a result of deleting such portion of the
Work, then tither party may make a claim therefor as
provided in Articles II and 12. OWNER may have such
deleted portion of the Work performed by OWNER's own
forces or others in accordance with Article 7.
4.5.4. To the fullest extent permitted by Laws and Reg-
ulations. OWNER shall indemnify and hold harmless CON-
TRACTOR. Subcontractors, ENGINEER, ENGINEER's
' 19
LJ
Consultants and the officers, directors, employees, agents.
other consultants and subcontractors of each and any of
them from and against all claims, costs, losses and damages
arising out of or resulting from such hazardous condition,
provided that: (i) any such claim, cost, loss or damage is
attributable to bodily injury, sickness, disease or death, or to
injury to or destruction of tangible property (other than the
Work itself), including the loss of use resulting therefrom.
and (ii) nothing in this subparagraph 4.5.4 shall obligate
OWNER to indemnify any person or entity from and against
the consequences of that person's or entity's own negli-
gence. 1
4.5.5.The provisions of paragraphs 4.2 and 4.3 are not
intended to apply to Asbestos, PCBs, Petroleum, Hazardous
Waste or' Radioactive Material uncovered or revealed at the
site. I
ARTICLES —BONDS AND INSURANCE
Additions see SC -5.1.1 and 5.1.2
Payment and Other Bonds:
5.1. CONTRACTOR shall furnish Performance and Pay-
ment Bonds, each in an amount at least equal to the Contract
Price as security for the faithful performance and payment of
all CONTRACTOR's obligations under the Contract Docu-
ments. These Bonds shall remain in effect at least until one
year after the date when final payment becomes due, except as
provided otherwise by Laws or Regulations or by the Contract
Documents. CONTRACTOR shall also furnish such other
Bonds as are required by the Supplementary Conditions. All
Bonds shall be in the form prescribed by the Contract Docu-
ments except as provided otherwise by Laws or Regulations.
and shall be executed by such sureties as are named in the
current list Hof "Companies Holding Certificates of Authority as
Acceptable' Sureties on Federal Bonds and as Acceptable
Reinsuring Companies" as published in Circular 570 (amended)
by the Audit Staff, Bureau of. Government Financial Opera-
tions, U.S. Treasury Department. All Bonds signed by an
agent must be accompanied by a certified copy of such agent's
authority to act.
1
5.2. If tIhe.surety on any Bond furnished by CONTRAC-
TOR is declared a bankrupt or becomes insolvent or its right to
do business is terminated in any state where any part of the
Project is located or it ceases to meet the requirements of
paragraph 5.1. CONTRACTOR shall within ten days thereafter
substitute Another Bond and surety, both of which must be
acceptable to OWNER.
Repladement see SC 5.2
5.3. licensed Sureties and Insurers; Cerrfftcates of Insurance:
5.3.1. All Bonds and insurance required by the Contract
Documents to be purchased and maintained by OWNER or
CONTRACTOR shall be obtained from surety or insurance
companies that arc duly licensed or authorized in the juris-
diction in which the project is located to issue Bonds or
insurance policies for the limits and coverages so required.
Such surety and insurance companies shall also meet such
additional requirements and qualifications as may be pro-
vided in the Supplementary Conditions.
Additions see Sc 5.3.1
5.3.2. CONTRACTOR shall deliver to OWNER, with
copies to each additional insured identified in the Supple-
mentary Conditions, certificates of insurance (and other
evidence of insurance requested by OWNER or any other
additional insured) which CONTRACTOR is required to
purchase and maintain in accordance with paragraph 5.4.
OWNER shall deliver to CONTRACTOR, with copies to
each additional insured identified in the Supplementary
Conditions, certificates of insurance (and other evidence of
insurance requested by CONTRACTOR or any other addi-
tional insured) which OWNER is required to purchase and
maintain in accordance with paragraphs 5.6 and 5.7 hereof.
Revision see SC 5.3.2
CONTRACTOR's Liability Insurance:
5.4. CONTRACTOR shall purchase and maintain such
liability and other insurance as is appropriate for the Work
being performed and furnished and as will provide protection
from claims set forth below which may arise out of or result
from CONTRACTOR's performance and furnishing of the
Work and CONTRACTOR's other obligations under the Con-
tract Documents, whether it is to be performed or furnished by
CONTRACTOR, any Subcontractor or Supplier, or by anyone
directly or indirectly employed by any of them to perform or
furnish any of the Work, or by anyone for whose acts any of
them may be liable:
5.4.1. claims under workers' compensation, disability
benefits and other similar employee benefit acts;
5.4.2. claims for damages because of bodily injury, oc-
cupational sickness or disease, or death of CONTRAC-
TOR's employees;
5.4.3. claims for damages because of bodily injury, sick-
ness or disease, or death of any person other than CON-
TRACTOR's employees;
5.4.4. claims for damages insured by customary personal
injury liability coverage which are sustained: (i) by any
person as a result of an offense directly or indirectly related
to the employment of such person by CONTRACTOR, or (ii)
by any other person for any other reason;
5.4.5. claims for damages, other than to the Work itself.
because of injury to or destruction of tangible property
wherever located, including loss of use resulting therefrom;
and
5.4.6. claims for damages because of bodily injury or
death of any person or property damage arising out of the
ownership, maintenance or use of any motor vehicle.
I
I
[1
I
I
I
I
I
I
I
I
11
I
C
I
I
L
C
H
I
I
L
G
Ii
I
I
ru
II
J
LI
The policies of insurance so required by this paragraph 5.4 to
be purchased and maintained shall:
5.4.7. with respect to insurance required by paragraphs
5.4.3 through 5.4.6 inclusive, include as additional insureds
(subject to any customary exclusion in respect of profes-
sional liability) OWNER. ENGINEER. ENGINEER's Con-
sultants and any other persons or entities identified in the
Supplementary Conditions, all of whom shall be listed as
additional insureds. and include coverage for the respective
officers and employees of all such additional insureds;
5.4.8. include the specific coverages and be written for
not less than the limits of liability provided in the Supple-
mentary Conditions or required by Laws or Regulations.
whichever is greater:
5.4.9. include completed operations insurance:
5.4.10. include contractual liability insurance covering
CONTRACTOR's indemnity obligations under paragraphs
6.12. 6.16 and 6.31 through 6.33;
5.4.11. contain a provision or endorsement that the
coverage afforded will not be cancelled, materially changed
or renewal refused until at least thirty days prior written
notice has been given to OWNER and CONTRACTOR and
to each other additional insured identified in the Supplemen-
tary Conditions to whom a certificate of insurance has been
issued (and the certificates of insurance furnished by the
CONTRACTOR pursuant to paragraph 5.3.2 will so pro-
vide):
5.4.12. remain in effect at least until final payment and at
all times thereafter when CONTRACTOR may be correct-
ing. removing or replacing defective Work in accordance
with paragraph 13.1?: and
5.4.13. with respect to completed operations insurance.
and any insurance coverage written on a claims -made basis,
remain in effect for at least two years after final payment
(and CONTRACTOR shall furnish OWNER and each other
additional insured identified in the Supplementary Condi-
tions to whom a certificate of insurance has been issued
evidence satisfactory to OWNER and any such additional
insured of continuation of such insurance at final payment
and one year thereafter).
Addition see Sc 5.4.14
OWNER': Liability Insurance:
5.5. In addition to the insurance required to be provided by
CONTRACTOR under paragraph 5.4. OWNER, at OWNER's
option. may purchase and maintain at OWNER's expense
OWNER's own liability insurance as will protect OWNER
against claims which may arise from operations under the
Contract Documents.
Replacement see Sc 5.5
Property Insurance:
5.6. Unless otherwise provided in the Supplementary Con-
ditions, OWNER shall purchase and maintain property insur-
Replacement see Sc 5.6
ance upon the Work at the site in the amount of the full
replacement cost thereof (subject to such deductible amounts
as may be provided in the Supplementary Conditions or
required by Laws and Regulations). This insurance shall:
5.6.1. include the interests of OWNER. CONTRAC-
TOR, Subcontractors. ENGINEER. ENGINEER's Con-
sultants and any other persons or entities identified in the
Supplementary Conditions. each of whom is deemed to have
an insurable interest and shall be listed as an insured or
additional insured;
5.6.2. be written on a Builder's Risk "all-risk" or open
peril or special causes of loss policy form that shall at least
include insurance for physical loss or damage to the Work.
temporary buildings. falsework and Work in transit and shall
insure against at least the following perils fire, lightning.
extended coverage, theft, vandalism and malicious mischief.
earthquake, collapse. debris removal. demolition occasioned
by enforcement of Laws and Regulations. water damage.
and such other perils as may be specifically required by the
Supplementary Conditions:
5.6.3. include expenses incurred in the repair or replace-
ment of any insured property (including but not limited to
fees and charges of engineers and architects);
5.6.4. cover materials and equipment stored at the site or
at another location that was agreed to in witting by OWNER
prior to being incorporated in the Work, provided that such
materials and equipment have been included in an Applica-
tion for Payment recommended by ENGINEER: and
5.6.5. be maintained in effect until final payment is made
unless otherwise agreed to in writing by OWNER. CON-
TRACTOR and ENGINEER with thirty days written notice
to each other additional insured to whom a certificate of
insurance has been issued.
5.7, OWNER shall purchase and maintain such boiler and
machinery insurance or additional property insurance as may
be required by the Supplementary Conditions or Laws and
Regulations which will include the interests of OWNER,
CONTRACTOR, Subcontractors. ENGINEER. ENGINEER's
Consultants and any other persons or entities identified in the
Supplementary Conditions, each of whom is deemed to have
an insurable interest and shall be listed as an insured or
additional insured.
Replacement see Sc 5.7
5.8. All the policies of insurance (and the certificates or
other evidence thereof) required to be purchased and main-
tained by OWNER in accordance with paragraphs 5.6 and 5.7
will contain a provision or endorsement that the coverage
afforded will not be cancelled or materially changed or renewal
refused until at least thirty days' prior written notice has been
given to OWNER and CONTRACTOR and to each other
additional insured to whom a certificate of insurance has been
issued and will contain waiver provisions in accordance with
paragraph 5.11.
71
I
1
5.9. OWNER shall not be responsible for purchasing and
maintaining any property insurance to protect the interests of
CONTRACTOR, Subcontractors or others in the Work to the
extent of any deductible amounts that are identified in the
Supplementary Conditions. The risk of loss within such iden-
tified deductible amount, will be borne by CONTRACTOR.
Subcontractor or others suffering any such loss and if any of
them wishes property insurance coverage within the limits of
such amounts, each may purchase and maintain it at the
purchaser's own expense.
Delete 5.10
5.10. If CONTRACTOR requests in writing that other
special insurance be included in the property insurance policies
provided cinder paragraphs 5.6 or 5.7. OWNER shall, if possi-
ble, include such insurance, and the cost thereof will be
charged to CONTRACTOR by appropriate Change Order or
Written.Amendment. Prior to commencement of the Work at
the site. OWNER shall in writing advise CONTRACTOR
whether or not such other insurance has been procured by
OWNER.
i
5.11. Waiver of Rights:
5.11`.'1 OWNER and CONTRACTOR intend that all
policies purchased in accordance with paragraphs 5.6 and
5.7 will'protect OWNER, CONTRACTOR, Subcontractors.
ENGINEER, ENGINEER's Consultants and all other per-
sons or entities identified in the Supplementary Conditions to
be listed'as insureds or additional insureds in such policies
and will provide primary coverage for all losses and damages
caused by the perils covered thereby. All such policies shall
contain provisions to -the effect that in the event of payment
of any loss or damage the insurers will have no rights of
recovery, against any of the insureds or additional insureds
thereunder. OWNER and CONTRACTOR waive all rights
against each other and their respective officers, directors.
employees and agents for all losses and damages caused by,
arising out of or resulting from any of the perils covered by
such policies and any other property insurance applicable to
the Work; and, in addition, waive all such rights against
Subcontractors, ENGINEER, ENGINEER's Consultants
and all other persons or entities identified in the Supplemen-
tary Conditions to be listed as insureds or additional insureds
under such policies for losses and damages so caused. None
of the above waivers shall extend to the rights that any party
making such waiver may have to the proceeds of insurance
held by OWNER as trustee or otherwise payable under any
policy so; issued.
5.11 2i In addition. OWNER waives all rights against
CONTRACTOR, Subcontractors. ENGINEER. ENGI-
NEER's Consultants and the officers, directors, employees
and agents of any of them, for:
5.11:2. I. loss due to business interruption, loss of use
or other consequential loss extending beyond direct phys-
ical loss or damage to OWNER's property or the Work
caused; by, arising out of or resulting from fire or other
peril, whether or not insured by OWNER; and
5.11.2.2. loss or damage to the completed Project or
part thereof caused by. arising out of or resulting from fire
or other insured peril covered by any property insurance
maintained on the completed Project or part thereof by
OWNER during partial utilization pursuant to paragraph
14.10. after substantial completion pursuant to paragraph
14.8 or after final payment pursuant to paragraph 14.13.
Any insurance policy maintained by OWNER covering any
loss, damage or consequential loss referred to in this paragraph
5.11.2 shall contain provisions to the effect that in the event of
payment of any such loss. damage or consequential loss the
insurers will have no rights of recovery against any of CON-
TRACTOR,Subcontractors. ENGINEER. ENGINEER's Con-
sultants and the officers, directors, employees and agents of
any of them.
Receipt and App�cation of Insurance Proceeds
Delete 5.12
5.12. Any insured loss under the policies of insurance
required by paragraphs 5.6 and 5.7 will be adjusted with
OWNER and made payable to OWNER as fiduciary for the
insureds. as their interests may appear, subject to the require-
ments of any applicable mortgage clause and of paragraph 5.13.
OWNER shall deposit in a separate account any money so
received, and shall distribute it in accordance with such agree-
ment as the parties in interest may reach. If no other special
agreement is reached the damaged Work shall be repaired or
replaced, the moneys so received applied on account thereof
and the Work and the cost thereof covered by an appropriate
Change Order or Written Amendment.
Delete 5.13
5.13. OWNER as fiduciary shall have power to adjust and
settle any loss with the insurers unless one of the parties in
interest shall object in writing within fifteen days after the
occurrence of loss to OWNER's exercise of this power. If such
objection be made. OWNER as fiduciary shall make settlement
with the insurers in accordance with such agreement as the
parties in interest may reach. If no such agreement among the
parties in interest is reached, OWNER as fiduciary shall adjust
and settle the loss with the insurers and, if required in writing
by any party in interest. OWNER as fiduciary shall give bond
for the proper performance of such duties.
Acceptance of Bonds and lnsumnce; Option to Replace:
5.14. If either party (OWNER or CONTRACTOR) has any
objection to the coverage afforded by or other provisions of the
Bonds or insurance required to be purchased and maintained
by the other party in accordance with Article 5 on the basis of
non-conformance with the Contract Documents, the objecting
party shall so notify the other party in writing within ten days
after receipt of the certificates (or other evidence requested)
required by paragraph 2.7. OWNER and CONTRACTOR shall
each provide to the other such additional information in respect
of insurance provided as the other may reasonably request. If
either party does not purchase or maintain all of the Bonds and
insurance required of such party by the Contract Documents.
such party shall notify the other party in writing of such failure
to purchase prior to the start of the Work, or of such failure to
maintain prior to any change in the required coverage. Without
prejudice to any other right or remedy, the other party may
elect to obtain equivalent Bonds or insurance to protect such
other party's interests at the expense of the party who was
_l
I
I
I
I
I
Li]
I
I
I
22
I
11
I
I
Li
I
C
P
I
1,
C
I
11
I
I
I
1
I1
required to provide such coverage, and a Change Order shall
be issued to adjust the Contract Price accordingly.
Partial Utilization— Property Insurance:
5.15. If OWNER finds it necessary to occupy or use a
portion or portions of the Work prior to Substantial Completion
of all the Work, such use or occupancy may be accomplished in
accordance with paragraph 14.10: provided that no such use or
occupancy shall commence before the insurers providing the
property insurance have acknowledged notice thereof and in
writing effected any changes in coverage necessitated thereby.
The insurers providing the properly insurance shall consent by
endorsement on the policy or policies. but the propcn} insur-
ance shall not be cancelled or permitted to lapse on account of
any such partial use or occupancy.
ARTICLE 6-- CONTRACTOR'S RESPONSIBILITIES
.rs
$ rnswn and Superinrendenn:
6.1. CONTRACTOR shall supervise, inspect and direct the
Work competently and efficiently, devoting such attention
thereto and applying such skills and expertise as may be
necessary to perform the Work in accordance with the Con-
tract Documents. CONTRACTOR shall be solely responsible
for the means. methods. techniques. sequences and procedures
of construction, but CONTRACTOR shall not be responsible
for the negligence of others in the design or specification of a
specific means, method. technique. sequence or procedure of
construction which is shown or indicated in and expressly
required by the Contract Documents. CONTRACTOR shall be
responsible to see that the completed Work complies accu-
rately with the Contract Documents.
6.2. CONTRACTOR shall keep on the Work at all times
during its progress a competent resident superintendent, who
shall not be replaced without written notice to OWNER and
ENGINEER except under extraordinary circumstances. The
superintendent will be CONTRACTOR's representative at the
site and shall have authority to act on behalf of CONTRAC-
TOR. All communications to the superintendent shall be as
binding as if given to CONTRACTOR.
Labor, .Materials and Equipment:
6.3. CONTRACTOR shall provide competent. suitably qual-
ified personnel to survey, lay our and consuuct the Work as
required by the Contract Documents. CONTRACTOR shall at
all times maintain good discipline and order at the site. Except
as otherwise required for the safety or protection of persons or
the Work or property at the site or adjacent thereto. and except
as otherwise indicated in the Contract Documents. all Work at
the site shall be performed during regular working hours and
CONTRACTOR will not permit overtime work or the perfor-
mance of Work on Saturday. Sunday or any legal holiday
without OWNER's written consent given after prior written
notice to ENGINEER.
6.4. Unless otherwise specified in the General Require-
ments. CONTRACTOR shall furnish and assume full respon-
sibility for all materials. equipment. labor, transportation. con-
struction equipment and machinery, tools, appliances, fuel.
power. light, heat. telephone, water, sanitary facilities, tempo-
rary facilities and all other facilities and incidentals necessary
for the furnishing. performance. testing, scan -up and comple.
tion of the Work.
6.5. All materials and equipment shall be of good quality
and new, except as otherwise provided in the Contract Docu-
ments. All warranties and guarantees specifically called for by
the Specifications shall expressly run to the benefit ofOWNER.
W N ER.
If required by ENGINEER. CONTRACTOR shall furnish
satisfactory evidence (including reports of required tests) as to
the kind and quality of materials and equipment. All materials
and equipment shall be applied. installed, connected. erected.
used. cleaned and conditioned in accordance with instructions
of the applicable Supplier, except as otherwise provided in the
Contract Documents.
Progress Schedule:
6.6. CONTRACTOR shall adhere to the progress schedule
established in accordance with paragraph 2.9 as it may be
adjusted from time to time as provided below:
6.6.1. CONTRACTOR shall submit to ENGINEER for
acceptance (to the extent indicated in paragraph 2.9) pro-
posed adjustments in the progress schedule that will not
change the Contract Times (or Milestones). Such adjust-
ments will conform generally to the progress schedule then
in effect and additionally will comply with any provisions of
the General Requirements applicable thereto.
6.6.2. Proposed adjustments in the progress schedule
that will change the Contract Times (or Milestones) shall be
submitted in accordance with the requirements of paragraph
12.1. Such adjustments may only be made by a Change
Order or Written Amendment in accordance with Article 12.
Addition see SC 6.6
6.7. Subsnmtes and "Or -Equal" Items:
6.7.1. Whenever an item of material or equipment is
specified or described in the Contract Documents by using
the name of a proprietary item or the name of a particular
Supplier, the specification or description is intended to
establish the type. function and quality required. Unless the
specification or description contains or is followed by words
reading that no like, equivalent or "or -equal" item or no
substitution is permitted. other items of material or equip-
ment or material or equipment of other Suppliers may be
accepted by ENGINEER under the following circumstances:
J
23
6.7.1.1. "Or -Equal": If in ENGINEER's sole discre-
tion an item of material or equipment proposed by CON-
TRACTOR is functionally equal to that named and suffi-
ciently similar so that no change in related Work will be
required, it may be considered by ENGINEER as an
"or -equal" item, in which case review and approval of the
proposed item may, in ENGINEER's sole discretion, be
accomplished without compliance with some or all of the
requirements for acceptance of proposed substitute items.
6.7.1.2. Substitute Items: If in ENGINEER's sole
discretion an item of material or equipment proposed by
CONTRACTOR does not qualify as an "or -equal" item
under subparagraph 6.7.1.1. it will be considered a pro-
posed -substitute item. CONTRACTOR shall submit suffi-
cient information as provided below to allow ENGINEER
to determine that the item of material or equipment
proposed is essentially equivalent to that named and an
acceptable substitute therefor. The procedure for review
by the! ENGINEER will include the following as supple-
mented in the General Requirements and as ENGINEER
may decide is appropriate under the circumstances. Re-
quests1for review of proposed substitute items of material
or equipment will not be accepted by ENGINEER from
anyone other than CONTRACTOR. If CONTRACTOR
wishes to furnish or use a substitute item of material or
equipment, CONTRACTOR shall first make written appli-
catioto ENGINEER for acceptance thereof, certifying
that the proposed substitute will perform adequately the
functions and achieve the results called for by the general
design.' be similar in substance to that specified and be
suited to the same use as that specified. The application
will state the extent, if any, to which the evaluation and
acceptance of the proposed substitute will prejudice CON-
TRACTOR's achievement of Substantial Completion on
time, whether or not acceptance of the substitute for use in
the Work will require a change in any of the Contract
Documents (or in the provisions of any other direct
contract with OWNER for work on the Project) to adapt
the design to the proposed substitute and whether or not
incorporation or use of the substitute in connection with
the Work is subject to payment of any license fee or
royalty .1 All variations of The proposed substitute from that
specified will be identified in the application and available
maintenance, repair and replacement service will be indi-
cated. The application will also contain an itemized esti-
mate of all costs or credits that will result directly or
indirectly from acceptance of such substitute, including
costs of redesign and claims of other contractors affected
by the resulting change. all of which will be considered by
ENGINEER in evaluating the proposed substitute. EN-
GINEER may require CONTRACTOR to furnish addi-
tional data about the proposed substitute.
1
6.7.1.3. CONTRACTOR's Expense: All data to be
provided by CONTRACTOR in support of any proposed
"or -equal" or substitute item will be at CONTRACTOR'S
expense.
6.7.2. Substitute Construction Methods or Procedures: If a
specific means, method, technique, sequence or procedure of
24
construction is shown or indicated in and expressly required by
the Contract Documents, CONTRACTOR may furnish or
utilize a substitute means, method, technique, sequence or
procedure of construction acceptable to ENGINEER. CON-
TRACTOR shall submit sufficient information to allow ENGI-
NEER, in ENGINEER's sole discretion, to determine that the
substitute proposed is equivalent to that expressly called for by
the Contract Documents. The procedure for review by ENGI-
NEER will be similar to that provided in subparagraph 6.7.1.2.
6.7.3. Engineer's Evaluation: ENGINEER will be allowed
a reasonable time within which to evaluate each proposal or
submittal made pursuant to paragraphs 6.7.1.2 and 6.7.2.
ENGINEER will be the sole judge of acceptability. No "or -
equal" or substitute will be ordered, installed or utilized
without ENGINEER's prior written acceptance which will be
evidenced by either a Change Order or an approved Shop
Drawing. OWNER may require CONTRACTOR to furnish at
CONTRACTOR's expense a special performance guarantee or
other surety with respect•to any "or -equal" or substitute.
ENGINEER will record. time required by ENGINEER and
ENGINEER's Consultants in evaluating substitutes proposed
or submitted by CONTRACTOR pursuant to paragraphs 6.7.1.2
and 6.7.2 and in making changes in the Contract Documents (or
in the provisions of any other direct contract with OWNER for
work on the Project) occasioned thereby. Whether or not
ENGINEER accepts a substitute item so proposed or submit-
ted by CONTRACTOR, CONTRACTOR shall reimburse
OWNER for the charges of ENGINEER and ENGINEER's
Consultants for evaluating each such proposed substitute item.
Concerning Subcontracwrs, Suppliers and Others:
6.8.1. CONTRACTOR shall not employ any Subcon-
tractor, Supplier or other person or organization (including
those acceptable to OWNER and ENGINEER as indicated
in paragraph 6.8.2), whether initially or as a substitute.
against whom OWNER or ENGINEER may have reason-
able objection. CONTRACTOR shall not be required to
employ any Subcontractor, Supplier or other person or
organization to furnish or perform any of the Work against
whom CONTRACTOR has reasonable objection.
6.8.2. If the Supplementary Conditions require the iden-
tity of certain Subcontractors, Suppliers or other persons or
organizations (including those who are to furnish the princi-
pal items of materials or equipment) to be submitted to
OWNER in advance of the specified date prior to the
Effective Date of the Agreement for acceptance by OWNER
and ENGINEER, and if CONTRACTOR has submitted a
list thereof in accordance with the Supplementary Condi-
tions, OWNER's or ENGINEER's acceptance (either in
writing or by failing to make written objection thereto by the
date indicated for acceptance or objection in the bidding
documents or the Contract Documents) of any such Subcon-
tractor. Supplier or other person or organization so identified
may be revoked on the basis of reasonable objection after
due investigation, in which case CONTRACTOR shall sub-
mit an acceptable substitute, the Contract Price will be
adjusted by the difference in the cost occasioned by such
I
I
I
11
H
I
I
LI
H
H
H
H
I
I
[1
H
H
H
C
P
1,
I
I
H
H
I
I
I
I
substitution and an appropriate Change Order will be issued
or Written Amendment signed. No acceptance by OWNER
or ENGINEER of any such Subcontractor. Supplieror other
person or organization shall constitute a waiver of any right
of OWNER or ENGINEER ro reject defective Work.
£.9.1. CONTRACTOR shall be fully responsible to
OWNER and ENGINEER for all acts and omissions of the
Subcontractors. Suppliers and other persons and organiza-
tions performing or furnishing any of the Work under a direct
or indirect contract with CONTRACTOR just as CON-
TRACTOR is responsible for CONTRACTOR's own acts
and omissions. Nothing in the Contract Documents shall
create for the benefit of any such Subcontractor. Supplier or
other person or organization any contractual relationship
between OWNER or ENGINEER and any such Subcon-
tractor. Supplier or other person or organization. nor shall it
create any obligation on the part of OWNER or ENGI-
NEER to pay or to see to the payment of any moneys due
any such Subcontractor. Supplier or other person or organi-
zation except as may otherwise be required by Laws and
Regulations.
%6.92. CONTRACTOR shall be solely responsible for
scheduling and coordinating the Work of Subcontractors.
Suppliers and other persons and organizations performing or
(umishing any of the Work under a direct or indirect contract
with CONTRACTOR. CONTRACTOR shall require all Sub-
contractors. Suppliers and such other persons and organiza-
tions performing or furnishing any of the Work to communi-
cate with the ENGINEER through CONTRACTOR.
6.10. The divisions and sections of the Specifications and
the identifications of any Drawings shall not control CO` -
TRACTOR in dividing the Work among Subcontractors or
Suppliers or delineating the Work to be performed by any
specific trade.
6.11. All Work performed for CONTRACTOR by a Sub-
contractor or Supplier will be pursuant to an appropriate
agreement between CONTRACTOR and the Subcontractor or
Supplier which specifically bind, the Subcontractor or Supplier
to the applicable terms and conditions of the Contract Docu-
ments for the benefit of OWNER and ENGINEER. Whenever
any such agreement is with a Subcontractor or Supplier who is
listed as an additional insured on the property insurance
provided in paragraph 5.6 or 5.7. the agreement between the
CONTRACTOR and the Subcontractor or Supplier will con-
tain provisions whereby the Subcontractor or Supplier waives
all rights against OWNER. CONTRACTOR. ENGINEER.
ENGINEER's Consultants and all other additional insureds for
all losses and damages caused by. arising out of or resulting
from any of the penis covered by such policies and any other
property insurance applicable to the Work. If the insurers on
any such policies require separate waiver forms to be signed by
any Subcontractor or Supplier. CONTRACTOR will obtain the
same.
Patera Fees and Royalties:
6.12. CONTRACTOR shall pay all license fees and royal.
ties and assume all costs incident to the use in the performance
of the Work or the incorporation in the Work of any invention.
design, process. product or device which is the subject of
patent rights or copyrights held by others. If a particular
invention, design. process. product or device is specified in the
Contract Documents for use in the performance of the Work
and if to the actual knowledge of OWNER or ENGINEER its
use is subject to patent rights or copyrights calling for the
payment of any license fee or royalty to others. the existence of
such rights shall be disclosed by OWNER in the Contract
Documents. To the fullest extent permitted by Laws and
Regulations. CONTRACTOR shall indemnify and hold harm-
less OWNER, ENGINEER. ENGINEER's Consultants and
the officers. directors. employees, agents and other consultants
of each and any of them from and against all claims. costs.
losses and damages arising out of or resulting from any
infringement of patent rights or copyrights incident to the use in
the performance of the Work or resulting from the incorpora-
tion in the Work of any invention, design, process. product or
device not specified in the Contact Documents.
Permits:
6.13. Unless otherwise provided in the Supplementary
Conditions. CONTRACTOR shall obtain and pay for all con-
struction permits and licenses. OWNER shall assist CON-
TRACTOR. when necessary. in obtaining such permits and
licenses. CONTRACTOR shall pay all governmental charges
and inspection fees necessary for the prosecution of the Work,
which are applicable at the time of opening of Bids. or. if there
are no Bids, on the Effective Date of the Agreement. CON-
TRACTOR shall pay all charges of utility owners for connec-
tions to the Work, and OWNER shall pay all charges of such
utility owners for capital costs related thereto such as plant
investment fees.
Law's and Regulaa'ons:
6.14.1. CONTRACTOR shall give all notices and comply
with all Laws and Regulations applicable to furnishing and
performance of the Work. Except where otherwise expressly
required by applicable Laws and Regulations. neithc r OWN ER
nor ENGINEER shall be responsible for monitoring CON-
TRACTOR's compliance with any Laws or Regulations.
6.14.2. If CONTRACTOR performs any Work knowing
or having reason to know that it is contrary to Laws or
Regulations. CONTRACTOR shall bear all claims, costs.
losses and damages caused by. arising out of or resulting
therefrom; however, it shall not be CONTRACTOR -s pri-
mary responsibility to make certain that the Specifications
and Drawings arc in accordance with Laws and Regulations.
but this shall not relieve CONTRACTOR of CONTRAC-
TOR's obligations under paragraph 3.3.2.
Tarn:
6.15. CONTRACTOR shall pay all sales, consumer. use
and other similar taxes required to be paid by CONTRACTOR
in accordance with the Laws and Regulations of the place of
I
25
I
the Project which are applicable during the performance of the
Work.
Use of Prrmises:
6.16. CONTRACTOR shall confine construction equip-
ment, the storage of materials and equipment and the opera-
tions of workers to the site and land and areas identified in and
permitted by the Contract Documents and other land and areas
perm fitted by Laws and Regulations, rights -of -way, permits and
easements, and shall not unreasonably encumber the premises
with construction equipment or other materials or equipment.
CONTRACTOR shall assume full responsibility for any dam-
age to any such land or area, or to the owner or occupant
thereof or of any adjacent land or areas, resulting from the
performance of the Work. Should any claim be made by any
such owner or occupant because of the performance of the
Work. CONTRACTOR shall promptly settle with such other
party by negotiation or otherwise resolve the claim by arbitra-
tion or other dispute resolution proceeding or at law. CON-
TRACTOR shall, to the fullest extent permitted by Laws and
Regulations, indemnify and hold harmless OWNER. ENGI-
NEER, ENGINEER's Consultant and anyone directly or
indirectty'employed by any of them from and against all claims.
costs, losses and damages arising out of or resulting from any
claim oraction. legal or equitable, brought by any such owner
or occupant against OWNER. ENGINEER or any other party
indemnified hereunder to the extent caused by or based upon
C0NTRPCTOR's performance of the Work.
6.17. During the progress of the Work, CONTRACTOR
shall keep the premises free from accumulations of waste
materials,1 rubbish and other debris resulting from the Work. At
the completion of the Work CONTRACTOR shall remove all
waste materials, rubbish and debris from and about the pre-
mises as well as all tools, appliances, construction equipment
and machinery and surplus materials. CONTRACTOR shall
leave the site clean and ready for occupancy by OWNER at
Substantial Completion of the Work. CONTRACTOR shall
restore to original condition all property not designated for
alterationiby the Contract Documents.
i
6.18. CONTRACTOR shall not load nor permit any part of
any structure to be loaded in any manner that will endanger the
structure.1 nor shall CONTRACTOR subject any pan of the
Work or adjacent property to stresses or pressures that will
endanger it.
I
i
Record D cumenu
6.19. CONTRACTOR shall maintain in a safe place at the
site one record copy of all Drawings, Specifications. Addenda,
Written Amendments. Change Orders. Work Change Direc-
tives. Field Orders and written interpretations and clarifica-
tions (issued pursuant to paragraph 9.4) in good order and
annotated; to show all changes made during construction.
These record documents together with all approved Samples
and a counterpart of all approved Shop Drawings will be
available to ENGINEER for reference. Upon completion of
the Work, these record documents. Samples and Shop Draw-
ings will be delivered to ENGINEER for OWNER.
Safety and Protection:
6.20. CONTRACTOR shall be responsible for initiating.
maintaining and supervising all safety precautions and pro-
grams in connection with the Work. CONTRACTOR shall take
all necessary precautions for the safety of, and shall provide
the necessary protection to prevent damage, injury or loss to:
6.20.1. all persons on the Work site or who may be
affected by the Work;
6.20.2. all the Work and materials and equipment to be
incorporated therein, whether in storage on or off the site:
and
6.20.3. other property at the site or adjacent thereto.
including trees, shrubs, lawns, walks, pavements, roadways.
structures, utilities and Underground Facilities not desig-
nated for removal, relocation or replacement in the course of
construction.
CONTRACTOR shall comply with all applicable Laws and
Regulations of any public body having jurisdiction for safety of
persons or property or to protect them from damage. injury or
loss: and shall erect and maintain all necessary safeguards for
such safety and protection. CONTRACTOR shall notify own-
ers of adjacent property and of Underground Facilities and
utility owners when prosecution of the Work may affect them.
and shall cooperate with them in the protection, removal,
relocation and replacement of their property. All damage,
injury or loss to any property referred to in paragraph 6.20.2 or
6.20.3 caused, directly or indirectly, in whole or in part. by
CONTRACTOR, any Subcontractor, Supplier or any other
person or organization directly or indirectly employed by any
of them to perform or furnish any of the Work or anyone for
whose acts any of them may be liable, shall be remedied by
CONTRACTOR (except damage or loss attributable to the
fault of Drawings or Specifications or to the acts or omissions
of OWNER or ENGINEER or ENGINEER's Consultant or
anyone employed by any of them or anyone for whose acts any
of them may be liable, and not attributable, directly or indi-
rectly. in whole or in part, to the fault or negligence of
CONTRACTOR or any Subcontractor. Supplier or other per-
son or organization directly or indirectly employed by any of
them). CONTRACTOR's duties and responsibilities for safety
and for protection of the Work shall continue until such time as
all the Work is completed and ENGINEER has issued a notice
to OWNER and CONTRACTOR in accordance with para-
graph 14.13 that the Work is acceptable (except as otherwise
expressly provided in connection with Substantial Comple-
tion).
Safety Reprcsentarive:
6.21. CONTRACTOR shall designate a qualified and expe-
rienced safety representative at the site whose duties and
I
I
I
L1
I
I
H
I
1-I
H
26
I
I
C
I
I
1
L
H
H
I
I
I
I
I
I
U
responsibilities shall be the prevention of accidents and the
maintaining and supervising of safety precautions and pro-
grams.
Hazard Communiraion Programs:
6.22. CONTRACTOR shall be responsible for coordinating
any exchange of material safety data sheets or other hazard
communication information required to be made available to or
exchanged between or among employers at the site in accor-
dance with Laws or Regulations.
Emergencies:
6.23. In emergencies affecting the safety or protection of
persons or the Work or property at the site or adjacent
thereto. CONTRACTOR, without special instruction or au-
thorization from OWNER or ENGINEER, is obligated to
act to prevent threatened damage. injury or loss. CON-
TRACTOR shall give ENGINEER prompt written notice if
CONTRACTOR believes that any significant changes in the
aG Work or variations from the Contract Documents have been
t caused thereby. If ENGINEER determines that a change in
'a the Contract Documents is required because of the action
taken by CONTRACTOR in response to such an emergency.
a Work Change Directive or Change Order will be issued to
document the consequences of such action.
6.24. Shop Drawings and Samples:
6.24.1. CONTRACTOR shall submit Shop Drawings to
ENGINEER for review and approval in accordance with the
accepted schedule of Shop Drawings and Sample submittals
(see paragraph 2.9). All submittals will be identified as
ENGINEER may require and in the number of copies
specified in the General Requirements. The data shown on
the Shop Drawings will be complete with respect to quanti-
ties. dimensions. specified performance and design criteria.
materials and similar data to show ENGINEER the materi-
als and equipment CONTRACTOR proposes to provide and
to enable ENGINEER to review the information for the
limited purposes required by paragraph 6.26.
6.24.2. CONTRACTOR shall also submit Samples to
ENGINEER for review and approval in accordance with
said accepted schedule of Shop Drawings and Sample sub-
mittals. Each Sample will be identified clearly as to material.
Supplier, pertinent data such as catalog numbers and the use
for which intended and otherwise as ENGINEER may
require to enable ENGINEER to review the submittal for
the limited purposes required by paragraph 6.26. The num-
bers of each Sample to be submitted will be as specified in
the Specifications.
6.25. SubmirW Procedures:
6.25.1. Before submitting each Shop Drawing or Sam-
ple. CONTRACTOR shall have determined and verified:
6.25.1.1. ail field measurements, quantities. dimen-
sions. specified performance criteria. installation require-
ments. materials. catalog numbers and similar information
with respect thereto.
6.25.1.2. all materials with respect to intended use.
fabrication, shipping. handling, storage. assembly and
installation pertaining to the performance of the Work. and
6.25.1.2. all information relative to CONTRACTOR's
sole responsibilities in respect of means, methods, tech-
niques. sequences and procedures of construction and
safety precautions and programs incident thereto.
CONTRACTOR shall also have reviewed and coordinated
each Shop Drawing or Sample with other Shop Drawings
and Samples and with the requirements of the Work and the
Contract Documents.
6.25.2. Each submittal will bear a stamp or specific
written indication that CONTRACTOR has satisfied CON-
TRACTOR's obligations under the Contact Documents with
respect to CONTRACTOR'S review and approval of that
submittal.
6.25.3. At the time of each submission. CONTRACTOR
shall give ENGINEER specific written notice of such vari-
ations, if any, that the Shop Drawing or Sample submitted
may have from the requirements of the Contract Documents.
such notice to be in a written communication separate from
the submittal; and, in addition, shall cause a specific notation
to be made on each Shop Drawing and Sample submitted to
ENGINEER for review and approval of each such variation.
6.'_6. ENGINEER will review and approve Shop Drawings
and Samples in accordance with the schedule of Shop Draw-
ings and Sample submittals accepted by ENGINEER as re-
quired by paragraph 2.9. ENGINEER's review and approval
will be only to determine if the items covered by the submittals
will, after installation or incorporation in the Work, conform to
the information given in the Contract Documents and be
compatible with the design concept of the completed Project as
a functioning whole as indicated by the Contract Documents.
ENGINEER's review and approval will not extend to means.
methods. techniques. sequences or procedures of construction
(except where a particular means, method, technique. se-
quence or procedure of construction is specifically and ex-
pressly called for by the Contract Documents) or to safety
precautions or programs inc.dent thereto. The review and
approval of a separate item as such will not indicate approval of
the assembly in which the item functions. CONTRACTOR
shall make corrections required by ENGINEER, and shall
return the required number of corrected copies of Shop Draw-
ings and submit as required new Samples for review and
approval. CONTRACTOR shall direct specific attention in
writing to revisions other than the corrections called for by
ENGINEER on previous submittals.
6.27. ENGINEER's review and approval of Shop Draw-
ings or Samples shall not relieve CONTRACTOR from respon-
sibility for any variation from the requirements of the Contract
27
I
Documents' unless CONTRACTOR has in writing called EN-
GINEER's attention to each such variation at the time of
submission 'as required by paragraph 6.25.3 and ENGINEER
has given written approval of each such variation by specific
written notation thereof incorporated in or accompanying the
Shop Drawing or Sample approval: nor will any approval by
ENGINEER relieve CONTRACTOR from responsibility for
complying with the requirements of paragraph 6.25.1.
6.28. Where a Shop Drawing or Sample is required by the
Contract Documents or the schedule of Shop Drawings and
Sample submissions accepted by ENGINEER as required by
paragraph 2, 9, any related Work performed prior to ENGI-
NEER's review and approval of the pertinent submittal will be
at the sole expense and responsibility of CONTRACTOR.
Continuing the Work:
6.29. CONTRACTOR shall carry on the Work and adhere
to the progress schedule during all disputes or disagreements
with OWNER. No Work shall be delayed or postponed pend-
ing resolution of any disputes or disagreements, except as
permitted by paragraph 15.5 or as OWNER and CONTRAC-
TOR may otherwise agree in writing.
6.30. CONTRACTOR's General W'arranry and Guarantee:
Addition — See SC 6.30.3.
6.30.1. i CONTRACTOR warrants and guarantees to
OWNER. ENGINEER and ENGINEER's Consultants that
all Work will be in accordance with the Contract Documents
and will not be defective. CONTRACTOR's warranty and
guarantee hereunder excludes defects or damage caused by:
I
6.30. I I. I. abuse, modification or improper maintenance
or operation by persons other than CONTRACTOR. Sub-
contractors or Suppliers: or
6.30.1!.2. normal wear and tear under normal usage.
6.30.2. CONTRACTOR's obligation to perform and com-
plete the Work in accordance with the Contract Documents
shall be absolute. None of the following will constitute an
acceptance of Work that is not in accordance with the
Contract Documents or a release of CONTRACTOR's obli-
gation to perform the Work in accordance with the Contract
Documents:
6.30.211. observations by ENGINEER;
6.30.2:3. recommendation of any progress or final
payment!by ENGINEER;
i
6.302.3. the issuance of a certificate of Substantial
Completion or any payment by OWNER to CONTRAC-
TOR under the Contract Documents;
6.30.24. use or occupancy of the Work or any pan
thereof by OWNER:
28
6.30.2.5. any acceptance by OWNER or any failure to
do so;
6.30.2.6. any review and approval of a Shop Drawing
or Sample submittal or the issuance of a notice of accept-
ability by ENGINEER pursuant to paragraph 14.13;
6.30.2.7. any inspection, test or approval by others; or
6.3(12.8. any correction of defective Work by OWNER.
Addition — See SC 6.30.3
lndemnifumion:
6.31. To the fullest extent permitted by Laws and Regula-
tions, CONTRACTOR shall indemnify and hold harmless
OWNER. ENGINEER, ENGINEER's Consultants and the
officers, directors, employees, agents and other consultants of
each and any of them from and against all claims, costs, losses
and damages (including but not limited to all fees and charges
of engineers, architects, attorneys and other professionals and
all court or arbitration or other dispute resolution costs) caused -
by, arising out of or resulting from the performance of the
Work, provided that any such claim, cost, loss or damage: (i) is
attributable to bodily injury, sickness, disease or death, or to
injury to or destruction of tangible property (other than the
Work itself), including the loss of use resulting therefrom, and
(ii) is caused in whole or in part by any negligent act or
omission of CONTRACTOR. any Subcontractor, any Supplier,
any person or organization directly or indirectly employed by
any of them to perform or furnish any of the Work or anyone
for whose acts any of them may be liable. regardless of whether
or not caused in part by any negligence or omission of a person
or entity indemnified hereunder or whether liability is imposed
upon such indemnified party by Laws and Regulations regard-
less of the negligence of any such person or entity.
6.32. In any and all claims against OWNER or ENGI-
NEER or any of their respective consultants, agents, officers,
directors or employees by any employee (or the survivor or
personal representative of such employee) of CONTRACTOR,
any Subcontractor, any Supplier, any person or organization
directly or indirectly employed by any of them to perform or
furnish any of the Work, or anyone for whose acts any of them
may be liable, the indemnification obligation under paragraph
6.31 shall not be limited in any way by any limitation on the
amount or type of damages, compensation or benefits payable
by or for CONTRACTOR or any such Subcontractor, Supplier
or other person or organization under workers' compensation
acts, disability benefit acts or other employee benefit acts.
6.33. The indemnification obligations of CONTRACTOR
under paragraph 6.31 shall not extend to the liability of ENGI-
NEER and ENGINEER's Consultants, officers, directors,
employees or agents caused by the professional negligence,
errors or omissions of any of them.
Survival of Obligations:
6.34. All representations. indemnifications, warranties and
guarantees made in. required by or given in accordance with
I
L
F.
I
1
A}
1
1
-1
J
J
I
J
I
I
I
I
H
I
7.4.1. the person. firm or corporation who will have
' ARTICLE 7 —OTHER WORK authonty and responsibility for coordination of the activities
among the various prime contractors will be identified;
the Contract Documentsas well as all continuing obligations
indicated in the Contract Documents, will survive final pay-
ment, completion and acceptance of the Work and termination
or completion of the Agreement.
Coordination:
7.4. If OWNER contracts with others for the performance
of other work on the Project at the site, the following will be set
forth in Supplementary Conditions:
I
r,
n
I
H
I
I
I
Additions see SC 7.5
Related Wont at Site:
7.1. OWNER may perform other work related to the
Project at the site by OWNER's own forces, or let other
direct contracts therefor which shall contain General Condi-
tions similar to these, or have other work performed by
utility owners. If the fact that such other work is to be
performed was not noted in the Contract Documents. then:
(i) written notice thereof will be given to CONTRACTOR
prior to starting any such other work. and (ii) CONTRAC-
TOR may make a claim therefor as provided in Articles II
an' 12 if CONTRACTOR believes that such performance
will involve additional expense to CONTRACTOR or re-
quires additional time and the parties are unable to agree as
tthe amount or extent thereof.
7.2. CONTRACTOR shall afford each other contractor
who is a party to such a direct contract and each utility
owner (and OWNER, if OWNER is performing the addi-
tional work with OWNER's employees) proper and safe
access to the site and a reasonable opportunity for the
introduction and storage of materials and equipment and the
execution of such other work and shall properly connect and
coordinate the Work with theirs. Unless otherwise provided
in the Contract Documents, CONTRACTOR shall do all
cutting, fitting and patching of the Work that may be required
to make its several parts come together properly and inte-
grate with sucn other work. CONTRACTOR shall not en•
danger any work of others by cutting. excavating or other-
wise altering their work and will only cut or alter their work
with the written consent of ENGINEER and the others
whose work will be affected. The duties and responsibilities
of CONTRACTDR under this paragraph are for the benefit of
such utility owners and other contractors to the extent that
there are comparable provisions for the benefit of CON-
TRACTOR in said direct contracts between OWNER and
such utili:y owners and other contractors.
7.3. If the proper execution or results of any part of
CONTRACTOR's Work depends upon work performed by
others under this Article 7. CONTRACTOR shall inspect such
other work and promptly report to ENGINEER in writing any
delays, defects or deficiencies in such other work that render it
unavailable or unsuitable for the proper execution and results
of CONTRACTOR's Work. CONTRACTOR's failure so to
report will constitute an acceptance of such other work as fit
and proper for irr:. graiion with CONTRACTOR's Work except
for latent or nonapparent defects and deficiencies in such other
work.
7.4.2. the specific matters to be covered by such author-
ity and responsibility will be itemized: and
7.4.3, the extent of such authority and responsibilities
will be provided.
Unless otherwise provided in the Supplementary Condi-
tions. OWNER shall have sole authority and responsibility in
respect of such coordination.
ARTICLE 8 —OWNER'S RESPONSIBILITIES
8.1. Except as otherwise provided in these General Condi-
tions. OWNER shall issue all communications to CONTRAC-
TOR through ENGINEER.
8.2. In case of termination of the employment of ENGI-
NEER. OWNER shall appoint an engineer against whom
CONTRACTOR makes no reasonable objecuon. whose status
under the Contract Documents shall be that of the former
ENGINEER.
8.3. OWNER shall furnish the data required of OWNER
under the Contract Documents promptly and shall make pay-
ments to CONTRACTOR promptly when they are due as
provided in paragraphs 14.4 and 14.13.
8,4. OWNER's duties in respect of providing lands and
easements and providing engineering surveys to establish ref-
erence points are set forth in paragraphs 4.1 and 4.4. Paragraph
4.2 refers to OWNER's identifying and making available to
CONTRACTOR copies of reports of explorations and tests of
subsurface conditions at the site and drawings of physical
conditions in existing structures at or contiguous to the site that
have been utilized by ENGINEER in preparing the Contract
Documents.
Delete 8.5
8.5. OWNER's responsibilities in respect of purchasing
and maintaining liability and property insurance are set forth in
paragraphs 5.5 through 5.10.
8.6. OWNER is obligated to execute Change Orders as
indicated in paragraph 10.4.
8.7. OWNER's responsibility in respect of certain inspec-
tions. tests and approvals is set forth in paragraph 13.4.
8.8. In connection with OWNER's right to stop Work or
suspend Work, see paragraphs 13.10 and 15.1. Paragraph 15.2
deals with OWNER's right to terminate services of CON-
TRACTOR under certain circumstances.
k
29
1l
8.9. The OWNER shall not supervise, direct or have
control or authority over, nor be responsible for, CONTRAC-
TOR's means, methods, techniques, sequences or procedures
of construction or the safety precautions and programs incident
thereto, or for any failure of CONTRACTOR to comply with
Laws and Regulations applicable to the furnishing or perfor-
mance of the Work. OWNER will not be responsible for
CONTRACTOR's failure to perform or furnish the Work in
accordance, with the Contract Documents.
8.10. OWNER'S responsibility in respect of undisclosed
Asbestos, PCBs, Petroleum. Hazardous Waste or Radioactive
Materials uncovered or revealed at the site is set forth in
paragraph 4:5.
8.11. If and to the extent OWNER has agreed to furnish
CONTRACTOR reasonable evidence that financial arrange-
ments have been made to satisfy OWNER's obligations under
the Contract' Documents, OWNER's responsibility in respect
thereof will be as set forth in the Supplementary Conditions.
ARTICLE.x$_ENGINEER'S STATUS DURING
CONSTRUCTION
OWNER's Representative:
i
9.1. ENGINEER will be OWNER's representative during
the construction period. The duties and responsibilities and the
limitations of authority of ENGINEER as OWNER's repre-
sentative during construction are set forth in the Contract
Documents and shall not be extended without written consent
of OWNER and ENGINEER.
Visits to Site:
9.2. ENGINEER will make visits to the site at intervals
appropriate to the various stages of construction as ENGI-
NEER deems necessary in order to observe as an experienced
and qualified design professional the progress that has been
made and the quality of the various aspects of CONTRAC-
TOR's executed Work. Based on information obtained during
such visits and observations, ENGINEER will endeavor for
the benefit of OWNER to determine, in general. if the Work is
proceeding inlaccordance with the Contract Documents. EN-
GINEER willnot be required to make exhaustive or continu-
ous on -site inspections to check the quality or quantity of the
Work. ENGINEER's efforts will be directed toward providing
for OWNER a greater degree of confidence that the completed
Work will conform generally to the Contract Documents. On
the basis of such visits and on -site observations. ENGINEER
will keep OWNER informed of the progress of the Work and
will endeavor to guard OWNER against defective Work. EN-
GINEER's visits and on -site observations are subject to all the
limitations on ,ENGINEER'S authority and responsibility set
forth in paragraph 9.13, and particularly, but without limitation,
during or as a result of ENGINEER's on -site visits or
observations of CONTRACTOR's Work ENGINEER will not
supervise, direct, control or have authority over or be respon-
sible for CONTRAC OR's means, methods, techniques, se-
quences or procedures of construction, or the safety precau-
tions and programs incident thereto, or for any failure of
CONTRACTOR to comply with Laws and Regulations appli-
cable to the furnishing or performance of the Work.
Project Reprrsentative:
9.3. If OWNER and ENGINEER agree. ENGINEER will
furnish a Resident Project Representative to assist ENGI-
NEER in providing more continuous observation of the Work.
The responsibilities and authority and limitations thereon of
any such Resident Project Representative and assistants will be
as provided in paragraph 9.13 and in the Supplementary
Conditions. If OWNER designates another representative or
agent to represent OWNER at the site who is not ENGI-
NEER's Consultant, agent or employee, the responsibilities
and authority and limitations thereon of such other person will
be as provided in the Supplementary Conditions.
Clarification and Ituerpretanons:
9.4. ENGINEER will issue with reasonable promptness
such written clarifications or interpretations of the require-
ments of the Contract Documents (in the form of Drawings or
otherwise) as ENGINEER may determine necessary, which
shall be consistent with the intent of and reasonably inferable
from Contract Documents. Such written clarifications and
interpretations will be binding on OWNER and CONTRAC-
TOR. If OWNER or CONTRACTOR believes that a written
clarification or interpretation justifies an adjustment in the
Contract Price or the Contract Times and the parties are unable
CO agree to the amount or extent thereof, if any. OWNER or
CONTRACTOR may make a written claim therefor as pro-
vided in Article II or Article 12.
Authorized Variations in {York:
9.5. ENGINEER may authorize minor variations in the
Work from the requirements of the Contract Documents which
do not involve an adjustment in the Contract Price or the
Contract Times and are compatible with the design concept of
the completed Project as a functioning whole as indicated by
the Contract Documents. These may be accomplished by a
Field Order and will be binding on OWNER and also on
CONTRACTOR who shall perform the Work involved promptly.
If OWNER or CONTRACTOR believes that a Field Order
justifies an adjustment in the Contract Price or the Contract
Times and the parties are unable to agree as to the amount or
extent thereof. OWNER or CONTRACTOR may make a
written claim therefor as provided in Article II or 12.
Rejecting Defective Work:
I
I
I
L
L
I
•1
I
I
I
I
I
L
L
9.6. ENGINEER will have authority to disapprove or
reject Work which ENGINEER believes to be defective, or
y
I
I
I
L
I
F
I
r
I
I
I
I
I
I
I
GI
I
I
I
that ENGINEER believes will not produce a completed Project
that conforms to the Contract Documents or that will prejudice
the integrity of the design concept of the completed Project as
a functioning whole as indicated by the Contract Documents.
ENGINEER will also have authority to require special inspec-
tion or testing of the Work as provided in paragraph 13.9.
whether or not the Work is fabricated, installed or completed.
Shop Drawings, Change Orders and Payments:
9.7. In connection with ENGINEER's authority as to
Shop Drawings and Samples. see paragraphs 6.'_4 through 6.28
inclusive.
9.8. In connection with ENGINEER's authority as to
Change Orders. see Articles 10. II. and 12.
9.9. In connection with ENGINEER's authonty as to
Applications for Payment. see Article 14.
Det nninations for Unit Prices:
9.10. ENGINEER will determine the actual quantities and
classifications of Unit Price Work performed by CONTRAC-
TOR. ENGINEER will review with CONTRACTOR the EN
GINEER's preliminary determinations on such matters before
rendering a written decision :hereon (by recommendation of an
Application for Payment or otherwise). ENGINEER's written
decision thereon will be finrl and binding upon OWNER and
CONTRACTOR, unless, within ten days after the dalc of any
such decision. either OWNER or CONTRACTOR delivers to
the other and to ENGINEER written notice of intention to
appeal from ENGINEER's decision and: ti) an appeal from
ENGINEER's decision is taken within the time limits and in
accordance with the procedures set forth in Exhibit GC -A.
'Dispute Resolution Agreement.' entered into between
OWNER an] CONTRACTOR pursuant to Article 16. or (iii if
no such Dispute Resolution Agreement has been entered into.
a formal proceeding is instituted by the appealing party in a
forum of competent jurisdiction to exercise such rights or
remedies as the appealing party may have with respect to
ENGINEER's decision, unless otherwise agreed in writing by
OWNER and CONTRACTOR. Such appeal will not be subject
to the procedures of paragraph 9.1 1.
Decisions on Disputes:
9.11. ENGINEER will be the initial interpreter of the
requirements of (he Contract Documents and judge of the
acceptability of the Work thereunder. Claims, disputes and
other matters relating to (he acceptability of the Work or the
interpretation of the requirements of the Contract Documents
pertaining to the performance and furnishing of the Work and
Claims under Articles II and 12 in respect of changes in the
Contract Price or Contract Times will be referred initially to
ENGINEER In writing with a request for a formal decision in
accordance with (his paragraph. Written notice of each such
claim, dispute or other matter will be delivered by the claimant
to ENGINEER and the other party to the Agreement promptly
(but in no event later than thirty days) after the start of the
occurrence or event giving rise thereto, and written supporting
data will be submitted to ENGINEER and (he other party
within sixty days after the start of such occurrence or event
unless ENGINEER allows an additional period of time for the
submission of additional or more accurate data in support of
such claim, dispute or other matter. The opposing party shall
submit any response to ENGINEER and the claimant within
thirty days after receipt of the claimant's last submittal (unless
ENGINEER allows additional time). ENGINEER will render
a formal decision in writing within thirty days after receipt of
the opposing party's submittal, if any, in accordance with this
paragraph. ENGINEER's written decision on such claim,
dispute or other matter will be final and binding upon OWNER
and CONTRACTOR unless: ti) an appeal from ENGINEER's
decision is taken within the time limits and in accordance with
the procedures set forth in EXHIBIT GC -A. "Dispute Reso-
lution Agreement." entered into between OWNER and CON-
TRACTOR pursuant to Article 16. or (ii) if no such Dispute
Resolution Agreement has been entered into, a written notice
of intention to appeal from ENGINEER's written decision is
delivered by OWNER or CONTRACTOR to the other and to
ENGINEER within thirty days after the date of such decision
and a formal proceeding is instituted by the appealing party in
a forum of competent jurisdiction to exercise such rights or
remedies as the appealing party may have with respect to such
claim, dispute or other matter in accordance with applicable
Lives and Regulations within sixty days of the date of such
decision, unless otherwise agreed in wnting by OWNER and
CONTRACTOR.
9.12. When functioning as interpreter and judge under
paragraphs 9.10 and 9.11. ENGINEER will not show partiality
to OWNER or CONTRACTOR and will not be liable in
connection with any interpretation or decision rendered in
good faith in such capacity. The rendering of a decision by
ENGINEER pursuant to paragraphs 9.10 or 9.11 with respect
to any such claim, dispute or other matter (except any which
have been waived by the making or acceptance of final
payment as provided in paragraph 14.15) will be a condition
precedent to any exercise by OWNER or CONTRACTOR of
such rights or remedies as either may otherwise have under the
Contract Documents or by Laws or Regulations in respect of
any such claim, dispute or other matter pursuant to Article 16.
9.13. lywabons on ENGINEER's Au hority and kesponsibdietr
9.13.1. Neither ENGINEER's authority or responsibil-
ity under (his Article 9 or under any other provision of the
Contract Documents nor any decision made by ENGINEER
in good faith either to exercise or not exercise such authority
or responsibility or the undertaking. exercise or performance
of any authority or responsibility by ENGINEER shall
create. impose or give rise to any duty owed by ENGINEER
to CONTR?rT C P any Subcontractor. any Supplier, any
other person or organization, or to any surety for or em-
ployee or agent of any of them.
31
I
9.I32. ENGINEER will not supervise, direct, control
or have authority over or be responsible for CONTRAC-
TOR's means, methods, techniques, sequences or proce-
dures Hof construction, or the safety precautions and pro -
grains incident thereto, or for any failure of CONTRACTOR
to comply with Laws and Regulations applicable to the
furnishing or performance of the Work. ENGINEER will not
be responsible for CONTRACTOR's failure to perform or
furnish the Work in accordance with the Contract Docu-
ments.
19.13.3. ENGINEER will not be responsible for the acts
or omissions of CONTRACTOR or of any Subcontractor.
any Supplier, or of any other person or organization perform-
ing or furnishing any of the Work.
9.13.14. ENGINEER's review of the final Application for
Payment and accompanying documentation and all mainte-
nance and operating instructions, schedules, guarantees.
bonds and certificates of inspection, tests and approvals and
Other documentation required to be delivered by paragraph
14.12 will only be to determine generally that their content
complies with the requirements of. and in the case of
certificates of inspections, tests and approvals that the
results. certified indicate compliance with, the Contract Doc-
uments,
9.13.5. The limitations upon authority and responsibility
set forth in this paragraph 9.13 shall also apply to ENGI-
NEER'�s Consultants, Resident Project Representative and
assistants.
ARTICLE 10 —CHANGES IN THE WORK
10.1. Without invalidating the Agreement and without
notice to any surety. OWNER may. at any time or from time
to time, order additions, deletions or revisions in the Work.
Such additions, deletions or revisions will be authorized by
a Written�Amendment, a Change Order, or a Work Change
Directive.I Upon receipt of anysuch document. CONTRAC-
TOR shall promptly proceed with the Work involved which
will be performed under the applicable conditions of the
Contract Documents (except as otherwise specifically pro-
vided).
10.2. If OWNER and CONTRACTOR are unable to agree
as to the extent, if any, of an adjustment in the Contract Price
or an adjustment of the Contract Times that should be allowed
as a result of a Work Change Directive, a claim may be made
therefor as provided in Article II or Article 12.
10.3. CONTRACTOR shall nor be entitled to an increase in
the Contract Price or an extension of the Contract Times with
respect to:any Work performed that is not required by the
Contract Documents as amended, modified and supplemented
as provided in paragraphs 3.5 and 3.6 except in the case of an
emergency; -as provided in paragraph 6.23 or in the case of
uncoverins Work as provided in paragraph 13.9.
10.4. OWNER and CONTRACTOR shall execute appro-
priate Change Orders recommended by ENGINEER (or Writ-
ten Amendments) covering:
10.4.1. changes in the Work which are (i) ordered by
OWNER pursuant to paragraph 10.1, (ii) required because of
acceptance of defective Work under paragraph 13.13 or
correcting defective Work under paragraph 13.14. or (iii)
agreed to by the parties:
10.4.2.
changes
in the Contract
Price or Contract Times
which
are
agreed to
by the parties;
and
10.4.3. changes in the Contract Price or Contract Times
which embody the substance of any written decision ren-
dered by ENGINEER pursuant to paragraph 9.11;
provided that, in lieu of executing any such Change Order, an
appeal may be taken from any such decision in accordance
with the provisions of the Contract Documents and applicable
Laws and Regulations, but during any such appeal. CON-
TRACTOR shall carry on the Work and adhere to the progress
schedule as provided in paragraph 6.29.
10.5. If notice of any change affecting the general scope of
the Work or the provisions of the Contract Documents (includ-
ing, but not limited to, Contract Price or Contract Times) is
required by the provisions of any Bond to be given to a surety,
the giving of any such notice will be CONTRACTOR's respon-
sibility, and the amount of each applicable Bond will be
adjusted accordingly.
Addition see SC 10.6
ARTICLE 1 I —CHANGE OF CONTRACT PRICE
11.1. The Contract Price constitutes the total compensa-
tion (subject to authorized adjustments) payable to CON-
TRACTOR for performing the Work. All duties, responsibili-
ties and obligations assigned to or undertaken by CONTRACTOR
shall be at CONTRACTOR's expense without change in the
Contract Price.
11.2. The Contract Price may only be changed by a Change
Order or by a Written Amendment. Any claim for an adjust-
ment in the Contract Price shall be based on written notice
delivered by the party making the claim to the other party and
to ENGINEER promptly (but in no event later than thirty
days) after the start of the occurrence or event giving rise to the
claim and staring the general nature of the claim. Notice of the
amount of the claim with supporting data shall be delivered
within sixty days after the start of such occurrence or event
(unless ENGINEER allows additional time for claimant to
submit additional or more accurate data in support of the claim)
and shall be accompanied by claimant's written statement that
the adjustment claimed covers all known amounts to which the
claimant is entitled as a result of said occurrence or event. All
claims for adjustment in the Contract Price shall be determined
by ENGINEER in accordance with paragraph 9.11 ifOWNER
W N ER
and CONTRACTOR cannot otherwise agree on the amount
involved. No claim for an adjustment in the Contract Price will
H
I.
I
I
I
I
1
I
I
I
I
I
32
I
I
C
I
C
I
I
I
I
I
I
I
I
I
I
be valid if not submitted in accordance with this paragraph
11.2. -
1 I.3. The value of any Work covered by a Change Order or
of any claim for an adjustment in the Contract Price will be
determined as follows:
11.3.1, where the Work involved is covered by unit
prices contained in the Contract Documents, by application
of such unit prices to the quantities of the items involved
(subject to the provisions of paragraphs 11.9.1 through
11.9.3. inclusive):
11.3.2. where the Work involved is not covered by unit
prices contained in the Contract Documents, by a mutually
agreed lump sum (which may include an allowance for
overhead and profit not necessarily in accordance with
paragraph 11.6.2):
11.3.3. where the Work involved is not covered by unit
prices contained in the Contract Documents and agreement
to a lump sum is not reached under paragraph 11.3.2. on the
basis of the Cost of the Work (determined as provided in
paragraphs 11.4 and 11.5) plus a CONTRACTOR's fee for
overhead and profit (determined as provided in paragraph
11.6).
Cost of the Work:
11.4. The term Cost of the Work means the sum of all costs
necessarily incurred and paid by CONTRACTOR in the proper
performance of the Work. Except as otherwise may be agreed
to in writing by OWNER, such costs shall be in amounts no
higher than those prevailing in the locality of the Project. shall
include only the following items and shall not include any of the
costs itemized in paragraph 11.5:
11.4.1. Payroll costs for employees in the direct employ
of CONTRACTOR in the performance of the Work under
schedules of job classifications agreed upon by OWNER and
CONTRACTOR. Such employees shall include without lim-
itation superintendents. foremen and other personnel em-
ployed full- time at the site. Payroll costs for employees not
employed full time on the Work shall be apportioned on the
basis of their time spent on the Work. Payroll costs shall
include, but not be limited to, salaries and wages plus the
cost of fringe benefits which shall include social security
contributions. unemployment, excise and payroll taxes, work-
ers' compensation, health and retirement benefits, bonuses.
sick leave. vacation and holiday pay applicable thereto. The
expenses of performing Work after regular working hours.
on Saturday. Sunday or legal holidays, shall be included in
the above to the extent authorized by OWNER.
11.4.2. Cost of all materials and equipment furnished and
incorporated in the Work, including costs of transportation
and storage thereof, and Suppliers' field services required in
connection therewith. All cash discounts shall accrue :c
CONTRACTOR unless OWNER deposits funds with CON-
TRACTOR with which to make payments, in which case the
cash discounts shall accrue to OWNER. All trade discounts.
rebates and refunds and returns from sale of surplus materi-
als and equipment shall accrue to OWNER, and CON-
TRACTOR shall make provisions so that they may be
obtained.
11.4.3. Payments made by CONTRACTOR to the Sub-
contractors for Work performed or furnished by Subcontrac-
tors. If required by OWNER. COM1TRACTDR shall obtain
competitive bids from subcontractors acceptable to OWNER
and CONTRACTOR and shall deliver such bids to OWNER
who will then determine, with the advice of ENGINEER.
which bids, if any. will be accepted. If any subcontract
provides that the Subcontractor is to be paid on the basis of
Cost of the Work Pius a fee, the Subcontractor's Cost of the
Work and fee shall be determined in the same manner as
CONTRACTOR's Cost of the Work and fee as provided in
paragraphs 11.4. 11.5. 11.6 and 11.7. All subcontracts shall
be subject to the other provisions of the Contract Documents
insofar as applicable.
11.4.4. Costs of special consultants (including but not
limited to engineers, architects, testing laboratories. survey-
ors. attorneys and accountants) employed for services spe-
cifically related to the Work.
11.4.5. Supplemental costs including the following:
11.4.5.1. The proportion of necessary transportation.
travel and subsistence expenses of C0NTRACTOR's em-
ployees incurred in discharge of duties connected with the
Work.
11.4.5.2. Cost, including transportation and mainte-
nance, of all materials, supplies. equipment, machinery.
appliances, office and temporary facilities at the site and
hand tools not owned by the workers, which are con-
sumed in the performance of the Work, and cos: less
market value of such items used but not consumed which
remain the property of CONTRACTOR.
11.4.5.3. Rentals of all construction equipment and
machinery and the parts thereof whether rented from
CON I KAL juRor others in accordance with rental agree-
ments approved by OWNER with the advice of ENGI-
NEER. and the costs of transportation, loading. unload-
ing, installation, dismantling and removal thereof all in
accordance with the terms of said rental agreements. The
rental of any such equipment, machinery or parts shall
cease when the use thereof is no longer necessary for the
Work.
11.4.5.4. Sales, consumer, use or similar taxes related
to the Work, and for which CONTRACTOR is liable,
imposed by Laws and Regulations.
11.4.5.5. Deposits lost for causes other than negli-
gence of CONTRACTOR, any Subcontractor or anyone
directly or indirectly employed by any of them or for
t- hose acts any of them may be liable, and royalty
payments and fees for permits and licenses.
' 33
I
I1:4.5.6. Losses and damages (and related expenses)
caused by damage to the Work, not compensated by
insurance or otherwise, -sustained by CONTRACTOR in
connection with the performance and furnishing of the
Work (except losses and damages within the deductible
amounts of property insurance established by OWNER in
accordance with paragraph 5.9). provided they have re-
sulted from causes other than the negligence of CON-
TRACTOR, any Subcontractor, or anyone directly or
indirectly employed by any of them or for whose acts any
of them may be liable. Such losses shall include settle-
ments made with the written consent and approval of
OWNER. No such losses, damages and expenses shall be
included in the Cost of the Work for the purpose of
determining CONTRACTOR's fee. If, however, any such
loss or damage requires reconstruction and CONTRAC-
TOR is placed in charge thereof, CONTRACTOR shall be
paid for services a fee proportionate to that stated in
paragraph 11.6.2.
11.4.5.7. The cost of utilities, fuel and sanitary facili-
ties at the site.
11.4.5.8. Minor expenses such as telegrams, long dis-
tance�telephone calls, telephone service at the site, ex-
pressage and similar petty cash items in connection with
the Work.
Ii
11.4.5.9. Cost of premiums for additional Bonds and
insurance required because of changes in the Work.
11.5. The term Cost of the Work shall not include any of
the following:
11.5.1. Payroll costs and other compensation of CON-
TRACTOR's officers, executives, principals (of partnership
and sole Iproprietorships), general managers, engineers. ar-
chitects,iestimator . attorneys, auditors, accountants, pur-
chasing and contracting agents, expediters. timekeepers.
clerks and other personnel employed by CONTRACTOR
whether at the site or in CONTRACTOR's principal or a
branch office for general administration of the Work and not
specifically included in the agreed upon schedule of job
classifications referred to in paragraph 11.4.1 or specifically
covered by paragraph 11.4.4 —all of which are to be consid-
ered administrative costs covered by the CONTRACTOR's
fee.
11.5.2.1 Expenses of CONTRACTOR's principal and
branch offices other than CONTRACTOR's office at the site.
11.5.3. j Any part of CONTRACTOR's capital expenses,
including interest on CONTRACTOR's capital employed for
the WorkI and charges against CONTRACTOR for delin-
quent payments.
.11.5.4.1 Cost of premiums for all Bonds and for all
insurance whether or not CONTRACTOR is required by the
Contract Documents to purchase and maintain the same
(except for the cost of premiums covered by subparagraph
11.4.5.9 above).
11.5.5. Costs due to the negligence of CONTRAC-
TOR, any Subcontractor, or anyone directly or indi-
rectly employed by any of them or for whose acts any
of them may be liable, including but not limited to, the
correction of defective Work, disposal of materials or
equipment wrongly supplied and making good any
damage to property.
Other overhead orgeneral expense costs of any kind
and the costs of any item not specifically and expressly
included in paragraph 11.4.
11.6. The CONTRACTOR's fee allowed to CONTRAC-
TOR for overhead and profit shall be determined as follows:
L
I
I
11.6.1. a mutually acceptable fixed fee; or I
11.6.2. if a fixed fee is not agreed upon, then a fee
based on the following percentages of the various
portions of the Cost of the Work:
11.6.2.1. for costs incurred under paragraphs 11.4.1
and 11.4.2. the CONTRACTOR's fee shall be fifteen
percent;
I
I
11.6.2.2. for costs
incurred
under
paragraph 11.4.3,
the CONTRACTOR's
fee shall
be five
percent;
11.6.2.3. where one or more tiers of subcontracts are
on the basis of Cost of the Work plus a fee and no fixed fee
is agreed upon, the intent of paragraphs 11.4.1, 11.4.2,
11.4.3 and 11.6.2 is that the Subcontractor who actually
performs or furnishes the Work, at whatever tier, will be
paid a fee of fifteen percent of the costs incurred by such
Subcontractor under paragraphs 11.4.1 and 11.4.2 and that
any higher tier Subcontractor and CONTRACTOR will
each be paid a fee of five percent of the amount paid to the
next lower tier Subcontractor;
11.6.2.4.
no
fee shall be
payable
on
the basis of costs
itemized
under
paragraphs 11.4.4.
11.4.5
and 11.5;
11.6.2.5. the amount of credit to be allowed by CON-
TRACTOR to OWNER for any change which results in a
net decrease in cost will be the amount of the actual net
decrease in cost plus a deduction in CONTRACTOR's fee
by an amount equal to five percent of such net decrease:
and
11.6.2.6. when both additions and credits are involved
in any one change, the adjustment in CONTRACTOR's
fee shall be computed on the basis of the net change in
accordance with paragraphs 11.6.2.1 through 11.6.2.5,
inclusive.
11.7. Whenever the cost of any Work is to be determined
pursuant to paragraphs 11.4 and 11.5, CONTRACTOR will
establish and maintain records thereof in accordance with
generally accepted accounting practices and submit in form
acceptable to ENGINEER an itemized cost breakdown to-
gether with supporting data.
11
H
I
I
I
I
L
H
L
I
I
Li
I
I
C
I
F
I
I
I
IH
Cash Allowances:
11.8. It is understood that CONTRACTOR has included in
(he Contract Price all allowances so named in the Contract
Documents and shall cause the Work so covered to be fur-
nished and performed for such sums as may be acceptable to
OWNER and ENGINEER. CONTRACTOR agrees that:
11.8.1. the allowances include the cost to CONTRAC-
TOR (less any applicable trade discounts) of materials and
equipment required by the allowances to be delivered at the
site, and all applicable taxes: and
11.8.2. CONTRACTOR's costs for unloading and han-
dling on the site, labor, installation costs, overhead, profit
and other expenses contemplated for the allowances have
been included in the Contract Price and not in the allowances
and no demand for additional payment on account of any of
the foregoing will be valid.
Prior to final payment, an appropriate Change Order will be
issued as recommended by ENGINEER to reflect actual
amounts due CONTRACTOR on account of Work covered by
allowances. and the Contract Price shall be cortesponding)y
adjusted.
d
a-
11.9. Unit Price Work:
11.9.1. Where the Contract Documents provide that all
or part of the Work is to be Unit Price Work. initially the
Contract Price will be deemed to include for all Unit Price
Work an amount equal to the sum of the established unit
price for each separately identified item of Unit Price Work
times the estimated quantity of each item as indicated in the
Agreement. The estimated quantities of items of Unit Price
Work arc not guaranteed and arc solely for the purpose or
comparison of Bids and determining an initial Contract
Price. Determinations of the actual quantities and classifica-
tions of Unit Price Work performed by CONTRACTOR will
be made by ENGINEER in accordance with paragraph 9.10.
11.9.2. Each unit price will be deemed to include an
amount considered by CONTRACTOR to be adequate to
cover CONTRACTOR's overhead and profit for each sepa-
rately identified item.
Replace 11.93 with SC 11.9.3
11.9.3. OWNER or CONTRACTOR may make a claim
for an adjustment in the Contract Price in accordance with
Article II if:
11.9.3.1. the quantity of any item of Unit Price Work
performed by CONTRACTOR differs materially and sig-
nificantly from the estimated quantity of such item indi-
cated in the Agreement: and
11.9.3.2.
there is
no
corresponding
adjustment with
respect
to
any other
item
of Work: and
11.9.3.3. if CONTRACTOR believes that CONTRAC-
TOR is entitled to an increase in Contract Price as a result
of having incurred additional expense or OWNER be-
lieves that OWNER is entitled to a decrease in Contract
Price and the panics are unable to agree as to the amount
of any such increase or decrease.
ARTICLE 12 —CHANGE OF CONTRACT TIMES
12.1. The Contract Times (or Milestones) may only be
changed by a Change Order or a Written Amendment. Any
claim for an adjustment of the Contract Times (or Milestones)
shall be based on written notice delivered by the party making
the claim to the other party and to ENGINEER promptly (but
in no event later than thirty days) after the occurrence of the
event giving rise to the claim and stating the general nature of
the claim. Notice of the extent of the claim with supporting
data shall be delivered within sixty'days after such occurrence
(unless ENGINEER allows an additional period of time to
ascertain more accurate data in support of the claim) and shall
be accompanied by the claimant's written statement that the
adjustment claimed is the entire adjustment to which the
claimant has reason to believe it is entitled as a result of the
occurrence of said event. All claims for adjustment in the
Contract Times (or Milestones) shall be determined by ENGI-
NEER in accordance with paragraph 9.11 if OWNER and
CONTRACTOR cannot otherwise agree. No claim for an
adjustment in the Contract Times (or Milestones) will be valid
if not submitted in accordance with the requirements of this
paragraph 12.1.
12.2. All time limits stated in the Contract Documents arc
of the essence of the Agreement.
12.3. Where CONTRACTOR is prevented from complet-
ing any part of the Work within the Contract Times (or
Milestones) due to delay beyond the control of CONTRAC-
TOR. the Contract Times (or Milestones) will be extended in an
amount equal to the time lost due to such delay if a claim is
made therefor as provided in paragraph 12.1. Delays beyond
the control of CONTRACTOR shall include, but not be limited
to. acts or neglect by OWNER, acts or neglect of utility owners
or other contractors performing other work as contemplated by
Article 7. fires, floods. epidemics, abnormal weather condi-
tions or acts of God. Delays anributable to and within the
control of a Subcontractor or Supplier shall be deemed to be
delays within the control of CONRACIOR.
12.4. Where CONTRACTOR is prevented from complet-
ing any pan of the Work within the Contract Times (or
Milestones) due to delay beyond the control of both OWNER
and CONTRACTOR, an extension of the Contract Times (or
Milestones) in an amount equal to the time lost due to such
delay shall be C0NTRACTOR's sole and exclusive remedy for
such delay. In no event shall OWNER be liable to CONTRAC-
TOR, any Subcontractor, any Supplier, any other person or
organization- or to any surety for or employee or agent of any
of them, for damages arising out of or resulting from (i) delays
caused by or within the control of CONTRACTOR. or (ii)
' 35
delay's beyond the control of both parties including but not
limited to fires, floods, epidemics. abnormal weather condi-
tions acts of God or acts or neglect by utility owners or
otherIcontractors performing other work as contemplated by
Article 7.
ARTICLE 13 —TESTS AND INSPECTIONS;
CORRECTION. REMOVAL OR
ACCEPTANCE OF DEFECTIVE WORK
13.1. Notice of Defects: Prompt notice of all defective
Work'of which OWNER -or ENGINEER have actual knowl-
edge will be given to CONTRACTOR. All defective Work
may be rejected. corrected or accepted as provided in this
Article 13.
Access to Work
I a
13.2' OWNER, ENGINEER. ENGINEER's Consultants,
other i-eprcsentatives and personnel of OWNER, independent
testing laboratories and governmental agencies with jurisdic-
tional interests will have access to the Work at reasonable times
for their observation, inspecting and testing. CONTRACTOR
shall provide them proper and safe conditions for such access
and advise them of CONTRACTOR's site safety procedures
and programs so that they may comply therewith as applicable.
Tests and Inspections:
I
13.3. CONTRACTOR shall give ENGINEER timely no-
tice of readiness of the Work for all required inspections, tests
or approvals. and shall cuopemte with inspection and testing
personnel to facilitate required inspections or tests.
Replacement with SC 13.3
13.4. OWNER shall employ and pay for the services of an
independent testing laboratory to perform all inspections, tests.
or approvals required by the Contract Documents except:
Replacement with SC 13.4
13.4.1. for inspections, tests or approvals covered by
paragraph 13.5 below:
13.4.2. that costs incurred in connection with tests or
inspections conducted pursuant to paragraph 13.9 below
shall be paid as provided in said paragraph 13.9: and
• 13.4.3. as otherwise specifically provided in the Con-
tract Documents.
13.5. If Laws or Regulations of any public body having
jurisdiction require any Work (or pan thereof] specifically to be
inspected, tested or approved by an employee or other repre-
sentative of such public body- CONTRACTOR shall assume
full responsibility for arranging and obtaining such inspections,
tests or approvals, pay all costs in connection therewith, and
furnish ENGINEER the required certificates of inspection, or
approval. CONTRACTOR shall also be responsible for arrang-
ing and obtaining and shall pay all costs in connection with any
inspections, tests or approvals required for OWNER's and
ENGINEER's acceptance of materials or equipment to be
incorporated in the Work, or of materials, mix designs, or
equipment submitted for approval prior to CONTRACTOR's
purchase thereof for incorporation in the Work.
13.6. If any Work (or the work of others) that is to be
inspected, tested or approved is covered by CONTRACTOR
without written concurrence of ENGINEER, it must, if re-
quested by ENGINEER. be. uncovered for observation.
13.7. Uncovering Work as provided in paragraph 13.6 shall
be at CONTRACTOR's expense unless CONTRACTOR has
given ENGINEER timely notice of CONTRACTOR's inten-
tion to cover the same and ENGINEER has not acted with
reasonable promptness in response to such notice.
Uncovering /cork:
13.8. If any Work is covered contrary to the written request
of ENGINEER, it must. if requested by ENGINEER, be
uncovered for ENGINEER's observation and replaced at
CONTRACTOR's expense.
13.9. If ENGINEER considers it necessary or advisable
that covered Work be observed by ENGINEER or inspected
or tested by others, CONTRACTOR, at ENGINEER's re-
quest, shall uncover, expose or otherwise make available for
observation, inspection or testing as ENGINEER may require.
that portion of the Work in question, furnishing all necessary
labor, material and equipment. If it is found that such Work is
defective, CONTRACTOR shall pay all claims, costs, losses
and damages caused by, arising out of or resulting from such
uncovering, exposure, observation, inspection and testing and
of satisfactory replacement or reconstruction (including but not
limited to all costs of repair or replacement of work of others);
and OWNER shall be entitled to an appropriate decrease in the
Contract Price. and, if the panics are unable 'to agree as to the
amount thereof. may make a claim therefor as provided in
Article II. If. however, such Work is not found to be defective.
CONTRACTOR shall be allowed an increase in the Contract
Price or an extension of the Contract Times (or Milestones). or
both, directly attributable to such uncovering, exposure, ob-
servation. inspection, testing. replacement and reconstruction:
and, if the parties are unable to agree as to the amount or extent
thereof. CONTRACTOR may make a claim therefor as pro-
vided in Articles II and 12.
OWNER May Stop the Work:
13.10. If the Work is defective, or CONTRACTOR fails to
supply sufficient skilled workers or suitable materials or equip-
ment, or fails to furnish or perform the Work in such a way that
the completed Work will conform to the Contract Documents.
OWNER may order CONTRACTOR to stop the Work, or any
portion thereof, until the cause for such order has been
eliminated: however, this right of OWNER to stop the Work
I
I
11
I
I
I
I
I
I
I
I
I
36
I
1l
1
1
El
[1
I
I
H
I
H
I
I
I
I
7
shall not give rise to any duty on the part of OWNER to
exercise this right for the benefit of CONTRACTOR or any
surety or other party.
Correction or Renwwl of Defective Work:
13.11. If required by ENGINEER. CONTRACTOR shall
promptly, as directed. either correct all defective Work, whether
or not fabricated. installed or completed, or. if the Work has
been rejected by ENGINEER, remove it from the site and
replace it with Work that is not defective. CONTRACTOR shall
pay all claims, costs, losses and damages caused by or resulting
from such correction or removal (including but not limited to all
costs of repair or replacement of work of others).
13.)2. Correction Prriod'
13.12.1. If within one year alter the date of Substantial
Completion or such longer period of time as may be pre-
scribed by Laws or Regulations or by the terms of any
applicable special guarantee required by the Contract Doc-
uments or by any specific provision of the Contract Docu-
ments. any Work is found to be defective. CONTRACTOR
shall promptly. without cost to OWNER and in accordance
•.iith OWNER's written instructions: (i) correct such defec-
tive Work, or. if it has been rejected by OWNER, remove it
from the site and replace it with Work that is not defective.
and (ii) satisfactorily correct or remove and replace any
damage to other Work or the work of others resulting
therefrom. If CONTRACTOR does not promptly comply
with the terms of such instructions, or in an emergency
where delay would cause serious risk of loss or damage.
OWNER may have the defective Work corrected or the
rejected Work removed and replaced. and all claims, costs.
losses and damages caused by or resulting from such re-
moval and replacement (including but not limited to all costs
of repair or replacement of work of others) will be paid by
CONTRACTOR.
13.12.2. In special circumstances where a particular item
of equipment is placed in continuous service before Substan-
tial Completion of all the Work, the correction period for that
item may start to run from an earlier date if so provided in
the Specifications or by Written Amendment.
13.12.3. Where defective Work (and damage to other
Work resulting therefrom) has been corected, removed or
replaced under this paragraph 13.12, the correction period
hereunder with respect to such Work will be extended for an
additional period of one year after such correction or re-
movai and replacement has been satisfactorily completed.
Accepmnce of Defective Woe*:
13.13. If, instead of requiring correction or removal and
recommendation
of defective Work. OWNER (and. prior to ENGI-
NEER's of final payment. also ENGINEER)
prefers to accept it. OWNER may do so. CONTRACTOR shall
pay all claims, costs. losses and damages attributable to
OWNER's evaluation of and determination to accept such
defective Work (such costs to be approved by ENGINEER as
to reasonableness). If any such acceptance occurs prior to
ENGINEER's recommendation of final payment. a Change
Order will be issued incorporating the necessary revisions in
the Contract Documents with respect tothe Work: and OWNER
shall be entitled to an appropriate decrease in the Contract
Price, and, if the panics are unable to agree as to the amount
thereof. OWNER may make a claim therefor as provided in
Article II. If the acceptance occurs after such recommenda-
tion, an appropriate amount will be paid by CONTRACTOR to
OWNER.
OWNER May Correct Defective Work:
13.14. If CONTRACTOR fails within a reasonable time
after written notice from ENGINEER to correct defective
Work or to remove and replace rejected Work as required by
ENGINEER in accordance with paragraph 13.11, or if CON-
TRACTOR fails to perform the Work in accordance with the
Contract Documents, or if CONTRACTOR fails to comply
with any other provision of the Contract Documents. OWNER
may. after seven days' written notice to CONTRACTOR.
correct and remedy any such deficiency. In exercising the
rights and remedies under this paragraph OWNER shall pro-
ceed expeditiously. In connection with such corrective and
remedial action, OWNER may exclude CONTRACTOR from
all or pan of the site, take possession of all or part of the Work.
and suspend CONTRACTOR'S services related thereto, take
possession of CONTRACTOR's tools, appliances, construc-
tion equipment and machinery at the site and incorporate in the
Work all materials and equipment stored at the site or for which
OWNER has paid CONTRACTOR' but which are stored
elsewhere. CONTRACTOR shall allow OWNER. OWNER's
representatives, agents and employees, OWNER's other con-
tractors and ENGINEER and ENGINEER's Consultants ac•
cess to the site to enable OWNER to exercise the rights and
remedies under this paragraph. All claims, costs. losses and
damages incurred or sustained by OWNER in exercising such
nghts and remedies will be charged against CONTRACTOR
and a Change Order will be issued incorporating the necessary
revisions in the Contract Documents with respect to the Work:
and OWNER shall be entitled to an appropriate decrease in the
Contract Price. and• if the panics are unable to agree as to the
amount thereof. OWNER may make a claim therefor as
provided in Article II. Such claims, costs, losses and damages
will include but not be limited to all costs of repair or replace-
ment of work of others destroyed or damaged by correction.
removal or replacement of CON TRACIOR's defective Work.
CONTRACTOR shall not be allowed an extension of the
Contract Times (or Milestones) because of any delay in the
performance of the Work attributable to the exercise byOWNER
W N E R
of OWNER's rights and remedies hereunder.
ARTICLE 14 —PAYMENTS TO CONTRACTOR AND
COMPLETION
Schedule of Value,:
14.1. The schedule of values established as provided in
paragraph 2.9 will serve as the basis for progress payments and
1 37
I
will be incorporated into a form of Application for Payment
acceptable to ENGINEER. Progress payments on account of
Unit Price Work will be based on the number of units com-
pleted.
Application for Progress Payment:
Replacement with SC 14.2
14._. At least twenty days before the date established for
each progress payment (but not more often than once a
month), CONTRACTOR shall submit to ENGINEER for
review an' Application for Payment filled out and signed by
CONTRACTOR covering the Work completed as of the date
of the Application and accompanied by such supporting
documentation as is required by the Contract Documents. If
payment is requested on the basis of materials and equip-
ment not incorporated in the Work but delivered and suitably
stored at the site or at another location agreed to in writing,
the Application for Payment shall also be accompanied by a
bill of sale, invoice or other documentation warranting that
OWNER has received the materials and equipment free and
clear of all Liens and evidence that the materials and
equipment are covered by appropriate property insurance
and other arrangements to protect OWNER's interest therein.
all of which will be satisfactory to OWNER. The amount of
retainage:with respect to progress payments will be as
stipulated in the Agreement.
COATRAC 19R's Warranty of Tide:
14.3. CONTRACTOR warrants and guarantees that title to
all Work, materials and equipment covered by any Application
for Payment, whether incorporated in the Project or not, will
pass to OWNER no later than the time of payment free and
clear of all!Liens.
Review of Applications for Progress Payment:
Revision see SC 14.4
14.4. ENGINEER will, within ten days after receipt of
each Application for Payment, either indicate in writing a
recommendation of payment and present the Application to
OWNER. or return the Application to CONTRACTOR indi-
cating in writing ENGINEER's reasons for refusing to recom-
mend payment. In the latter case. CONTRACTOR may make
the necessary corrections and resubmit the Application. Ten
days after presentation of the Application for Payment to
OWNER with ENGINEER's recommendation, the amount
recommended will (subject to the provisions of the last sen-
tence of paragraph 14.7) become due and when due will be paid
by OWNER to CONTRACTOR.
14.5. ENGINEER's recommendation of any payment re-
quested in an Application for Payment will constitute a repre-
sentation b ENGINEER to OWNER, based on ENGINEER'S
on -site observations of the executed Work as an experienced
and qualified design professional and on ENGINEER's review
of the Application for Payment and the accompanying data and
schedules, that to the best of ENGINEER's knowledge, infor-
mation and:belief:
14.5.1. the Work has progressed to the point indicated,
14.5.2. the quality of the Work is generally in accor-
dance with the Contract Documents (subject to an evalu-
ation of the Work as a functioning whole prior to or upon
Substantial Completion, to the results of any subsequent
tests called for in the Contract Documents, to a final
determination of quantities and classifications for Unit
Price Work under paragraph 9.10. and to any other quali-
fications stated in the recommendation). and
14.5.3. the conditions precedent to CONTRACTOR's
being entitled to such payment appear to have been
fulfilled in so far as it is ENGINEER's responsibility to
observe the Work.
However, by recommending any such payment ENGINEER
will not thereby be deemed to have represented that: (i)
exhaustive or continuous on -site inspections have been made
to check the quality or the quantity of the Work beyond the
responsibilities specifically assigned to ENGINEER in the
Contract Documents or (ii) that there may not be other matters
or issues between the parties that might entitle CONTRAC-
TOR to be paid additionally by OWNER or entitle OWNER to
withhold payment to CONTRACTOR.
14.6. ENGINEER's recommendation of any payment, in-
cluding final payment, shall not mean that ENGINEER is
responsible for CONTRACTOR'S means, methods, techniques.
sequences or procedures of construction, or the safety precau-
tions and programs incident thereto, or for any failure of
CONTRACTOR to comply with Laws and Regulations appli-
cable to the furnishing or performance of Work, or for any
failure of CONTRACTOR to perform or furnish Work in
accordance with the Contract Documents.
14.7. ENGINEER may refuse to recommend the whole or
any part of any payment if. in ENGINEER's opinion, it would
be incorrect to make the representations to OWNER referred
to in paragraph 14.5. ENGINEER may also refuse to recom-
mend any such payment, or. because of subsequently discov-
ered evidence or the results of subsequent inspections or tests.
nullify any such payment previously recommended, to such
extent as may be necessary in ENGINEER's opinion to
protect OWNER from loss because: .
14.7.1. the Work is defective, or completed Work has
been damaged requiring correction or replacement.
14.7.?. the Contract Price has been reduced by Writ-
ten Amendment or Change Order,
14.7.3. OWNER has been required to correct defec-
tit•e Work or complete Work in accordance with paragraph
13.14. or
14.7.4. ENGINEER has actual knowledge of the oc-
currence of any of the events enumerated in paragraphs
15.2.1 through 15.2.4 inclusive.
OWNER may refuse to make payment of the full amount
recommended by ENGINEER because:
14.7.5. claims have been made against OWNER on
account of CONTRACTORS performance or furnishing of
the Work.
I
I
[1
I
I
I
LII
I
I
I
I
I
I
I
L
I
I
I
lJ
I
I
I
I
7
I
ri
H
I
14.7.6. Liens have been filed in connection with the
Work. except where- CONTRACTOR has delivered a
specific Bond satisfactory to OWNER to secure the
satisfaction and discharge of such Liens,
14.7.7. there are other items entitling OWNER to a
set-off against the amount recommended, or
14.7.8. OWNER has actual knowledge of the occur-
rence of any of the events enumerated in paragraphs
14.7.1 through 14.7.3 or paragraphs 15.2.1 through 15.2.4
inclusive:
but OWNER must give CONTRACTOR immediate written
notice (with a copy to ENGINEER) stating the reasons for
such action and promptly pay CONTRACTOR the amount so
withheld, or any adjustment thereto agreed to by OWNER and
CONTRACTOR, when CONTRACTOR corrects to OWN -
ER's satisfaction the reasons for such action.
Substannd Completion:
14.8. When CONTRACTOR considers the entire Work
readyfor its intended use CONTRACTOR shall notify OWNER
and ENGINEER in writing that the entire Work is substantially
complete (except for items specifically listed by CONTRAC-
TOR as incomplete) and request that ENGINEER issue a
certificate of Substantial Completion. Within a reasonable time
thereafter. OWNER. CONTRACTOR and ENGINEER shall
make an inspection of the Work to determine the status of
completion. If ENGINEER does not consider the Work sub-
stantially complete. ENGINEER will notify CONTRACTOR
in writing giving the reasons therefor. If ENGINEER considers
the Work substantially complete. ENGINEER will prepare and
deliver to OWNER a tentative certificate of Substantial Com-
pletion which shall fix the date of Substantial Completion.
There shall be attached to the certificate a tentative list of items
to be completed or corrected before final payment. OWNER
shall have seven days after receipt of the tentative certificate
during which to make written objection to ENGINEER as to
any provisions of the certificate or attached list. If. after
considering such objections. ENGINEER concludes that the
Work is not substantially complete. ENGINEER will within
fourteen days after submission of the tentative certificate to
OWNER notify CONTRACTOR in writing, stating the reasons
therefor. If. after consideration of OWNER's objections. EN-
GINEER considers the Work substantially complete. ENGI-
NEER will within said fourteen days execute and deliver to
OWNER and CONTRACTOR a definitive certificate of Sub-
stantial Completion (with a revised tentative list of items to be
completed or corrected) reflecting such changes from the
tentative certificate as ENGINEER believes justified after
consideration of any objections from OWNER. At the time of
delivery of the tentative certificate of Substantial Completion
ENGINEER will deliver to OWNER and CONTRACTOR a
written recommendation as to division of responsibilities pend-
ing final payment between OWNER and CONTRACTOR with
respect to security, operation. safety. maintenance, heat. utili-
ties. insurance and warranties and guarantees. Unless OWNER
and CONTRACTOR agree otherwise in writing and so inform
ENGINEER in writing prior to ENGINEER's issuing the
definitive certificate of Substantial Completion. ENGINEER's
aforesaid recommendation will be binding on OWNER and
CONTRACTOR until final payment.
14.9. OWNER shall have the right to exclude CONTRAC-
TOR from the Work after the date of Substantial Completion.
but OWNER shall allow CONTRACTOR reasonable access to
complete or correct items on the tentative list.
Ftrthal Utilization:
14.10. Use by OWNER at OWNER's option of any sub-
stantially completed part of the Work which: li) has specifically
been identified in the Contract Documents, or (ii) OWNER.
ENGINEER and CONTRACTOR agree constitutes a sepa-
rately functioning and usable part of the Work that can be used
by OWNER for its intended purpose without significant inter-
ference with CONTRACTOR's performance of the remainder
of the Work, may be accomplished prior to Substantial Com-
pletion of all the Work subject to the following:
14.10.1. OWNER at any time may request CON-
TRACTOR in writing to permit OWNER to use any such
pan of the Work which OWNER believes to be ready for
its intended use and substantially complete. If CON-
TRACTOR agrees that such part of the Work is substan-
tially complete. CONTRACTOR will certify to OWNER
and ENGINEER that such pan of he Work is substan-
tially complete and request ENGINEER to issue a certif-
icate of Substantial Completion for that part of the Work.
CONTRACTOR at any time may notify OWNER and
ENGINEER in writing that CONTRACTOR considers
any such part of the Work ready for its intended use and
substantially complete and request ENGINEER to issue a
certificate of Substantial Completion for that pan of the
Work. Within a reasonable time after either such request.
OWNER. CONTRACTOR and ENGINEER shall make
an inspection of that part of the Work to determine its
status of completion. If ENGINEER does not consider
that pan of the Work to be substantially complete. ENGI-
NEER will notify OWNER and CONTRACTOR in writ-
ing giving the reasons therefor. If ENGINEER considers
that pan of the Work to be substantially complete. the
provisions of paragraphs 14.8 and 14.9 will apply with
respect to certification of Substantial Completion of that
part of the Work and the division of responsibility in
respect thereof and access thereto.
14.10.2. No occupancy or separate operation of part
of the Work will be accomplished prior to compliance with
the requirements of paragraph 5.15 in respect of property
insurance.
Final Inspection:
14.11. Upon written notice from CONTRACTOR that the
entire Work or an agreed portion thereof is complete. ENGI-
NEER will make a final inspection with OWNER and CON-
TRACTOR and will notify CONTRACTOR in writing of all
I
39
I
particulars in which this inspection reveals that the Work is
incomplete or defective. CONTRACTOR shall immediately
take such measures as are -necessary to complete such Work or
remedy such deficiencies.
Final Appfic. ton for Payment
14.12. After CONTRACTOR has completed all such cor-
rections to the satisfaction of ENGINEER and delivered in
accordance with the Contract Documents all maintenance and
operating instructions, schedules, guarantees. Bonds. certifi-
cates or other evidence of insurance required by paragraph 5.4.
certificates of inspection, marked -up record documents (as
provided in paragraph 6.19) and other documents. CONTRAC-
TOR may make application for final payment following the
procedure for progress payments. The final Application for
Payment shall be accompanied (except as previously delivered)
by: (i) all documentation called for in the Contract Documents.
including but not limited to the evidence of insurance required
by subparagraph 5.4.13. (ii) consent of the surety. if any. to final.
payment, and (iii) complete and legally effective releases or
waivers (satisfactory to OWNER) of all Liens arising out of or
filed in connection with the Work. In lieu of such releases or
waivers of Liens and as approved by OWNER. CONTRAC-
TOR may furnish receipts or releases in full and an affidavit of
CONTRACTOR that: (i) the releases and receipts include all
labor.:services, material and equipment for which a Lien could
be filed, and (ii) all payrolls, material and equipment bills and
other indebtedness connected with the Work for which O W N ER
or OWNER's property might in any way be responsible have
been paid or otherwise satisfied. If any Subcontractor or
Supplier fails to furnish such a release or receipt in full.
CONTRACTOR may furnish a Bond or other collateral satis-
factory to OWNER to indemnify OWNER against any Lien.
Final Payment and Acceptance:
14.13. If, on the basis of ENGINEER's observation of the
Work during construction and final inspection, and ENGI-
NEER'S review of the final Application for Payment and
accompanying documentation as required by the Contract
Documents, ENGINEER is satisfied that the Work has been
completed and CONTRACTOR's other obligations under the
Contract Documents have been fulfilled. ENGINEER will.
within ten days after receipt of the final Application for
Payment. indicate in writing ENGINEER's recommendation
of payment and present the Application to OWNER for pay-
ment. At the same time ENGINEER will also give written
notice to OWNER and CONTRACTOR that the Work is
acceptable subject to the provisions of paragraph 14.15. Oth-
erwise.' ENGINEER will return the Application to CON-
TRACTOR, indicating in writing the reasons for refusing to
recommend final payment, in which case CONTRACTOR shall
make the necessary corrections and resubmit the Application.
Thirty days after the presentation to OWNER of the Applica-
tion and accompanying documentation, in appropriate form
and substance and with ENGINEER'S recommendation and
notice of acceptability, the amount recommended b ENGI-
NEER will become due and will be paid by OWNER to
CONTRACTOR.
14.14. If. through no fault of CONTRACTOR. final com-
pletion of the Work is significantly delayed and if ENGINEER
so confirms. OWNER shall, upon receipt of CONTRACTOR's
final Application for Payment and recommendation of ENGI-
NEER. and without terminating the Agreement. make pay-
ment of the balance due for that portion of the Work fully
completed and accepted. If the remaining balance to be held by
OWNER for Work not fully completed or corrected is less than
the retainage stipulated in the Agreement. and if Bonds have
been furnished as required in paragraph 5.1. the written con-
sent of the surety to the payment of the balance due for that
portion of the Work fully completed and accepted shall he
submitted by CONTRACTOR to ENGINEER with the Appli-
cation for such payment. Such payment shall he made under
the terms and conditions governing final payment. except that
it shall not constitute a waiver of claims.
Waiver of Claims:
14.15. The making and acceptance of final payment will
constitute:
14.15.1. a waiver of all claims by OWNER against
CONTRACTOR. except claims arising from unsettled Liens.
from defective Work appearing after final inspection pursu-
ant to paragraph 14.11. from failure to comply with the
Contract Documents or the terms of any special guarantees
specified therein, or from CONTRACTOR's continuing ob-
ligations under the Contract Documents: and
14.15.2. a waiver of all claims by CONTRACTOR against
OWNER other than those previously made in writing and
still unsettled.
ARTICLE 15 —SUSPENSION OF WORK AND
TERMINATION
OWNER May Suspend Work:
15.1. At any time and without cause. OWNER may sus-
pend the Work or any portion thereof for a period of not more
than ninety days by notice in writing to CONTRACTOR and
ENGINEER which will fix the date on which Work will he
resumed. CONTRACTOR shall resume the Work on the date
so fixed. CONTRACTOR shall be allowed an adjustment in the
Contract Price or an extension of the Contract Times, or both.
directly attributable to any such suspension if CONTRACTOR
makes an approved claim therefor as provided in Articles II
and 12.
OWNER May Terminate:
15 2. Upon the occurrence of any one or more of the
following events:
I
I
I
I
I
I
I
I
I
I
I
I
I
I
H
I
I
I
C
I
I
I
I
I
El
H
H
J
IJ
I
15.2.1. if CONTRACTOR persistently fails to perform
the Work in accordance with the Contract Documents (in-
cluding. but not limited to. failure to supply sufficient skilled
workers or suitable materials or equipment or failure to
adhere to the progress schedule established under paragraph
2.9 as adjusted from time to time pursuant to paragraph 6.6):
15.2.2. if CONTRACTOR disregards Laws or Regula-
tions of any public body having jurisdiction:
15.2.2. if CONTRACTOR disregards the authority of
ENGINEER: or
15.2.4. if CONTRACTOR otherwise violates in any sub-
stantial way any provisions of the Contract Documents:
OWNER may. after giving CONTRACTOR (and the surety.
if any.) seven days' written notice and to the extent permit-
ted by Laws and Regulations. terminate the services of
CONTRACTOR. exclude CONTRACTOR from the site and
take possession of the Work and of all CONTRACTOR'S
tools, appliances, construction equipment and machinery at
the site and use the same to the full extent they could be used
by CONTRACTOR (without liability to CONTRACTOR for
trespass or conversion), incorporate in the Work all materi-
als and equipment stored at the site or for which OWNER
has paid CONTRACTOR but which are stored elsewhere,
and finish the Work as OWNER may deem expedient. In
such case CONTRACTOR shall not be entitled to receive
any further payment until the Work is finished. If the unpaid
balance of the Contract Price exceeds all claims. costs.
losses and damages sustained by OWNER arising out of or
resulting from completing the Work such excess will be paid
to CONTRACTOR. If ;uch claims, costs, losses and dam-
ages exceed such unpaid balance. CONTRACTOR shall pay
(he difference to OWNER. Such claims, costs. losses and
damages incurred by OWNER will be reviewed by ENGI-
NEER as to their reasonableness and when so approved by
ENGINEER incorporated in a Change Order. provided that
when exercising any rights or remedies under this paragraph
OWNER shall not be required to obtain the lowest price for
the Work performed.
15.3. Where CONTRACTOR's services have been so ter-
minated by OWNER, the termination will not affect any rights
or remedies of OWNER against CONTRACTOR then existing
or which may thereafter accrue. Any retention or payment of
moneys due CONTRACTOR by OWNER will not release
CONTRACTOR from liability.
15.4. Upon seven days' written notice to CONTRACTOR
and ENGINEER. OWNER may. without cause and without
prejudice to any other right or remedy of OWNER. elect to
terminate the Agreement. In such case. CONTRACTOR shall
be paid (without duplication of any items):
15.4.1, for completed and acceptable Work executed in
accordance with the Contract Documents prior to the effec-
tive date of termination, including fair and reasonable sums
for over.`....^d and profit on such Work:
15.4.2. for expenses sustained prior to the effective date
of termination in performing services and furnishing labor.
materials or equipment as required by the Contract Docu-
ments in connection with uncompleted Work, plus fair and
reasonable sums for overhead and profit on such expenses:
15.4.3. for all claims, costs, losses and damages incurred
in settlement of terminated contracts with Subcontractors.
Suppliers and others: and
15.4.4. for reasonable expenses directly attributable to
termination.
CONTRACTOR shall not be paid on account of loss of
anticipated profits or revenue or other economic loss arising
out of or resulting from such termination.
COATRAC7OR May Stop Work or Te-rmiru*e:
15.5. If. through no act or fault of CONTRACTOR. the
Work is suspended for a period of more than ninety days by
OWNER or under an order of court or other public author-
ity. or ENGINEER fails to act on any Application for
Payment within thirty days after it is submitted or OWNER
fails for thirty days to pay CONTRACTOR any sum finally
determined to be due, then CONTRACTOR may. upon
seven days' written notice to OWNER and ENGINEER.
and provided OWNER or ENGINEER do not remedy such
suspension or failure within that time, terminate the Agree-
ment and recover from OWNER payment on the same terms
as provided in paragraph 15.4. In lieu of terminating the
.Agreement and without prejudice to any other right or
remedy. if ENGINEER has failed to act on an Application
for Payment within thirty days after it is submitted, or
OWNER has failed for thirty days to pay CONTRACTOR
any sum finally determined to be due, CONTRACTOR may
upon seven day's written notice to OWNER and ENGI•
NEER stop the Work until payment of all such amounts due
CONTRACTOR. including interest thereon. The provisions
of this paragraph 15.5 are not intended to preclude CONS
TRACTOR from making claim under Articles II and 12 for
an increase in Contract Price or Contract Times or otherwise
for expenses or damage directly attributable to CONTRAC-
TOR's stopping Work as permitted by this paragraph.
ARTICLE 16 —DISPUTE RESOLUTION
Replaced with SC 14.5
If and to the extent that OWNER and CONTRACTOR have
agreed on the method and procedure for resolving disputes
between them that may arise under this Agreement. such
dispute resolution method and procedure. if any, shall be as set
forth in Exhibit GC -A, "Dispute Resolution Agreement." to be
attached hereto and made a part hereof. If no such agreement
on the method and procedure fut rtsuivitg such disputes has
been reached, and subject to the provisions of paragraphs 9.10,
9.11. and 9.12. OWNER and CONTRACTOR may exercise
41
I
such rights or remedies as either may otherwise have under the
Contract Documents or by Laws or Regulations in respect of
any dispute.
ARTICLE 17 —MISCELLANEOUS
Giving Notice:
17.1. Whenever any provision of the Contract Documents
requires the giving of written notice, it will be deemed to have
been validly given if delivered in person to the individual or to
a member of the firm or to an officer of the corporation for
wflom-it is intended, or if delivered at or sent by registered or
certified mail, postage prepaid, to the last business address
known to the giver of the notice.
Computation of Times:
17.2.1.'1 When any period of time is referred to in the
Contract Documents by days, it will be computed to exclude
the first and include the last day of such period. If the last day
of any such period falls on a Saturday or Sunday or on a day
made a legal holiday by the law of the applicable jurisdiction,
such day will be omitted from the computation.
17.2.2. 1 A calendar day of twenty-four hours measured
from midnight to the next midnight will constitute a day.
Notice of Claim:
17.3. Should OWNER or CONTRACTOR suffer injury or
damage to person or property because of any error, omission or
act of the other party or of any of the other party's employees
or agents or others for whose acts the other party is legally
liable, claim will be made in writing to the other party within a
reasonable time of the first observance of such injury or
damage. The provisions of this paragraph 17.3 shall not be
construed as a substitute for or a waiver of the provisions of
any applicable statute of limitations or repose.
Cumulaor+e Remedies:
17.4. The duties and obligations imposed by these General
Conditions and the rights and remedies available hereunder to
the parties hereto, and, in particular but without limitation, the
warranties, guarantees and obligations imposed upon CON-
TRACTOR by paragraphs 6.12. 6.16, 6.30, 6.31, 6.32, 13.1.
13.12, 13.14, 14.3 and 15.2 and all of the rights and remedies
available to OWNER and ENGINEER thereunder. are in
addition to, and are not to be construed in any way as a
limitation of, any rights and remedies available to any or all of
them which are otherwise imposed or available by Laws or
Regulations, by special warranty or guarantee or by other
provisions of the Contract Documents, and the provisions of
this paragraph will be as effective as if repeated specifically in
the Contract Documents in connection with each particular
duty, obligation, right and remedy to which they apply.
Professional Fees and Court Costs 1ncladed
17.5. Whenever reference is made to "claims, costs, losses
and damages." it shall include in each case, but not be limited
to. all fees and charges of engineers, architects, attorneys and
other professionals and all court or arbitration or other dispute
resolution costs.
(The remainder of this page was left blank intentionally.]
I
I
I
I
I
I
I
I
1
I
I
I
J
42
I
I
I
I
I
I
I
I
I
SUPPLEMENT TO THE GENERAL CONDITIONS
The following Supplementary Conditions amend or supplement the Standard General
Conditions of the Construction Contract (EJCDC No. 1910-8, 1990 Edition) and
other provisions of the Contract Documents as indicated below. All provisions
which are not so amended or supplemented remain in full force and effect.
SC -1 Definitions and Abbreviations
in addition to the provisions of Article 1, the following supplemental
definitions apply:
"Owner" shall mean the City of Fayetteville, Arkansas, acting thorough its duly
authorized representatives. Address - City of Fayetteville, 113 West Mountain,
Fayetteville, AR 72701.
"Engineer" shall mean the City of Fayetteville Engineering Division (telephone
501-575-8206). Note "OWNER", "ENGINEER" and "OWNER and ENGINEER" may be used
interchangeably.
"Resident Project Representative" shall be the authorized representative of the
"Engineer".
"Surety" or "sureties" shall mean the bondsmen or party or parties who have made
the fulfillment of the contract by bonds, and whose signatures are attached to
such bonds.
"Advertisement" shall mean the all legal publications pertaining to the work of
this contract.
"Plans" shall mean, collectively, all of the drawings pertaining to the contract
' and made a part thereof, and also such supplementary drawings as the Engineer may
issue from time to time in order to clarify the drawings, or for the purpose of
showing changes in the work as authorized under the section "Modifications and
Alterations," or for the showing of details which are not shown thereon.
' "Grade" as used in these specifications shall mean and indicate the established
elevations of the paving, flow lines of sewers and other appurtenances as shown
on the plans on file in the Engineer's office.
Whenever the following abbreviations are used, they shall have the corresponding
meaning as shown below:
' AASHTO - American Association of State Highway Officials
ACI American Concrete Institute
AGA American Gas Association
AHTD - Arkansas Highway and Transportation Department
ASHTD - Arkansas Highway and Transportation Department
AISC American Institute of Steel Construction
ANSI American National Standards Institute
APA - American Plywood Association
ASA - American Standards Association
ASTM American Society for Testing Materials
AWG American Wire Gage
AWPA - American Wood Products Association
' AWS _ American Welding Society
AWWA American Water Works Association
GSA General Services Administration, U.S. Government
iJ
1
I
I
NHBA - National Builders Hardware Association
NEC - National Electric Code
NEMA - National Electric Manufactures Association
NFPA - National Fire Protection Association
NPT - National Pipe thread
SBC - Standard Building Code (also SSBC)
SPA - Southern Products Association
UL - Underwriters Laboratories
A - Ampere
c£m - cubic feet per minute
CGMP - corrugated galvanized metal pipe
DIP - ductile iron pipe
gpm - gallons per minute
Hp - horsepower
lbs - pounds
MGD - million gallons per day
NJC. - normally closed
NM. - normally open
ppm - parts per million
psi - pounds per square inch
PVC - polyvinyl chloride (pipe)
RI - motor starter relay
RCP - reinforced concrete pipe
rpm - revolutions per minute
T!D. - time delay
TDH - total dynamic head
V' - volt
SC -2 Preliminary Matters - ..
Add the following to immediately follow paragraph 2.2 of the General Conditions. ._'
SC -2.2 Copies of Documents:
Article 2.2 of the General Conditions shall be amended to read that Not less than
five (5) bound copies of the proposal, contract, and stipulations shall be
prepared and submitted to the OWNER for execution, each containing an exact copy
of the CONTRACTOR'S proposal as submitted, the Bond or Bonds properly executed
and the Contract signed by both parties thereto. However, the CONTRACTOR and the
surety executing the bond shall not date the contract or the bond upon submission
or execution by the OWNER. These documents will be dated the date the OWNER
executes the contract.
OWNER shall furnish to CONTRACTOR up to two (2) copies of the contract documents
as are reasonably necessary for the execution of the work. Additional copies
will be furnished, upon request, at the cost of reproduction.
SC 2.7. Furnishing of Insurance Data. Delete all references to OWNER supplied
and OWNER delivered insurance.
SC -5 Bonds and Insurance:
SC5.1 Performance, Payment and other bonds:
Add the following new paragraphs immediately after paragraph 5.1 of the General
Conditions which reads as follows:
1
21
I
' SC5.1.1 Resident Agent. The CONTRACTOR shall furnish performance and payment
bonds as provided for by Article 5 of the General Conditions executed by a
resident local agent who is licensed by the Arkansas State Insurance Commissioner
Ito represent the surety company executing said bonds, and filing with such bonds
his power -of -attorney. The mere countersigning of the bonds by a resident agent
shall not be sufficient. No employers' liability, public liability or workmen's
collective insurance policy shall be written in any casualty company not
' authorized to do business in the State of Arkansas. These policies shall
likewise be issued by a resident local agent licensed by the Insurance Commission
of the State of Arkansas.
' SC5.1.2 Additional information. The Contractor shall provide the bonds as
described in these sections within ten (10) days after the receipt of the NOTICE
OF AWARD.
' For contracts in excess of 5100,000.00 the bonds shall be issued by a bonding
company listed by the A.M. BEST Rating Book as follows:
' (1) contracts in excess of $100,000.00, but less than $1,000,000.00 - "B+"
rating or higher and contract amount may not exceed 2.0% of the policyholder's
surplus.
(2) contracts in excess of $1,000,000.00 - "A" rating or higher and contracts
may not exceed 2.0% of the policyholder's surplus.
The expense of all bonds shall be borne by the CONTRACTOR.
•
SC 5.2. Delete paragraph 5.2 of the General Conditions in its entirety and
replace with the following new paragraph 5.2:
' SC 5.2. If at any time a surety on any such bond is declared bankrupt or loses
its right to do business in the State of Arkansas or is removed from the above
list of surety companies, the CONTRACTOR shall within ten (10) days after notice
from the bond company that conditions are as described in this sentence and/or
after notice from the OWNER to do so, substitute an acceptable bond or bonds in
such form and sum and signed by other surety or sureties as may be satisfactory
to the OWNER. The premiums on such bonds shall be paid by the CONTRACTOR. No
' further payment shall be deemed due nor shall be made until the new surety or
sureties shall have furnished an acceptable bond to the OWNER.
SC -5.3 Licensed Sureties and Insurers; Certificates of Insurance
SC5.3.1 Add the following new paragraph immediately after paragraph 5.3.1 of
the General Conditions which reads as follows:
The CONTRACTOR shall furnish performance and payment bonds as provided for by
Article 5 of the General Conditions executed by a resident local agent who is
licensed by the Arkansas State Insurance Commissioner to represent the surety
company executing said bonds, and filing with such bonds his power -of -attorney.
The mere countersigning of the bonds by a resident agent shall not be sufficient.
No employers' liability, public liability or workmen's collective insurance
policy shall be written in any casualty company not authorized to do business in
the State of Arkansas. These policies shall likewise be issued by a resident
local agent licensed by the Insurance Commission of the State of Arkansas.
I
1 3
SC5.3.2 Delete the second sentence of paragraph 5.3.2 ("OWNER shall deliver to
Contractor. . .") in its entirety.
I
SC5.4. CONTRACTOR'S Liability Insurance:
i
Add the following paragraphs immediately after the respective paragraphs
contained in paragraph 5.4 of the General Conditions:
SC5.4.14
i
The limits for liability for the insurance required by paragraph 5.4 of the
General Conditions shall provide coverage for not less than the following amounts
or the greater where required by law:
Workers Compensation:
1) State: Statutory
2) Applicable Federal: Statutory
3), Employer's Liability: $100,000.00 each occurrence
i
Comprehensive General Liability:
$1,000,000.00 Combined Single Limit
Policies will include premise/operations, products, completed operations,
independent contractors, explosions, collapse, underground hazard, Broad Form
contractual, personal injury, with employment exclusion deleted and broad form
property damage.
N1
Comprehensive Automobile Liability
Bodily Injury:
$1,000,000.00 Each person
$2,000,000.00 Each occurrence
Property Damage:
$500,000.00 Each occurrence
or a combined single limit of $2,000,000.00.
SC5.5 OWNER'S Liability Insurance. Delete paragraph 5.5 of the General
Conditions in its entirety and insert the following in its place:
1
515. OWNER'S and ENGINEER'S Contingent Protective Liability Insurance.
I
The CONTRACTOR shall indemnify and hold harmless the OWNER and the ENGINEER and
their agents and employees from and against all losses and claims, demands,
payments, suits, actions, recoveries, judgements of every nature and description
brought or recovered against them by reason of omission or act of the CONTRACTOR,
his agent(s), employees, subcontractor, anyone directly or indirectly employed
by any of them or anyone for whose acts any of them may be liable, in the
execution of the Work or guarding of it. The CONTRACTOR shall obtain in the name
of the OWNER and ENGINEER (either as co-insured or by endorsement), and shall
maintain and pay the premiums for such insurance in an amount not less that
$2,000,000.00 for property damage and bodily injury limits, and with such
provisions as shall protect the OWNER and ENGINEER from contingent liability
under this contract.
n
1
1
1
1
1
I
C
I
I
C
I
I
Li
I
I
SC5.6 Property Insurance.
Delete paragraph 5.6 of the General Conditions in its entirety and insert the
following in its place:
5.6 Property Insurance. CONTRACTOR shall purchase and maintain until final
payment property insurance upon the Work at the site to the full insurable value
thereof (subject to deductible amounts as may be provided in these Supplementary
Conditions or required by Laws and Regulations) but not less than an amount equal
to the total bid price. This insurance shall include the interest of OWNER,
CONTRACTOR, Subcontractors, ENGINEER and ENGINEER'S consultants in the Work (all
of whom shall be listed as insured or additional insured parties), shall insure
against the perils of fire and extended coverage, shall include "all-risk"
insurance for physical loss and damage including theft, vandalism and malicious
mischief, collapse, flood, and water damage, and such other perils as may be
provided in these Supplementary Conditions, and shall include damages, losses and
expenses arising out of or resulting from any insured loss or incurred in the
repair or replacement of any insured property (including but not limited to the
fees and charges of engineers, architects, attorneys and other professionals).
If not covered under the "all-risk" insurance or otherwise provided in these
Supplementary Conditions, CONTRACTOR shall purchase and maintain similar property
insurance on portions of the Work stored on and off the site or in transit when
such portions of the Work are to be included in an application for payment. The
polices of insurance required to be purchased and maintained by the CONTRACTOR
in accordance with this paragraph 5.6 will contain a provision or endorsement
that the coverage afforded will not be canceled or materially changed or renewal
'refused until at least 30 days prior written notice has been given to the OWNER
by certified mail and will contain wavier provisions in accordance with General
Condition paragraph 5.11.2.
SC5.7 Delete paragraph 5.7 of the General Conditions in its entirety and
insert the following in its place:
SC5.7 Other Insurance. The CONTRACTOR is to protect the OWNER against all loss
during the course of the Contract. If, due to the nature of the Project,
insurance coverage other than that specified is needed by the CONTRACTOR to
protect the OWNER against all losses, the CONTRACTOR shall be responsible for the
determination of and procurement of any additional insurance needed.
SC5.8 Delete paragraph 5.8 of the General Conditions in its entirety and
insert the following in its place:
SC 5.8. Policies shall also specify that insurance provided by CONTRACTOR will
be considered primary and not contributory to any other insurance available to
the OWNER or the ENGINEER.
All polices will provide for 30 days written notice (certified mail shall be
required) prior to any cancellation or non -renewal of insurance policies required
under the Contract. Any such wording as "will endeavor" or "but failure to mail
such notice shall impose no obligation or liability of any kind upon the
Company..." shall be deleted from the certificates.
SC5.10. Delete paragraph 5.10 of the General Conditions in its entirety.
' SCS.12. Receipt and Application of Proceeds
General Conditions in its entirety.
I
Delete paragraph 5.12 of the
5
H
I
n
SC5.13. Delete paragraph 5.13 of the General Conditions in its entirety.
SC,6 - CONTRACTOR'S RESPONSIBILITIES
I
SC16 6 - Progress schedules. '
I
Add a new paragraph 6.6.3. immediately following paragraph 6.6.2 which shall
read:
I
An updated schedule, in the format specified in the Technical Specifications,
shall be required with each submittal for progress payment by the CONTRACTOR.
Failure to provide an accurate schedule (and/or updated schedule) shall be reason
for OWNER to refuse progress payment to CONTRACTOR.
SC,6.30 CONTRACTOR'S General Warranty and Guarantee.
SC'6 30.3 - One Year Warranty.
Add a new paragraph 6.30.3 immediately following paragraph 6.30.2 which shall
read:
For a period of one year, or longer if specified by special guarantees or by law,
the Contractor shall at the Contractor's expense make all repairs and
replacements necessitated by defects in the materials, workmanship or prosecution
of! the Work supplied under this contract, and pay for any damage to other works
or1property resulting from such defects. The Contractor shall hold the Owner
and Engineer harmless from any liability of any kind arising from said defects.
Th effective date for the beginning of the one year warranty period will be as
decided by the Engineer and will be either the date of the Engineer's
recommendation for Final Payment in accordance with Article 14.13, Final Payment
and Acceptance, or the date of Substantial Completion as specified in Article
l48.
The Contractor shall make all repairs or replacements promptly upon receipt of
written order for the repairs or replacements from the Owner. If the Contractor
fails to make the repairs or replacements promptly, the Owner may perform the
work and the Contractor and the Contractor's Surety shall be liable for all costs
thereof.
SC 7 OTHER WORK
SC 7.5 Separate CONTRACTOR Claim. Add a new paragraph immediately after
paragraph 7.4 of the General Conditions which shall read as follows:
!
SC 7.5. Should CONTRACTOR cause damage to the Work or property of any separate
contractor (or separate party) at the site, or should any claim arising out of
CONTRACTOR'S performance of the Work at the site be made by any separate
contractor (or separate party) against CONTRACTOR, OWNER or ENGINEER, or any such
person, CONTRACTOR shall promptly attempt to settle with such other separate
contractor (or separate party) by agreement or otherwise resolve the dispute by
arbitration or at law. CONTRACTOR shall, to the fullest extent permitted by
Laws and Regulations, indemnify and hold OWNER and ENGINEER harmless from and
against all claims, damages, losses and expenses (including, but not limited to,
fees and charges of engineers, architects, attorneys and other professionals and
court and arbitration costs) arising directly, indirectly or consequentially out
of any action, legal or equitable, brought by any separate contractor (or
I
I
Li
I
nI
u
I
I
E
I
I
I
I
I
I
I
I
I
I
I
I
I
I
H
I
HI
separate party) against OWNER or ENGINEER to the extent based on a claim arising
out of CONTRACTOR'S performance of the Work. Should a separate contractor (or
separate party) cause damage to the Work or property of CONTRACTOR or should the
performance of Work by any separate contractor (or separate party) at the site
give rise to any other claim, CONTRACTOR shall not institute any action, legal
or equitable, against OWNER or ENGINEER or permit any action against them to be
maintained and continued in CONTRACTOR'S name for benefit in any court or before
any arbitrator which seeks to impose liability on, or recover damages from OWNER
or ENGINEER on account of such damage or claim. If CONTRACTOR is delayed at any
time in performing or furnishing Work by any act or neglect of a separate
contractor (or separate party) and OWNER and CONTRACTOR are unable to agree as
to the extent of any adjustment in Contract Time attributable thereof, CONTRACTOR
may make a claim for an Extension of Time in accordance with Article 12 of the
General Conditions. An extension of the Contract Time shall be the CONTRACTOR'S
exclusive remedy with respect to OWNER and ENGINEER for any delay, disruption,
interference or hindrance caused by any separate contractor (or separate party).
This paragraph does not prevent recovery from OWNER or ENGINEER for activities
that are their respective contractual responsibilities.
SC -8 OWNER'S RESPONSIBILITIES
SC 8.5 - Delete paragraph 8.5 of the General Conditions in it's entirety.
SC 10 CHANGES IN THE WORK
Add a new paragraph 10.6 immediately following paragraph 10.5 of the General
Conditions to read:
V
10.6. Limits of Authority. CONTRACTOR shall note and abide by the following
OWNER'S and ENGINEER'S limits of authority for changes in the Work which require
a change in the Contract Price and Contract time.
Except in the case of extreme emergency to protect public safety, public welfare
or substantial Work, the following limits of Authority to the OWNER and ENGINEER
shall apply:
Engineer's Representative - No authority.
Engineer - No authority.
Mayor - $20,000.00 (Accumulative).
All accumulative changes which result in Contract Price changes in excess of
$20,000.00 shall require the formal approval of the Fayetteville City Council
prior to execution of the work resulting in the price or scope change.
SC 11 CHANGE OF CONTRACT PRICE.
Sc 11.9.
Unit
Price Work.
Paragraph 11.9.3
of
the General
Conditions is
hereby
deleted
in its
entirety and
the following
is
substituted
in its place:
11.9.3 The
unit price of
an item
of Unit Price work shall
be subject to
reevaluation
and adjustment
under the
following conditions:
11.9.3.1 if the total cost of a particular item of Unit Price Work amounts to
25 percent or more of the Contract Price and the variation of the quantity of
that particular item of Unit Price work performed by CONTRACTOR differs by more
than 25 percent from the estimated quantity of such item indicated in the
Agreement; and
tl
Li
I
11.9.3.2. if there is no corresponding adjustment with respect to any other item
of Work; and
11.9.3.3 if CONTRACTOR believe that it has incurred additional expense as a
result thereof; or
11.9.3.4 if OWNER believes that the quantity variation entitles OWNER to an '
adjustment in unit price; then
11.9.3.5 either OWNER or CONTRACTOR make a claim for and adjustment in the
Contract Price in accordance with Article 11 of the General Conditions if the
parties are unable to agree as to the effect(s) of any such variations in the
quantity of Unit Price Work performed.
JC-1J 1LJ 1J P.DIL .yalq I. draY'_aw.., ........... v
WORK.
Sc 13.3 Tests and Inspections. Paragraph 13.3 of the General Conditions is
hereby deleted in its entirety and the following is substituted in its place:
SC 13.3. CONTRACTOR shall give the ENGINEER proper notification as detailed
below and cooperate with the testing and inspection of the work.
SC 13.3.1. All tests require a minimum notice of 24 hours. The 24 -hours is
a,minimum only, the exact time for testing and required inspections shall be
determined by the Engineer.
SC 13.3.2. All field tests required for a project shall be witnessed by the
City Engineering Division representatives in the presence of the ENGINEER and
CONTRACTOR, or their approved representatives.
SC 13.4 Paragraph 13.4 of the General Conditions is hereby deleted in its
entirety and the following substituted in its place:
SC 13.4. CONTRACTOR shall- employ and pay for the services of an independent
testing laboratory to perform all tests as required by the Contract Documents.
CONTRACTOR shall be responsible for the cost of all equipment, materials, labor,
testing procedures and lab work for all tests as outlined in these
specifications. ENGINEER shall have the right to approve or reject CONTRACTOR'S
proposed lab based upon sound Engineering principles. Copies of all testing
reports must be forwarded directly to the Engineer by the testing laboratory.
OWNER shall provide all inspection services required by the Contract Documents
and normally associated with the diligent progress of the Work (Except as
detailed in paragraphs 13.4.1,2,3.) Prior to final acceptance by OWNER, the
project shall be subject to a final inspection by designated representatives of
the OWNER and CONTRACTOR.
ARTICLE 14 PAYMENT TO CONTRACTOR AND COMPLETION.
I
SC 14.2 Application for Progress Payment. Paragraph 14.2 O£ the General
Conditions is hereby deleted in its entirety and the following substituted in its
place:
I
Sc 14.2.1. Monthly estimates will be prepared to include all work accomplished
for the period ending the third Friday of each month; or
8•
I
Sc 14.2.2. Progress payments will be prepared at regular intervals, as scheduled
by joint consent of the CONTRACTOR and the ENGINEER at the pre -construction
conference.
' SC 14.2.3. The ENGINEER, based upon data gathered during the construction
process, will make an estimate of the value of the Work done and materials
furnished in place during the previous estimate period. The CONTRACTOR shall
' furnish to the ENGINEER such detailed information including invoices from
material suppliers as the ENGINEER may request to aid in the preparation of the
progress payment estimate. All payment requests are subject to retainage as
determined by the ENGINEER. Retainage shall be 10% of said estimate until 50%
' of the work has been fully completed. At 50% completion, further partial
payments shall be made to the contractor in full with no additional retainage
unless the ENGINEER determines that the project is not progressing satisfactory,
in which case additional retainage may be retained to a maximum of 10%. When
the work is substantially completed, any retained amount may be paid to the
contractor except the OWNER shall retain an amount sufficient to cover any work
not yet completed. The release of retainage will be determined by the ENGINEER.
If the OWNER or ENGINEER shall at any time fail to make the CONTRACTOR a monthly
' estimate at the time herein specified, such failure shall not be held to violate
or void the Contract. Note, the failure of the Contractor to provide an
accurate and current schedule update shall be reason to reject CONTRACTOR'S
request for progress payment.
' Sc 14.4. Review of Applications for Progress Payment.
Delete the last sentence of paragraph 14.4 of the General Conditions and replace
with the following:
• After the required internal reviews and processing by the City of Fayetteville,
the city will diligently proceed to make payment to the contractor, in accordance
' with the approved payment request, within 30 days. All efforts will be made to
make payments within the 30 day period, but the City cannot guarantee the 30 days
maximum time.
SC 14.5. Dispute Resolution Agreement.
' For this Section, refer to the next three pages, 10, 11, & 12.
I
I
I
J
I
I.
I
I
Li
I
I
I
Li
I
I
I
L
u
L
J
J
J
H
II
I
EXHIBIT GC -A to General Conditions of the
Agreement Between OWNER and CONTRACTOR
Dated
For use with EJCDC No. 191O-8 (1990 ed.)
DISPUTE RESOLUTION AGREEMENT
OWNER and CONTRACTOR hereby agree that Article 16 of the
General Conditions to the Agreement between OWNER and CONTRACTOR is
amended to include the following agreement of the parties:
16.1 All claims, disputes and other matters in question
between OWNER and CONTRACTOR arising out of or relating to the
Contract Documents or the breach thereof (except for claims which
have been waived by the making or acceptance of final payment as
provided by paragraph 14.15) will be decided by arbitration in
accordance with the Construction Industry Arbitration Rules of the
American Arbitration Association then obtaining, subject to the
limitations of this Article 16. This agreement so to arbitrate and
any other agreement or consent to arbitrate entered into in
accordance herewith as provided in this Article 16 will be
specifically enforceable under the prevailing law of any court
having jurisdiction.
16.2 No demand for arbitration of any claim, dispute or
other matter that is required to be referred to ENGINEER initially
for decision in accordance with paragraph 9.11 will be made until
the earlier of (a) the date on which ENGINEER has rendered a
written decision or (b) the thirty-first day after the parties have
presented their evidence to ENGINEER if a written decision has not
been rendered by ENGINEER before that date. No demand for
arbitration of any such claim, dispute or other matter will be made
later than thirty days after the date on which ENGINEER has
rendered a written decision in respect thereof in accordance with
paragraph 9.11; and the failure to demand arbitration within said
thirty days period will result in ENGINEER's decision being final
and binding upon OWNER and CONTRACTOR. If ENGINEER renderers a
decision after arbitration proceedings have been initiated, such
decision may be entered as evidence but will not supersede the
arbitration proceedings, except where the decision is acceptable to
the parties concerned. No demand for arbitration of any written
decision of ENGINEER rendered in accordance with paragraph 9.10
will be made later than ten days after the party making such demand
has delivered written notice of intention to appeal as provided in
paragraph 9.10.
16.3 Notice of the demand for arbitration will be filed
in writing with the other party to the Agreement and with the
American Arbitration Association, and a copy will be sent to
ENGINEER for information. The demand for arbitration will be made
within the thirty -day or ten-day period specified in paragraph 16.2
as applicable, and in all other cases within a reasonable time
after the claim, dispute or other matter in question has arisen,
and in no event shall any such demand be made after the date when
I
10
P1
' institution of legal or equitable proceedings based on such claim,
dispute or other matter in question would be barred by the
tapplicable statute of limitations.
16.4 Except as provided in paragraph 16.5 below, no
' arbitration arising out of or relating to the Contract Documents
shall include by consolidation, joinder or in any other manner any
other person or entity (including ENGINEER, ENGINEER'S Consultant
and the officers, directors, agents, employees or consultants of
any of them) who is not a party to this contract unless:
16.4.1. the inclusion of such other person or entity is
necessary if complete relief is to be afforded among those who are
already parties to the arbitration, and
' 16.4.2. such other person or entity is substantially
involved in a question of law or fact which is common to those who
are already parties to the arbitration and which will arise in such
proceedings, and
16.4.3. the written consent of the other person or
entity sought to be included and of OWNER and CONTRACTOR has been
obtained for such inclusion, which consent shall make specific
reference to this paragraph; but no such consent shall constitute
consent to the arbitration of any dispute not specifically
described in such consent or to arbitration with any party not
' specifically identified in such consent.
16.5 Notwithstanding paragraph 16.4 if a claim, dispute
' or other matter in question between OWNER and CONTRACTOR involves
the Work of a Subcontractor, either OWNER of CONTRACTOR may join. such Subcontractor as a party to the arbitration between OWNER and
' CONTRACTOR hereunder. CONTRACTOR shall include in all subcontracts
required by paragraph 6.11 as a specific provision whereby the
Subcontractor consents to being joined in an arbitration between
OWNER and CONTRACTOR involving the Work of such Subcontractor.
' Nothing in this paragraph 16.5 nor in the provision of such
subcontract consenting to joinder shall create any claim, right or
cause of action in favor of Subcontractor and against OWNER,
'• ENGINEER or ENGINEER's consultants that does not otherwise exist.
16.6 The award rendered by the arbitrators will be final,
' judgment may be entered upon it in any court having jurisdiction
thereof, and it will not be subject to modification or appeal.
16.7 OWNER and CONTRACTOR agree that they shall first
' submit any and all unsettled claims, counterclaims, disputes and
other matters in question between them arising out of or relating
to the Contract Documents or the breach thereof ("disputes"), to
' mediation by the American Arbitration Association under the
Construction Industry Mediation Rules of the American Arbitration
Association prior to either of them initiating against the other a
demand for arbitration pursuant to paragraphs 16.1 through 16.6,
unless delay in initiating arbitration would irrevocably prejudice
' 11
I
' one cf the parties. The respective thirty and ten day time limits
within which to file a demand for arbitration as provided in
paragraphs 16.2 and 16.3 above shall be suspended with respect to
' a dispute submitted to mediation within those same applicable time
limits and shall remain suspended until ten days after the
termination of the mediation. The mediator of any dispute
submitted to mediation under this Agreement shall not serve as
arbitrator of such dispute unless otherwise agreed.
I
I
I
I
I
I
I
I
I17
I
H
I
H
12
H
• Section 100 GENERAL PROJECT REQUIREMENTS: - "-
1 Scope of Work.
The work shall be as shown upon the contract drawings and defined within.the
contract specifications, referenced AHTD Standard Drawings and Specifications:
andshall include the furnishing of all materials, equipment, tools, supplies,
plant, labor and others as necessary in the construction of work generally as
follows:
All traffic control, trenching, water lines, service lines, appurtenances and
and other construction required for the water and sewer line replacements on
Highway 16 W. Widening - water & Sewer Relocations Project
as shown in the contract documents.
No attempt has been made to segregate work to be performed by any trade or
subcontract. Any segregation between the trades or crafts will be solely a
matter for agreement between the Contractor, subcontractor, and their respective
employees.
The Specifications as a whole will govern the construction of the entire work.
The applicable provisions will govern work to be performed under each schedule.
2. Referenced AHTD Standard Specifications and Drawings.
' The AHTD Standard Specifications contained in the Standard Specifications for
Highway Construction," Edition of 1993, published by the Arkansas State Highway
Commission are hereby referenced and made a part of these Specifications.
': These Specifications are available for inspection in the Engineer's office, or
may be obtained from the Arkansas State Highway Department, Little Rock,
I: Arkansas.
The AHTD Standard Specifications, and Standard Drawings when referenced in the
bid schedule shall be used as the Technical Specifications for this specific
project.
The Standard "Front-end" specifications, including the Advertisement for Bids,
Instructions to Bidders, Bid Proposal, Contract, General Conditions,
Supplemental Conditions, Performance and Payment Bonds and Section 100 - "General
Project Requirements" shall be as contained and shown in this specific set of
Contract documents and specifications.
All conflicts and discrepancies shall be resolved in the favor of the Contract
Documents and Specifications as written by the City of Fayetteville.
Special attention is directed to paragraph 28 - Testing of this Section 100
for additional requirements for all tests.
After the contract bonds and certificates of insurance have been delivered to the
Owner, and the contract has been executed, the- Engineer will issue a Notice To
Proceed in accordance with the General Specifications which shall designate the
date the contract will commence.
' The Contractor shall complete the project within Ninety (90) calendar days from
the date specified in the Notice To Proceed.
Additionally, the Contractor shall be responsible to submit a schedule of
construction, in accordance with the General and Supplemental specifications, and
Technical specification 100.05 "Schedules", which completely and clearly defines
the items of work.
Section 100 page 1
The Owner may require the Contractor to add to his plant, equipment, or
construction forces, as well as increase the working hours, if operations fall
behind the approved schedule to an extent that the completion of the work within
the specified time appears doubtful.
I£ conditions beyond the control of the Contractor justify, and the Contracting
Authority approves an extension of contract time, the Contractor shall revise the
construction schedule in accordance with the approved extension.
4. Submittals.
The 'f ollowing. submittals shall be required for this specific project:
a. (Manufacturer's data for all pipe material, fittings, valves and fire
hydrants.
b. Schedules as noted in paragraph 5 below.
5. Schedules.
Before work is started, and in accordance with the General and Supplemental
Conditions, the Contractor under each schedule shall prepare a detailed schedule
of all construction operations that shall not only indicate the sequence of the
work, but also the time of starting and completion of each part. The schedule
shall be submitted to the Engineer for his approval.
`(For projects with a total estimated costs of up to $100,00.00 the Contractor
may submit a schedule(s) based upon bar charts, narrative or Critical Path
' Network Diagram.
IFor Projects with a total estimated costs in excess of $100,000.00 the
I Contractor shall submit the schedule(s) in the form of a Critical Path
(Method (CPM) Network Diagram.
The contractor shall also be required to submit an updated version of the
schedule(s) with each submission of a periodic payment request.
6. (Lands and Rights of Ways.
Theinecessary rights -of -way and easements for the project and to carry out the
work along the project will be provided by the City of Fayetteville except for
restrictions as noted below. The contractor shall confine his construction
operations to the immediate vicinity of the locations shown on the plans and
shall use due care in placing construction tools, equipment, excavated materials,
and pipeline materials and supplies, so as to cause the least possible damage to
property and interference with traffic. The placing of such tools, equipment,
andi materials shall be subject to the approval of the Engineer. The City of
Fayetteville will not be responsible for haul road to and from the right-of-way.
Thel contractor shall not store any material, place any construction material or
trench material, place any equipment or activities nor allow any workmen off of
the defined construction area.
The City o£ Fayetteville will not provide a materials storage area, a staging
area or any other area for use by the contractor except for the actual water line
and1 appurtenance construction -
The contractor shall not store any materials upon the streets or within the
street right-of-ways or on the utility or water line easements which will not be
installed wit -bin the same day. The contractor shall not store any materials in
any private yard without first furnishing to the Engineer a copy of written
permission from the property owner. The Contractor shall be responsible to
obtain any storage or yard areas the contractor requires.
Section 100 page 2
I
Ii
' The Contractor shall be responsible for all damage to all property outside of the
rights -of -way and easements, and shall make satisfactory settlement for the
damage directly with the property owner and tenant involved, as their interests
may require.
' All work performed, and all operations of the Contractor, his employees, or his
subcontractors, within the limits of railroad and highway rights -of -way shall be
in conformity with the requirements, and be under the control (with the City of
Fayetteville), of
the
railroad or highway
authority owning or
having
jurisdiction
'
over and control
of,
the right-of-way in
each case.
All existing fences which interfere with the construction operations small be
maintained by the Contractor until the completion of the work affected thereby,
unless written permission is obtained from the City of Fayetteville thereof, to
leave an interfering fence dismantled for an agreed period of time. Where fences
must be maintained across the right-of-way, adequate gates shall be installed
therein. Gates shall be kept closed and locked at all times when not in use,
with duplicate keys furnished to the Engineer.
' Upon completion of the work across any tract of land, the Contractor shall
restore all fences to their original or to a better condition and quality,
purchasing new material and replace all materials lost, damaged, or destroyed.
Temporary gates installed by the Contractor in any fence line may be left in
' place with the permission of the property owner and tenant of the property. All
materials used in fence repairs or replacements shall be approved by the
Engineer.
.j
7. Protection and Maintenance of Public and Private Property.
The Contractor shall protect, shore, brace, support, and maintain all underground
'—constructions uncovered or otherwise affected by the construction work performed
by him. All pavement, surfacing, driveways, curbs, walks, buildings, utility
poles, guy wires, and other surface structures affected by construction
operations in connection with the performance of the Contract, together with all
' sod and shrubs in yards and parking removed or otherwise damaged, shall be
restored to their original condition as determined and approved by the Engineer.
All replacements shall be made with new materials. The Contractor shall be
responsible for all damage to streets, roads, highways, shoulders, ditches,
' embankments, culverts, bridges, or other public or private property or facility,
regardless of location of character, which may be caused by moving, hauling, or
otherwise transporting equipment, materials, or men to or from the work or any
part or site thereof, whether by him or his subcontractors. The Contractor shall
' make satisfactory and acceptable arrangements with the owner of, or the agency
or authority having jurisdiction over, the damaged property or facility
concerning its repair or replacement or payment of costs incurred in connection
with said damage.
' All fire hydrants and water control valves shall be kept free from obstruction
and available for use at all times.
' 8. Maintenance of Traffic
The Contractor shall be responsible for the maintenance of traffic. All work
' within AHTD right-of-way shall be in conformance with the AHTD permit
requirements.
The Contractor shall be responsible to keep a minimum of one lane of traffic
' safely open at all times during this project - no exceptions.
The contractor shall limit the trenching and pipe installation to the work which
can be installed, inspected and properly backfilled within the working day and
' shall not block any private drives. Open trenches shall not be allowed to remain
overnight.
' Section !GO page 3
I
The contractor shall provide traffic control personnel and signage as necessary
for public safety.
91 Underground Installations and Structures.
Unless noted otherwise on the plan documents, pipelines and other existing
underground installations and structures in the vicinity of the work to be done
hereunder are indicated on the plans according to the best information available
to the Engineer. The Engineer and Owner does not guarantee to accuracy of such
information. House sewer connections, water and gas services, and other utility
lines may not be indicated on the plans. The Contractor shall make every effort
to locate all underground pipelines, conduits, and structures by contacting owner
of underground utilities and by prospection in advance of trench excavation. The
moving of planned improvements to avoid conflict with existing pipelines and
other existing installations and structures in the vicinity of the work to be
done for the convenience of the Contractor shall be accomplished at no additional
cost to the Owner.
10. Lines and Grades.
All work shall be done to the lines, grades, and elevations shown on the plans.
The Contractor shall keep the Engineer informed, a reasonable time in advance,
of the times and places at which he wishes to work, so that reference points in
accordance with General Conditions Article 4.4 may be established, and/or,
measurement for record and payment may be made with minimum inconvenience to the
Engineer and minimum delay to the Contractor.
The Contractor shall furnish, without charge, competent men from his force and
such tools, stakes, and other materials as the Engineer may require for restaking
and work required to be restaked. The Contractor will not proceed with the work
unless there is an accurate grade stake at a maximum distance of 50 feet. Any
restaking or other field work deemed excessive by the Engineer will be billed to
the contractor at a rate equal to comparable local rates (when performed by the
City, or at contract Engineering rates when contracted) and deducted from the
contractor's payments.
Any work done without being properly
ordered removed by the Engineer and
Construction staking, locating of th
shall be done by City staff.
1i. Public Notification.
I
The Contractor,on the basis of the schedule and progress
notify all adjacent property owners a minimum of 48
occupying,
storing
materials on,
or performing
work
on any
easement.
I
C
L
I
C
I
I
I
I
e
located on grade or off alignment, may be
replaced at the Contractor's expense.
easement lines and location of the fittings
shal
hours
I
1 be required to
in advance of
right-of-way or
All planned interruptions of water service shall be coordinated with the Engineer
and the Fayetteville Water Department. A minimum of 72 hours notice shall be
required. Service interruptions, if and when allowed by the Engineer, shall be
scheduled between 8:00 a.m. and 5:00 p.m. unless specifically approved otherwise.
It shall be the responsibility of the Contractor to provide a minimum of 72 hours
advance notice to the Engineer, Traffic Department, Police and Fire department
prior to cutting or blocking any public street or roadway.
FOR DETAIL INSTRUCTIONS SEE APPENDIX C.
I
I
I
Section 100 page 4
I
I
H
I
I
H
12. Storage of Materials.
In general, the Contractor shall be responsible for the all material furnished
by him and shall replace at his own expense all such material found defective in
manufacture or damaged in handling. This shall include the furnishing of all
material and labor required for the replacement of installed material discovered
defective prior to final acceptance of the work.
The Contractor shall be responsible for the delivery and distribution of
materials at the site. The Contractor shall be responsible for the safe storage
of materials furnished by or to him and accepted by him, and intended for the
work, until it has been incorporated into the completed and accepted project.
All materials shall be stored in strict confcrmance to the manufacturer's
recommendations.
Materials shall be stored so as to ensure the preservation of their quality and
fitness for the Work. When directed by the Engineer, the materials shall be
placed upon a wooden platform or other hard clean surfaces and not on the ground,
and shall be placed under cover when so directed. Stored materials shall not be
located so as to impede work or inspections.
Pipe and accessories shall be loaded and unloaded by lifting with hoists or other
equipment so as to avoid shock and damage. Under no circumstances shall material
be dropped or dumped. Pipe handled on skidways shall not be skidded or rolled
against pipe previously unloaded onto the ground. In distributing pipe material
at the site, each piece shall be unloaded opposite or near the place it is to be
laid in the trench. The interior of all pipe, fittings and other accessories
shall be kept free from dirt and foreign material at all times.
Pipe shall be so handled that the coating and lining will not be damaged.
However, if any part of the coating or lining is damaged, the repair or
replacement shall be made at the Contractor's expense in a manner satisfactory
to the Engineer.
NOTE: The City of Fayetteville will not provide a materials storage area, a
' staging area or any other area for use by the contractor except for the actual
water line and appurtenance construction. The contractor shall not store any
materials upon the streets or within the street right-of-ways or upon the water
line and/or utility easements which will not be installed within the same day
t placed at the street. The contractor shall not store any materials in any
private yard without first furnishing to the Engineer a copy of written
permission from the property owner.
' The Contractor shall be responsible to obtain any storage or yard areas the
contractor requires.
' 13. Saturday, Sunday, Holiday and Night Work.
Refer to paragraph 6.3 of the General Conditions.
' All work shall be performed during the normal work hours of the City of
Fayetteville Engineering Office, 8:00 a.m. - 5:00 p.m., Monday through Friday.
Except in an emergency to protect public health, safety or welfare or to protect
existing work, no overtime work, no work on Saturday or Sunday, nor work on any
legal holiday shall be permitted without specific written pre -authorization by
the Engineer.
14. Monthly Estimates and Payments.
' Refer to Article 14 of the General Conditions and the associated Supplemental
Conditions.
I
' Section 100 page 5
C
15 Connections to existing Facilities.
Unless otherwise indicated or specified, the Contractor shall provide for all
necessary connections to existing utilities such as water, sewer, telephone and
ellectric. In each case, the Contractor shall receive advance permission from
utility owner prior to providing for connections. Contractor shall protect
facilities against deleterious substances and damages.
Connections to existing facilities which are in service shall be thoroughly
planned in advance, and all required equipment, materials and labor shall be on
hand at the time of undertaking the connections. Work shall proceed continuous
(around the clock) as necessary to complete the connections in minimum time.
Operation of values or other appurtenances on existing utilities, when required,
shall be by or under the direct supervision of the owning utility.
I
All connections to the water and/or sewer facilities owned by the City of
Fayetteville shall be coordinated with and shall be inspected by the City of
Payetteville's Engineering Division and the Water/Sewer Department. .
1
16. Temporary Facilities.
(a) Utilities.
All water, electricity and other utility services required by the Contractor for
operation of Contractor's plant or equipment, or for any other use by the
Contractor to conduct or to expedite the work shall be provided by the Contractor
at his sole cost and expense. The Contractor shall arrange for service at his
discretion from the appropriate utility company, and shall assume liability for
ail charges until the improvements have been accepted by the Owner. When
applicable, the Owner will request the transfer of the service on that date, and
assume the liability for charges incurred by the Owner from that date forward.
Water to be used to test, flush and place the new water line in service shall be
provided by the City of Fayetteville.
(b) Sanitary Facilities. The Contractor shall furnish temporary sanitary
facilities at the site for the needs of the Construction workers and others
performing work or furnishing services on the project.
Sanitary facilities shall be of reasonable capacity, properly maintained
throughout the construction period, and obscured from public view to the greatest
practical extent. If toilets of the chemically -treated type are used, at least
one toilet will be furnished for each 20 workers. The Contractor shall enforce
the use of such sanitary facilities by all personnel at the site.
17. Oneration and Maintenance Data and Manuals.
Adequate operation and maintenance information shall be supplied to the Engineer
for all equipment requiring maintenance or other special attention. The
equipment supplier will prepare an operation and maintenance manual for each type
of equipment indicated herein. Parts lists and operating and maintenance
instructions shall be furnished for other equipment not listed in the following
schedule.
Information shall be required for:
I
All valves 6 inch and larger,
All fire hydrants.
I
I
I
I
I
I
I
I
U
I
I
H
H
I
H
Section 100 page 6
I
18. Tree and plant protection.
No trees or cultured plants shall be cut, trimmed or removed unless clearly shown
Ion the plans or marked by the Engineer. All trees and other vegetation which
are so marked and must be removed to perform the work, shall be removed and
disposed of by the Contractor. No on -site burning shall be permitted.
I. All protection of trees, trimming and repair of trees and plants shall be
performed by qualified nurserymen or horticulturists in accordance with the City
of Payetteville's Ordinance Chapter 162 "TREE PROTECTION AND PRESERVATION".
J
' 19. Security.
The contractor shall be responsible for protection of the site, and all work,
materials, equipment and existing facilities thereon against vandals and other
' unauthorized persons. Security measures shall be at least equal to those usually
provided by the Owner to protect his existing facilities during normal operation,
but shall also include such additional security fencing, lighting, barricades,
watchman's services and other measures as required to protect the site.
' No claim shall be made against the Owner by reason of any act of an employee or
trespasser, and the Contractor shall make good all damage to Owner's property
resulting from Contractor's failure to provide adequate security measures.
• 20. Safety.
' The Contractor is further notified and reminded of the presence of children and
pedestrians in the general vicinity of the project.
The Contractor shall take all measures necessary and as required by the General
Conditions (Article 6) to protect the General Public, animals and property from
harm due to the construction activities including the project site.
' 21. Parkin
The contractor shall provide and maintain suitable parking areas for the use of
' the construction workers and others performing work or furnishing services in
connection with the project, as required, to avoid any need of parking personal
vehicles where they may interfere with the owner's operations or construction
activities, or normal traffic operation on public and/or private roads.
I22. Dust Control.
' The Contractor shall take all reasonable measures to prevent unnecessary dust.
Earth surfaces subject to dusting shall be kepi moist with water or application
of an approved chemical dust suppressant. Dusty materials in piles or transit
shall be covered to prevent blowing.
' Buildings or operating facilities which may be adversely affected by dust shall
be adequately protected. Existing or new machinery, motors, instrument panels
or similar equipment shall be protected by suitable dust screens which include
adequate ventilation features.
I
' Section 100 page 7
I
23i Temporary Drainage and Erosion Control Provisions.
The Contractor shall provide for the drainage of storm water and such water as
may be applied or discharged on the site in the performance of the work.
Drainage facilities shall be adequate to prevent damage to the work, the site and
adjacent properties.
Existing drainage channels and conduits shall be cleaned, enlarged or
supplemented as necessary to carry increased runoff attributable to the
Contractor's operations. Temporary dikes shall be constructed as necessary to
divert increased runoff from entering adjacent properties (except in natural
channels or storm sewers), to protect the Owner's property, facilities and the
work, and to direct water into natural channels or conduits. Retention shall
beiprovided as necessary to prevent downstream flooding.
The Contractor shall prevent the erosion of soil on the site and adjacent
property resulting from the construction activities. Effective measures shall
beiinitiated prior to the commencement of clearing, grading, excavation or other
operations that will disturb the natural vegetation or protection. Erosion
measures may include hay bales, silt fencing, jute mat, fast growing vegetation,
and ponds.
I
Work shall be scheduled on exposed areas subject to erosion for the shortest
possible time, and natural vegetation shall be preserved to the greatest extent
possible. Temporary storage areas, construction building and access shall be
located to minimize erosion.
The Contractor shall be responsible for application and acquisition of all
necessary permits, including coverage under the Federal/State NSPDE Regulations
for Storm Water Management and the City of Fayetteville's Physical Alteration of
Land (Grading permit) when applicable.
Unless specifically included as separate bid item(s), all Work necessary for the
control of storm water runoff shall be considered as subsidiary to the project
and no separate payment shall be made to the Contractor.
24'. Pollution Control.
The Contractor shall apply with all requirements of the General Conditions and
all Federal, State and local laws and regulations governing pollution.
Additionally, the Contractor shall prevent the pollution of drains and
watercourses by sanitary wastes, sediment debris and other substances resulting
from construction activities. No sediment, debris or other substances shall be
permitted to enter any sanitary sewers, storm sewer, nor any drain or
watercourse.
25. Clean uo during construction.
Duffing construction, the Contractor shall keep
neat and workmen like condition at all times.
materials shall be stored and protected in an
activities. As soon as practicable, the are
ba'ckfilled, and the entire area maintained in
26,. Access.
a
the construction area in a clean,
Pipe, equipment, and all other
area away from the construction
around all structures shall be
a neat condition.
The Contractor shall provide for safe and ready access to the construction
activities during working hours or as requested to authorized representatives of
the City of Fayetteville and other State or Federal Agencies as required.
Section 100 page 8
I
I
J
rl
I
I
H
1J
I
H
J
'J
H
I
I
I
I
I
I
I
I
I
I
I
I
C
I
I
I
I
I
H
I
I
27. Construction Observation Inspection.
Construction observation and inspection shall be by the City of Fayetteville
Engineering Division. The Contractor shall note the requirements of a detailed
schedule and note all requirements for the scheduling of tests and test
requirements as noted in Technical Specification section 100.28 TESTING. The
Engineer shall have no responsibility to the Contractor or subcontractor for the
supervision of personnel or layout of work.
Prior to final acceptance by the City, the project shall be subject to a final
inspection by designated representatives of the City of Fayetteville and the
Contractor.
28. Testing.
The Contractor shall be responsible for the cost of all equipment, materials,
labor, testing procedures and lab work for all tests as outlined in these
specifications. The City of Fayetteville shall have the right to approve or
reject the contractor's proposed lab based upon sound Engineering principles.
Copies of all testing reports must be forwarded directly to the Engineer by the
testing laboratory.
All field tests required for a project shall be witnessed by the City Engineering
Division representatives in the presence of the Engineer and Contractor, or their
approved representatives.
All tests require a minimum notice of 24 hours. The 24 hours is a minimum only,
the exact time for testing and required inspections shall be determined by the
City of Fayetteville Engineering Office.
29. Measurement and Payment.
It is the intent of the proposal and the specifications that the total bid for
each schedule, as submitted, shall cover all work shown on the contract drawings
and required by the Specifications and other Contract Documents. All costs in
connection with the work including furnishing of all materials, equipment,
supplies, and appurtenances; providing all construction plant, equipment, and
tools; and performing of all necessary labor to fully complete the work, shall
be included in the unit and lump sum prices named in the proposal. No item of
work that is required by the Contract Documents for the proper and successful
completion of the Contract will be paid for outside of or in addition to the
prices submitted in the proposal. All work not specifically set forth in the
proposal as a pay item shall be considered a subsidiary obligation of the
Contractor and all costs in connection therewith shall be included in the prices
named in the proposal.
The method of measurement and basis of payment for each item as listed in the
proposal shall be as stipulated under the item of Work or as specified in Section
110, Measurement and Payment.
30. Explosives.
Explosives shall not be allowed for excavation or any other purpose unless a
detailed plan for such use is approved in writing by the Engineer, proof of
blasting insurance is submitted, and experienced personnel licensed in the State
of Arkansas for blasting is utilized. The plan must include as a minimum a pre -
blast survey and the utilization of qualified seismographic procedures.
I
Section 100 page 9
LJ
current edition of Occupational Safety and Health Administration Standard for
avation and Trench Safety Systems, 29 CFR 1926, Subpart P, is specifically
orporated and made a part of these specifications and contract documents as
aired by Arkansas Act 291 of the 79th General Assembly of 1993. The Contractor
11 be solely responsible for the implementation of these requirements.
i
Al copy of the OSHA regulations is included in this set of specifications as
Appendix A.
32. Utility Mix - Slurry mix "digable" backfill aka low strength flowable fill.
i
Where shown on the plans, a "digable" backfill, also called utility mix, shall
be used. The utility mix shall be a low strength concrete mixture that is
readily digable with standard equipment. The mixture shall be in the ratio of
3400 lbs sand: 150 lbs cement: 100 lbs flyash.
The mixture shall be plant mixed and shall have a compressive strength of 300 psi
at 28 days. The design of the mix may be modified if approved in writing by the
Engineer. Normal. strength concrete shall not be used for utility mix.
33. "Hillside" fill.
I
"Hillside" fill material, where shown on the plans or in the bid
bye cherty clay material locally referred to as "hillside".
material shall be supplied from off -site location and shall
approval by the Engineer. Compaction of "hillside" shall be
drawings or as specified int the technical specifications.
3�4. Disposal_ of waste materials
I
ID
I
I
I
I
Li
schedule, shall
All "hillside"
be subject to
is shown on the
The Contractor shall be responsible to disposal of all waste materials of all
types and conditions, including excavation materials not specified for reuse as
backfill, in compliance with all Federal, State and City of Fayetteville laws,
rules and regulations. The Engineer shall have the right to require the
Contractor to document the location of the disposal area and provide proof of
compliance with all Federal. State and City of Fayetteville laws, rules and
regulations for disposal of the materials.
End of Section 100 - General Project Requirements
Section 100 page 10
I
I
I
I
I
I
I
Li
I
Li
Section 110 METHODS OF MEASUREMENT AND PAYMENT
A. GENERAL
Methods of measurement and payment as set out in the Specifications covering the
various items of construction are hereby clarified and superseded as set out
herein. Wherever they are not clarified or superseded herein, methods of payment
as provided in the applicable section of the Specifications shall govern.
Payment for all work under this contract shall be made at the unit and lump sum
prices bid under the various items of the Bid as hereinafter set out.
Bid Items 1.7.22.32.34 and 35 - Water Line Pipe
' Payment for pipe shall be made at the unit prices bid per linear foot for
the various types and sizes of pipe, complete in place. The prices bid
' shall be full compensation for clearing, temporary fencing where
necessary, right of way preparation, surface removal, disposal of waste
materials, stripping and stockpiling topsoil where required, trenching,
disposal of trenched materials, furnishing and laying pipe, pipe bedding
' material, concrete thrust anchors where required, polyethylene encasement,
pipe detection tape, testing, sterilization, cleanup, repairing fences,
seeding, fertilizing, mulching, and every other item required for a
I. complete installation as specified with the sole exception of the Class 7
aggregate backfill, which shall be used for crossing driveways, and paved
areas, shall be paid for under bid item 424.
' Measurement will be based on the total length of the line, including pipe
required for ties to the existing system, with no deduction made for
valves or fittings.
' Measurement shall be made with a 100 foot tape along the centerline of the
pipeline after the trench has been backfilled. The footage installed to
' be paid for will be reflected in a daily written report, a copy of which
will be furnished to the Contractor.
' Bid Item 2 - Butterfly Valve with Box
Payment for butterfly valves shall be made at the unit price bid for each
' valve, complete in place. The price shall include furnishing and installing
valves, valve boxes, concrete pad at ground surface, valve operator
extension stem, and every other item required for complete installation as
specified.
Bid Items 3 and 8 - Taooina Sleeve and Valve Assembly
' Payment for tapping sleeve and valve shall be made at the unit price bid
for each assembly, complete in place. The price shall include furnishing
and installing tapping sleeve and valve, valve box, concrete pad at ground
' surface, valve operator extension stem (if required), and every other item
required for a complete installation as specified.
I
it
I
Payment for compact ductile iron fittings will be made at the unit price
bid per pound under this item for the various types of ductile iron
fittings, as provided. The unit price bid shall include the furnishing
and installation of the fittings, and all other related work not
t specifically compensated for under other items of the Bid. The weight of
the fittings 12 inches in diameter and smaller will be based on standard
AWWA C153/A21.53 weight tables for naked, compact mechanical joint
' fittings. The price bid shall include furnishing and installing the
fittings and the required concrete reaction backing in accordance with the
reaction detail schedule set out on the Plans.
• -°
' Payment for gate valves shall be made at the unit price bid for each of
the various sizes of valves, complete in place. The price shall include
furnishing and installing valves, valve boxes, concrete pad at ground
surface, valve operator extension stems, and every other item required for
'a complete installation as specified.
Bid Items 9 - Fire Hydrants
' Payment for fire hydrant assemblies will be made at the unit price bid for.
The bid price shall include furnishing and
installation of the fire hydrant, fire hydrant barrel extension if
' required, 6 inch ductile iron pipe, polyethylene encasement, main line
fitting, boss, or outlet, auxiliary gate valve, valve box and box
extension. All fittings, locked hydrant adapters, gravel
' drain, concrete collar, concrete support and reaction blocking will be
included in this pay item.
Bid Item 10 - Reconnect Service line by Bore Under Highway
' Payment under this item shall be made in accordance with the unit price bid
for each crossing, complete bore with 2" casing and 3/4" copper line
crossing.
Bid Item 11 - Connect services
Payment for the connection of existing services, to the new water lines
' shall be made at the unit price bid for 3/4" copper line defined on the
drawings. The price bid shall include all excavation of existing lines,
cutting existing lines, removal and replacement of existing fittings as
required, making connection of new water line to existing meters,
'
backfilling, cleanup, seeding, and every other item of work not
specifically compensated for under other items of the Bid required for a
complete installation.
2
Bid Item 12 - Topsoil/Seedina/Mulching
Payment under this item shall be made in accordance with the lump sum price
bid. The payment shall be for the percentage of project completed at the
time of payment.
' Bid Item 13 - Remove and Relay or Lay New Sod
Payment under this item shall be made in accordance with the lump sum price
Ibid. The price bid shall be for full compensation for either preserving the
existing sod and relaying it, or match the existing sod and lay new sod.
Payment for this item shall be made only after all sod sections are laid
and completed.
-un:euti
._• . .�-.__ •. - C -•-
I1
LJ
C
H
C
H
H
H
H
Payment for six inch thickness concrete driveway repair shall be made at
the unit price bid per square yard. The unit price bid shall be full
compensation for the removal and disposal of identified driveway areas,
furnishing and placement of concrete, all forming, labor, equipment, tools
and any other items required for a complete installation for driveway
repairs as determined necessary by the Engineer during construction.
.ttt)iiat
It.J,Ilt144t.J.W11-
Payment under this item shall be made in accordance with the unit price
bid. This unit price shall include the 2" tap and 2" pipe and all necessary
fittings and materials to connect the existing meter to the new water line.
Payment for the final asphalt street or parking lot repair shall be made
at the unit price bid per square yard. The unit price bid shall be full
compensation for the removal and disposal of the base material to the
depth required for the repairs as detailed on the contract drawings,
furnishing and placement of concrete, prime, hot mix asphalt concrete
(RMAC), all forming, labor, equipment, tools and any other items required
for a complete installation for asphalt street or asphalt parking lot
repairs as specified on the plans and defined in the technical
specifications. Measurement shall be allowed for a five (5) wide trench
only and to the nearest 0.1 square yard of final repair product in place.
Payment under this item shall be made in accordance with the lump sum
price bid. The price bid shall be full compensation for all mobilization,
storage and field incidentals. Payment under this item will be made as
a percentage of project completion.
3
I
I
tc'n - r r •.p )xs - •r -u.
I11
I
I
I
I
I
H
I
I
H
I
II
I
H
H
H
Payment under this item shall be made in accordance with the lump sum
price bid. The price bid shall be full compensation for trench or
excavation safety system requirements in accordance with Act 291 of the
1993 Arkansas General Assembly. Payment under this item will not be made
until project is completed, accepted, and the Contractor certifies that he
has met all requirements as set out in said Act 291.
Payment under this item shall be made in accordance to the unit bid price
and complete installation of curb and gutter per standards of the detail
drawings.
Payment under this item shall be made in accordance to the unit bid price
per square yard as measured, and per standards as specified.
Payment under this item shall be made in accordance to the unit bid price
per each hydrant, and only when salvaged and delivered to the City's
Operation Center located on Cato Springs Rd.
Payment for the excavation of "rock as defined in Section 320 of the
specifications shall be made at the unit price bid per cubic yard. Such
price shall be full compensation for excavation and proper disposal of
"rock" as defined in section 320.
p:ff• -u*tn-nt.c.i 43,ftbtfla.fNflhl
Payment for class 7 aggregate backfill will be made at the unit price bid
per ton for compacted class 7 aggregate as provided. The unit price bid
shall include the furnishing, compaction, testing and maintenance of class
7 aggregate backfill in all trenches in the roadway as shown on the plans
and as specified. Measurement shall be based upon verifiable truck
weight tickets furnished by the contractor to the engineer for quantities
up to the theoretical limits of the excavation required by the drawings
and specifications. No payment will be allowed for trench widths (in
excess of 5') or depths in excess of the requirements of the drawings and
specifications unless approved in advance by the engineer as necessitated
by field conflicts.
• 'u r .r• .. r.
This project requires very little clearing and grubbing. The lump sum price
bid shall be full compensation clearing, grubbing,proper disposal of
cleared materials, shaping, seeding and restoration of the utility and
51
J
access/utility easements as shown on the plans and/or specified
' elsewhere.
Bid Item 26 - Erosion Control
Payment under this item shall be made in accordance with the lump sum price bid.
The price bid shall be full compensation for erosion control measures required
to prevent erosion of materials onto the City streets or onto the Highway or
' private property as shown on the plans and/or shown elsewhere.
Bid Item 27 - Cap and Plua Existing Abandoned Water Lines
' Payment under this item shall be made in accordance with the lump sum price
bid. The price bid shall be full compensation for capping and plugging all
the existing water pipes that are killed and abandoned. This item shall
be paid for at the completion of the project.
' Bid Item 28.30.31 and 33 - Highway Bore Steel Encasement Pipe
Payment for the bore and encasement under the Highway or street shall be
' made at the unit price bid per foot of installation. The unit price bid
shall include the furnishing and installation of the smooth wall steel
encasement pipe (with specified thickness), the stainless steel spacers
' (Cascade Water or equal), placement of the Fernco Boots to seal the
ends of the pipes and all other related work not specifically
compensated for under items of the bid. The carrier pipes are on
' separate bid items. Payment shall be made only
for successful bores which satisfy the requirements of the plans and
specifications and are on desired grade.
Bid Item 29 - 8" D.I.P. (with Field Lock Gaskets) Sewer Pipe for Highway Xina
Payment for pipe shall be made at the unit prices bid per linear foot for
the sewer pipe, complete in place. The prices bid shall be full
compensation for clearing, temporary fencing where necessary, right of way
' preparation, surface removal, disposal of waste materials, stripping and
stockpiling topsoil where required, trenching, disposal of trenched
materials, furnishing and laying pipe, pipe bedding material,pipe
' detection tape, testing, cleanup, repairing fences, seeding, fertilizing,
mulching, and every other item required for a complete installation as
specified with the sole exception of the Class 7 aggregate backfill, which
shall be used for crossing driveways, and paved areas, shall be paid for
under bid item #24.
Measurement will be based on the total length of the line, including pipe
' required for ties to the existing system, with no deduction made for
valves or fittings.
Measurement shall be made with a 100 foot tape along the centerline of the
' pipeline after the trench has been backfilled. The footage installed to
be paid for will be reflected in a daily written report, a copy of which
will be furnished to the Contractor.
1
5
I
Payment under this item shall be made in accordance with the unit price
Ibid. 8" sewer pipe must be installed in the encasement pipe, and across the
Highway Right of way on desired grade as shown on the plans. Payment shall
be made for successful bore and the desired grade only.
Bid Item 32 34 and 35 - D.I.P. carrier pipes for Highway Crossings
C
I
I
I
I
I
I
I
I
I
I
Payment under this item shall be made in accordance with the unit price
bid. 6", 8, and 18" water pipe must be installed in the encasement pipe,
and across the Highway Right of Way on desired grade as shown on the
plans. Payment shall be made for successful bore and the desired grade
only. Also to apply are the requirements of Bid Item No.l.
Payment for 4 foot diameter cast -in -place manhole 8-10 feet in total depth
shall be paid at the unit price per vertical linear foot. The price bid
shall be made at the unit price bid per vertical linear foot. The price bid
shall be full compensation for every item of work to complete the manhole
barrel extensions as shown on the plans and specified, including forming
of 4 foot barrel, concrete, exterior waterproofing, backfill and every
other item required for a complete installation as shown on the plans and
specified.
Bid Item 37 - Connection of New 8• Sewer to Existing Manhole
Payment under this item shall be made in accordance with the lump sum price
bid. The price bid shall be full compensation for the connection complete
in place including core drilling (to the desired grade) , waterstop gasket,
concrete, grout, water/dye testing, and complete connection and invert
adjustments and sealing and waterproofing the existing manhole. Payment
under this item shall not be made until it passes all inspections.
Payment for sewer line pipe shall be made at the unit prices bid per linear
foot for the pipe, complete in place. The prices bid shall be full
compensation for clearing, temporary fencing where necessary, furnishing
and laying pipe, bedding material, pipe detection tape, testing, cleanup,
all other restorations. Plus all the pay item requirements of Item 29.
• ll • ,,xz..tvP1Iuatnn.wNfl ICn4a.fl.)iI,n44i.tLtajqa,t,tac
' Payment for Hillside Backfill Material shall be paid for each compacted
cubic yard of material to 95% standard compaction, for any excavation
within the Highway R.O.W. or other designated areas. The Unit price bid
' shall include the furnishing, compaction and testing of the hillside
backfill in all trenches in the Highway R.O.W. or any other designated
areas. Measurement shall be based upon verified quantities up to the
theoretical limits of the excavation required by the drawings and
'
specifications. No payment will be allowed for trench widths inexcess of
5 feet wide or excess of depths beyond the requirements of the plans
unless approved by the engineer
6
1
Bid Item 40 - New 3/4" meter box setting
' Payment for new meter box settings shall be paid for each new box set.
This item will include complete meter yoke, box and lid installed to the
' desired grade set in the field by the Engineer, and connected to the
existing servise line.
H
End of Section 110 Measurement and Payment
I
I
I
H
I
I
I
I
I
I
I
I
7
I
Section 120 TESTING
1. General.
The Contractor shall be responsible for and shall pay all costs associated with
any inspection or testing required in connection with the Owner's or Engineer's
acceptance of materials or equipment incorporated in the work, as provided for
in Article 13 of the General Conditions and Article SC -13 of the Supplementary
Conditions and paragraph 28 of Section 100, General Project Requirements -
Testing.
' 2. Certificates of Compliance.
The Contractor shall be responsible for furnish to the Engineer materials and
equipment manufacturers' duly sworn certificates of compliance with all
' requirements and provisions of applicable standards such as, but not limited to,
AWWA, ASTM, ANSI, AASHTO, AHTD or others for all materials and equipment
delivered to this project.
' The City of Fayetteville shall have the right to approve or reject the
contractor's proposed lab based upon sound Engineering principles. Copies of all
testing reports must be forwarded directly to the Engineer by the testing
laboratory.
' 3 . Specific Requirements.
' Specific requirements for testing and certificates of compliance are set forth
in the Technical Specifications for each item of work.
S
All field tests required for a project shall be witnessed by the City Engineering
' Division representatives in the presence of the Engineer and Contractor, or their
approved representatives.
All tests require a minimum notice of 24 hours. The 24 hours is a minimum only,
' the exact time for testing and required inspections shall be determined by the
City of Fayetteville Engineering Office.
I
I
I
I
I
I
I
1
L
I
I
I
I
C
I
I
I
The Contractor shall utilize and maintain through project completion, scheduling
of all phases of work required for completion of the project within the contract
time. Such schedule shall follow the requirements of Article 6 of the General
Conditions and Article SC -6 of the Supplementary Conditions, Paragraphs 3 and 5
of Technical Specification 100, General Project Requirements, and as specified
herein. The schedule; project status and progress of the work will be reviewed
at a weekly progress meeting.
t%nz.tlkn
The Contractor shall show all various phases of work to be performed,
submittals, materials, and equipment, manpower, skills, and equipment required,
and completion dates of various phases of the work to be performed for the timely
and proper completion of the project. The schedule must be in such detail that
the Contractor and Engineer can readily determine the work as planned and be able
to notify affected or adjacent property owners of the dates and times of work on
or adjacent to their property.
a
The Contractor's superintendent and the Engineer's Representative and others
' identified as needing to participate shall attend a weekly progress meeting
scheduled by the Engineer or his representative. The status of the project,
schedule and work to be accomplished in the next week will be reviewed and
discussed.
The location of the meeting will be as
set by
the Engineer at a time
'
agreeable
with the Contractor and the Engineer.
I
I
H
I
I
The Contractor, on the basis of the schedule and progress meetings shall notify
the appropriate property owners of trenching, pipe laying, cleanup or other
activities scheduled to occur on, or adjacent to, their property during the forth
coming week. The minimum acceptable notification of property owners will be 48
hours in advance of occupying, storing materials on, or performing work on any
right-of-way or easement. It shall be the responsibility of the Contractor to
provide a minimum of 72 hours advance notice to the Engineer, Traffic Department,
Police and Fire Department prior to cutting or blocking any public street or
roadway.
All planned interruptions of water service shall be coordinated with the Engineer
and the Fayetteville Water Department. A minimum of 48 hours notice shall be
required. Service interruptions shall require advance approval from the Engineer
and if allowed by the Engineer, shall be scheduled between 8:00 a.m. and 5:00
p.m. unless specifically approved otherwise.
For full details see Appendix "C"
1
H
C
I
I
I
I
L
I
L
I
I
I
I
I
I
Section 300 CRUSHED STONE BASE
1. General.
The work to be included under this section of the Specifications shall consist
of providing all materials, labor, equipment, tools, supplies and incidentals
necessary for the completion of crushed stone base in areas which are presently
paved or which are to be paved, as shown on the contract plans and herein
specified.
2. Materials and execution.
All crushed stone base shall be Class 7 Aggregate Base Course as specified in
Table 303-1, page 161, in section 303 AGGREGATE BASE COURSE, of the "Standard
Specifications for HIGHWAY CONSTRUCTION," Edition of 1993, published by the
Arkansas State Highway and Transportation Department.
Crushed stone base course shall be compacted to a minimum of 95 percent of
Modified Proctor Density (ASTM D1557-78).
3. Testing.
All Testing, gradation, plasticity, modified proctor standards and in -place
densities of crushed stone base course shall be performed by a qualified lab in
accordance with Article 13 of the General Conditions, Article SC -13 of the
Supplementary Conditions and paragraph 27 of Section 100 GENERAL PROJECT
REQUIREMENTS.
Each paved crossing requiring crushed stone base course shall require a minimum
of one test report documenting an in -place density of at least 95 percent of
Modified Proctor Density.
For pipelines parallel in the street, one density test shall be taken per 250
feet or portion thereof.
4. Measurement and Payment.
Crushed stone base course shall be measured and paid by the unit as established
in the Bid schedule. If no separate bid or pay item exists for crushed stone
base course then all crushed stone base course will be subsidiary and no separate
payment will be made.
3
I
Section 310 PIPE BEDDING MATERIAL
' 1. General.
' The work to be included under this section of the Specifications shall consist
of providing all materials, labor, equipment, tools, supplies and incidentals
necessary for the completion of pipe bedding material as shown on the contract
plans and herein specified.
' 2. Materials and execution.
I
I
I
I
I
I
I
I
I1
I
I
L
I
All pipe bedding materials shall be:
(1) ASTM D2774 - maximum particle size 1/2 inch. Contractor shall furnish
laboratory data documenting compliance with ASTM D2774 requirements prior to
placing of bedding material, or
(2) "Grit" as locally manufactu-ed from crushed limestone. All "grit"
material shall be durable crushed aggregate with a maximum particle size of 5/16
inch and a maximum percentage passing the no. 200 sieve of 10 percent, or
(3) Sand. Sand shall consist of clean, hard, durable uncoated grains free
from lumps, clay and organic materials. All (100%) of "sand" shall pass a no.
B sieve.
3. Execution
All pipe, regardless of type and material composition of the pipe, shall be
bedded with a minimum of 6 inches below the pipe to a minimum of 6 inches over
the top of the pipe the full width of the trench. Bedding material shall be
placed in maximum of 6 inch lifts and compacted with mechanical tamping
equipment. The Contractor shall use special care under pipe haunches and
fittings.
4. Testing and submittals.
The Contractor, prior to delivery of material, shall furnish the supplier's
certificates of compliance with these specifications.
5. Payment.
NO SEPARATE PAYMENT shall be made for pipe bedding material, complete as shown
and specified.
End of Section 310
1
I
Section 320 ROCK EXCAVATION
1. General.
' The work to be included under this section of the Specifications shall consist
of providing all materials, labor, equipment, tools, supplies and incidentals
necessary for the excavation and propoer disposal of "ROCK" as defined in the
following.
2. Materials.
' "ROCK" excavation shall be defined as all igneous, metamorphic and sedimentary
material encountered which requires the systematic drilling and/or hammering for
removal. Thic shall include all boulders or other detached stones each having
a volume of one cubic yard or more.
3. Execution.
' Blasting shall not be allowed.
Rock excavation shall be accomplished by the use of drilling, hammering or other
mechanical means.
4. Payment.
SEPARATE PAYMENT shall be made for "ROCK" excavation as further defined in
SECTION 110 MEASUREMENT AND PAYMENT and the BID SCHEDULE.
' End of Section 310
n
I
Li
H
H
I
I
Section 502 CONCRETE
1 A. GENERAL
' This work consists of all concrete work, forms, reinforcing and related items
necessary to complete all Concrete Paving, driving surface repairs, Street
repairs, sidewalk, curbs and gutter, reaction backing and other concrete work as
indicated on the drawings and described in the specifications.
B. REFERENCED MATERIALS AND CONSTRUCTION.
The following Specifications are hereby referenced and made a part cf these
Specifications. These Specifications are contained in the Standard
Specifications for Highway Construction,' Edition of 1993: published by the
Arkansas State Highway Commission. The page numbers given below refer to pages
in these Standard Specifications for Highway Construction.'
These Specifications are available for inspection in the Engineer's office, or
may be obtained from the Arkansas State Highway Department, Little Rock,
Arkansas, and are set out below.
' DIVISION 500 RIGID PAVEMENT Pages
SECTION 501 through SECTION 512 . . . . . . . . . . . . . . . 271 - 324
' DIVISION 600 INCIDENTAL CONSTRUCTION Pages
SECTION 609 DROP INLETS AND JUNCTION BOXES . . . . . . . . . 368 - 371
SECTION 633 CONCRETE WALKS AND STEPS.. . . . . . . ; . 438 - 438
I. SECTION 634 CURBING 440 - 443
DIVISION 800 STRUCTURES Pages
SECTION 802 CONCRETE FOR STRUCTURES . . . . . . . ; . . . . 561 - 614
SECTION 804 REINFORCING STEEL FOR STRUCTURES 616 - 623
All concrete for this project shall conform to the above referenced "Standard
'
Specifications for Highway Construction,' Edition of 1993, published by the
Arkansas State Highway Commission with the following specific exceptions.
1. All concrete shall be ready -mix type concrete. The Contractor shall not
'
batch or mix concrete.
2. Class "A" concrete is defined as a concrete with a minimum 28 day compressive
' strength of 3,000 psi. Class "A" concrete shall be used for constructing
manholes and other structures, concrete driveway repair, sidewalk repair and curb
and gutter repair, reaction backing, pipe encasement, and where otherwise
directed by the Engineer.
3. All concrete shall have air entrainment added at the ready -mix plant by the
concrete supplier. Concrete for paving shall have air entrainment of
6 % +/- 1 1/2 % (4.5 to 7.5 percent). All other concrete shall have air
' entrainment of 3 to 6 percent.
4. No other admixtures, including calcium chorlide, shall be permitted.
Is. TESTING
The Contractor, under the Engineer's supervision, shall take samples and make
tests as hereinafter listed for each 40 cubic yards of fresh concrete or fraction
thereof placed on the project, but not less than one set for each day's concrete
placement. It shall be the Contractor's responsibility to collect all samples,
prepare casting specimens, protect, cure, transport, and pay for all costs
associated with testing. The project inspector shall inspect the preparation of
' all specimens.
1
Slump Tests: Tests for slump shall be made at the place of deposit and in
accordance with ASTM C-143. Tests shall be made periodically, when cylinders are
made, and as often in the opinion of the Engineer when a change in consistency
of the concrete mix is noted. The Contractor shall have a slump cone at the job
site at all times when concreting operations are in progress. Unless otherwise
noted or specified, the slump shall be within the limits of 1 to 4 inches.
Compression and Strength Tests: Each test shall consist of four standard 6 inch
by 12 inch cylinders; two cylinders to be tested at the age of seven days and two
cylinders at the age of 28 days. Samples shall be taken, cured and tested in
accordance with latest ASTM standards.
When the ultimate compressive strength of any cylinder falls below the specified
strength for the class of concrete specified, the design mix and water content
shall be adjusted to produce the specified strength for concrete that is
subsequently placed. In addition, the Engineer may order additional curing for
that portion of the structure where the questionable concrete has been placed.
In the event that such additional curing does not give the strength required, as
determined by load tests made in accordance with ACT 318, or cored cylinder
tests, and if such tests indicate the necessity, the defective parts shall be
removed and replaced, or shall be reinforced as directed by the Engineer, at the
Contractor's expense, including the expense of the tests.
I
71 Measurement and payment shall be as defined in the Bid Proposal and/or as
specified elsewhere in these specifications.
Unless specifically noted above, the referenced 'Standard Specifications for
Highway Construction,Edition of 1993, published by the Arkansas State Highway
Commission will control.
End of Section 502 I
'
'
'
i
'
2'
'
I
Section 611 Pipe Underdrains (a.k.a. "French Drains")
A. GENERAL
' This work consists of constructing underdrains using pipe, aggregate and
geotextile filter material including trench excavation, backfill and cleanup.
' B. REFERENCED MATERIALS AND CONSTRUCTION.
The following Specifications are hereby referenced and made a part of these
Specifications. These Specifications are contained in the Standard
Specifications for Highway Construction,Edition of 1993, published by the
Arkansas State Highway Commission. The page numbers given below refer to pages
in these Standard Specifications for Highway Construction.'
' These Specifications are available for inspection in the Engineer's office, or
may be obtained from the Arkansas State Highway Department, Little Rock,
Arkansas, and are set out below.
DIVISION 600 INCIDENTAL CONSTRUCTION Pages
SECTION 611 Pipe Underdrains, outlet protectors and covers . 373 - 376
' C. CONSTRUCTION.
The pipe underdrain system shall be constructed in the location shown, and to the
dimensions as detailed on the contract plans.
Surface preparation, trenching, cleanup and restoration shall be as defined
elsewhere in these specifications.
D. MEASUREMENT AND PAYMENT.
Li
LI
U
L1
I
Li
Measurement and payment shall be as defined in the Bid Proposal and/or as
specified elsewhere in these specifications.
Unless specifically noted above, the referenced 'Standard Specifications for
Highway Construction,' Edition of 1993, published by the Arkansas State Highway
Commission will control.
End of Section 611
1
§1926.606
29 CFR-Ch. XVII (7-1-92 Edition)
(6) Obstructions shall not be laid on
or across the gangway.
(7) The means of access shall be ade-
quately illuminated for its full length.
(8) Unless the structure makes it im-
possible, the means .of access shall be
so located that the load will not pass
over employees.
(c) Working surfaces of barges. (1)
Employees shall not be permitted to
walk along the sides of covered light-
ers or barges with coamings more than
5 feet high, unless there is a 3 -foot
clear walkway, or a grab rail, or a taut
handline is provided.
I (2) Decks and other working sur-
faces shall be maintained in a safe
condition.
(3) Employees shall not be permitted
to pass fore and aft, over, or around
deckloads, unless there is a safe pas-
sage.
j (4) Employees shall not be permitted
to walk over deckloads from rail to
coaming unless there is a safe passage.
If it is necessary to stand at the out-
board or inboard edge of the deckload
where less than 24 inches of bulwark,
fail, coaming, or other protection
exists, all employees shall be provided
with a suitable means of protection
against falling from the deckload.
(d) First -aid and lifesaving equip-
ment. (1) Provisions for rendering first
aid and medical assistance shall be in
accordance with Subpart D of this
part.
(2) The employer shall ensure that
there is in the vicinity of each barge in
use at least one U.S. Coast Guard -ap-
proved 30 -inch lifering with not less
than 90 feet of line attached, and at
least one portable or permanent
ladder which will reach the top of the
apron to the surface of the water. If
the above equipment is not available
at the pier, the employer shall furnish
it during the time that he is working
the barge.
(3) Employees walking or working on
the unguarded decks of barges shall be
protected with U.S. Coast Guard -ap-
proved work vests or buoyant vests.
(e) Commercial diving operations,
Commercial diving operations shall be
subject to subpart T of part 1910,
§ § 1910.401-1910.441, of this chapter.
(39 FR 22801, June 24, 1974, as amended at
42 FR 37674, July 22, 1977]
§ 1926.606 Definitions applicable to this
subpart.
(a) Apron —The area along the wa-
terfront edge of the pier or wharf.
(b) Bulwark —The side of a ship
above the upper deck.
(c) Coaming—The raised frame, as
around a hatchway in the deck, to
keep out water.
(d) Jacob's. ladder —A marine ladder
of rope or chain, with wooden or metal
rungs. _
(e) Rail, for the purpose of
§ 1926.605, means a light structure
serving as a guard at the outer edge of
a ship's deck.
Subpart P —Excavations
AUTHORITY: Sec. 107, Contract Worker
Hours and Safety Standards Act (Construct
tion Safety Act) (40 U.S.C. 333); Secs. 4, 6, 8,
Occupational Safety and Health Act of
1970 (29 U.S.C. 653, 655, 657); Secretary of
Labor's Order No. 12-71 (36 FR 8754), 8-76
(41 FR 25059), or 9-83 (48 FR 35736), as ap-
plicable, and 29 CFR part 1911.
SOURCE, 54 FR 45959, Oct. 31, 1989, unless
otherwise noted.
§ 1926.650 Scope, application, and defini-
tions applicable to this subpart.
(a) Scope and application- This sub-
part applies to all open excavations
made in the earth's surface. Excava-
tions are defined to include trenches.
(b) Definitions applicable to this
subpart
Accepted engineering practices
means those requirements which are
compatible with standards of practice
required by a registered professional
engineer.
Aluminum Hydraulic Shoring means
a pre-engineered shoring system com-
prised of aluminum hydraulic cylin-
ders (crossbraces) used in conjunction
with vertical rails (uprights) or hori-
zontal rails (walers). Such system is
designed, specifically to support the
sidewalls of an excavation and prevent
cave-ins.
Bell-bottom pier hole means •a type
of shaft or footing excavation, the
bottom of which is made larger than
the cross section above to form a
belled shape.
I
I
I
I
[J
I
I
I
I
Hi
P1
L
I
I
11
I
I
I
ME
IOccupational Safety and Health Admin., Labor
§ 1926.650
I
I
I
I
r -
L
1J
I
H
L
U
I
I
IJ
7
7
L
I
Benching (Benching system) means
a method of protecting employees
from cave-ins by excavating the sides
of an excavation to form one or a
series of horizontal levels or steps,
usually with vertical or near -vertical
surfaces between levels.
Cave-in means the separation of a
mass of soil or rock material from the
side of an excavation, or the loss of
soil from under a trench shield or sup-
port system, and its sudden movement
into the excavation, either by falling
or sliding, in sufficient quantity so
that it could entrap, bury, or other-
wise injure and immobilize a person.
Competent person means one who is
capable of identifying existing and
predictable hazards in the surround-
ings, or working conditions which are
unsanitary, hazardous, or dangerous
to employees, and who has authoriza-
tion to take prompt corrective meas-
pres to eliminate them.
.s Cross braces mean the horizontal
members of a shoring system installed
perpendicular to the sides of the exca-
vation, the ends of which bear against
either uprights or wales.
Excavation means any man-made
cut, cavity, trench, or depression in an
earth surface, formed by earth remov-
al.
Faces or sides means the vertical or
inclined earth surfaces formed as a
result of excavation work.
Failure means the breakage, dis-
placement, or permanent deformation
of a structural member or connection
so as to reduce its structural integrity
and its supportive capabilities.
Hazardous atmosphere means an at-
mosphere which by reason of being ex-
plosive, flammable, poisonous, corro-
sive, oxidizing, irritating, oxygen defi-
cient, toxic, or otherwise harmful, may
cause death, illness, or injury.
Kickout means the accidental re-
lease or failure of a cross brace.
Protective system means a method of
protecting employees from cave-ins,
from material that could fall or roll
from an excavation face or into an ex-
cavation, or from the collapse of adja-
cent structures. Protective systems in-
clude support systems, sloping and
benching systems, shield systems, and
other systems that provide the neces-
sary protection.
Ramp means an inclined walking or
working surface that is used to gain
access to one point from another, and
is constructed from earth or from
structural materials such as steel or
wood.
Registered Professional Engineer
means a person who is registered as a
professional engineer in the state
where the work is to be performed.
However, a professional engineer, reg-
istered in any state is deemed to be a
"registered professional engineer"
within the meaning of this standard
when approving designs for "manufac-
tured protective systems" or "tabulat-
ed data" to be used in interstate com-
merce.
Sheeting means the members of a
shoring system that retain the earth
in position and in turn are supported
by other members of the shoring
system.
Shield (Shield system) means a
structure that is able to withstand the
forces imposed on it by a cave-in and
thereby protect employees within the
structure. Shields can be permanent
structures or can be designed to be
portable and moved along as work pro-
gresses. Additionally, shields can be
either premanufactured or job -built in
accordance with § 1926.652 (c)(3) or
(c)(4). Shields used in trenches are
usually referred to as "trench boxes"
or "trench shields."
Shoring (Shoring system) means a
structure such as a metal hydraulic,
mechanical or timber shoring system
that supports the sides of an excava-
tion and which is designed to. prevent
cave-ins.
Sides. See "Faces."
Sloping (Sloping system) means a
method of protecting employees from
cave-ins by excavating to form sides of
an excavation that are inclined away
from the excavation so as to prevent
cave-ins. The angle of incline required
to prevent a cave-in varies with differ-
ences in such factors as the soil type,
environmental conditions of exposure,
and application of surcharge loads.
Stable rock means natural solid min-
eral material that can be excavated
with vertical sides and will remain
intact while exposed. Unstable rock is
considered to be stable when the rock
material on the side or sides of the ex -
Li
219
§ 1926.651
29 CFR Ch. XVIi (7-1-92 Edition)
cavation is secured against caving -in or
movement by rock bolts or by another
protective system that has been de-
signed by a registered professional en-
gineer.
Structural ramp means a ramp built
'of steel or wood, usually used for vehi-
cle access. Ramps made of soil or rock
are not considered structural ramps.
Support system means a structure
such as underpinning, bracing, or
shoring, which provides support to an
adjacent structure, underground in-
stallation, or the sides of an excava-
tion.
Tabulated data means tables and
charts approved -by a registered prof es-
sional engineer and used to design and
construct a protective system.
Trench (Trench excavation) means a
narrow excavation (in relation to its
length) made below the surface of the
ground. In general, the depth is great-
er than the width, but the width of a
trench (measured at the bottom) is
knot greater than 15 feet (4.6 m). If
1forms or other structures are installed
,or constructed in an excavation so as
Ito reduce the dimension measured
from the forms or structure to the side
of the excavation to 15 feet (4.6 m) or
less (measured at the bottom of the
excavation), the excavation is also con-
sidered to be a trench.
Trench box. See "Shield."
Trench shield. See "Shield."
Uprights means the vertical mem-
bers of a trench shoring system placed
iri contact with the earth and usually
positioned so that individual members
do not contact each other. Uprights
placed so that individual members are
closely spaced, in contact with or
interconnected to each other, are
often called "sheeting."
Wales means horizontal members of
a shoring system placed parallel to the
excavation face whose sides bear
against the vertical members of the
shoring system or earth.
§ 1926.651 General requirements.
(a) Surface encumbrances. All sur-
face encumbrances that are located so
as to create a hazard to employees
shall be removed or supported, as nec-
essary, to safeguard employees.
(b) Underground installations. (1)
The estimated location of utility in-
i
stallations, such as sewer, telephone,
fuel, electric, water lines, or any other
underground installations that reason-
ably may be expected to be encoun-
tered during excavation work, shall be
determined prior to opening an exca-
vation.
(2) Utility companies or owners shall
be contacted within established or cus-
tomary local response times, advised
of the proposed work, and asked to es-
tablish the location of the utility un-
derground installations prior to the
start of actual excavation. When utili-
ty companies or owners cannot re-
spond to a request to locate under-
ground utility installations within 24
hours (unless a longer period is re-
quired by state or local law), or cannot
establish the exact location of these
installations, the employer may pro-
ceed, provided the employer does so
with caution, and provided detection
equipment or other acceptable means
to locate utility installations are used.
(3) When excavation operations ap-
proach the estimated location of un-
derground installations, the exact lo-
cation of the installations shall be de-
termined by safe and acceptable
means.
(4) While the excavation is open, un-
derground installations shall be pro-
tected, supported or removed as neces-
sary to safeguard employees.
(c) Access and egress —(1) Structural
ramps. (i) Structural ramps that are
used solely by employees as a means of
access or egress from excavations shall
•be designed by a competent person.
Structural ramps used for access or
egress of equipment shall be designed
by a competent person qualified in
structural design, and shall be con-
structed in accordance with the
design.
(ii) Ramps and runways constructed
of two or more structural members
shall have the structural members
connected together to prevent dis-
placement.
(iii) Structural members used for
ramps and runways shall be of uni-
form thickness.
(iv) Cleats or other appropriate
means used to connect runway struc-
tural members shall be attached to the
bottom of the runway or shall be at -
I
Li
I
I
I
L1
I
I
I
I
I
G
I
I
I
I
I
U
220
I
IOccupational Safety and Health Admin., Labor
§ 1926.651
I
I
I
I
I
CJ
I
I
I
I
I
I
I
tached in a manner to prevent trip-
ping.
(v) Structural ramps used in lieu of
steps shall be provided with cleats or
other surface treatments on the top
surface to prevent slipping.
(2) Means of egress from trench exca-
vations. A stairway, ladder, ramp or
other safe means of egress shall be lo-
cated in trench excavations that are 4
feet (1.22 m) or more in depth so as to
require no more than 25 feet (7.62 m)
of lateral travel for employees.
(d) Exposure to vehicular traffic.
Employees exposed to public vehicular
traffic shall be provided with, and
shall wear, warning vests or other suit-
able garments marked with or made of
reflectorized or high -visibility materi-
al.
(e) Exposure to falling loads. No em-
ployee shall be permitted underneath
loads handled by lifting or digging
equipment. Employees shall be re-
quired to stand away from any vehicle
being loaded or unloaded to avoid
being struck by any spillage or falling
materials. Operators may remain in
the cabs of vehicles being loaded or
unloaded when the vehicles are
equipped, in accordance with
§ 1926.601(b)(6), to provide adequate
protection for the operator during
loading and unloading operations.
(f) Warning system for mobile equip-
ment. When mobile equipment is oper-
ated adjacent to an excavation, or
when such equipment is required to
approach the edge of an excavation,
and the operator does not have a clear
and direct view of the edge of the ex-
cavation, a warning system shall be
utilized such as barricades, hand or
mechanical signals, or stop logs. If pos-
sible, the grade should be away from
the excavation.
(g) Hazardous atmospheres —(1)
Testing and controls. In addition to
the requirements set forth in subparts
D and E of this part (29 CFR 1926.50-
1926.107) to prevent exposure to
harmful levels of atmospheric con-
taminants and to assure acceptable at-
mospheric conditions, the following re-
quirements shall apply-
(i) Where oxygen deficiency (atmos-
pheres containing less than 19.5 per-
cent oxygen) or a hazardous atmos-
phere exists or could reasonably be ex-
pected to exist, such as in excavations
in landfill areas or excavations in
areas where hazardous substances are
stored nearby, the atmospheres in the
excavation shall be tested before em-
ployees enter excavations greater than
4 feet (1.22 m) in depth.
(ii) Adequate precautions shall be
taken to prevent employee exposure to
atmospheres containing less than 19.5
percent oxygen and other hazardous
atmospheres. These precautions in-
clude providing proper respiratory
protection or ventilation in accordance
with subparts D and E of this part re-
spectively.
(iii) Adequate precaution shall be
taken such as providing ventilation, to
prevent employee exposure to an at-
mosphere containing a concentration
of a flammable gas in excess of 20 per-
cent of the lower flammable limit of
the gas.
(iv) When controls are used that are
intended to reduce the level of atmos-
pheric contaminants to acceptable
levels, testing shall be conducted as
often as necessary to ensure that the
atmosphere remains safe.
(2) Emergency rescue equipment. (i)
Emergency rescue equipment, such as
breathing apparatus, a safety harness
and line, or a basket stretcher, shall be
readily available where hazardous at-
mospheric conditions exist or may rea-
sonably be expected to develop during
work in an excavation. This equipment
shall be attended when in use.
(ii) Employees entering bell-bottom
pier holes, or other similar deep and
confined footing excavations, shall
wear a harness with a life -line securely
attached to it. The lifeline shall be
separate from any line used to handle
materials, and shall be individually at-
tended at all times while the employee
.wearing the lifeline is in the excava-
tion.
(h) Protection from hazards associ-
ated with water accumulation. (1) Em-
ployees shall not work in excavations
in which there is accumulated water,
or in excavations in which water is ac-
cumulating, unless adequate precau-
tions have been taken to protect em-
ployees against the hazards posed by
water accumulation. The precautions
necessary to protect employees ade-
quately vary with each situation, but
I
221
1926.651
29 CFQ Ch. XVII (7-1-92 Edition)
could include special support or shield
systems to.. protect from cave-ins,
water removal to control the level of
accumulating water, or use of a safety
harness and lifeline.
(2) If water is controlled or prevent-
ed from accumulating by the use of
water removal equipment, the water
removal equipment and operations
shall be monitored by a competent
person to ensure proper operation.
1 (3) If excavation work interrupts the
natural drainage of surface water
(such as streams), diversion ditches,
dikes, or other suitable means shall be
used to prevent surface water from en-
tering the excavation and to provide
adequate drainage of the area adja-
cent to the excavation. Excavations
subject to runoff from heavy rains will
require an inspection by a competent
person and compliance with para-
graphs (h)(1) and (h)(2) of this sec-
tion.
(i) Stability of adjacent structures.
(1) Where the stability of adjoining
buildings, walls, or other structures is
endangered by excavation operations,
support systems such as shoring, brac-
ing, or underpinning shall be provided
to ensure the stability of such struc-
tures for the protection of employees.
'(2) Excavation below the level of the
base or footing of any foundation or
retaining wall that could be reason-
ably expected to pose a hazard to em-
ployees shall not be permitted except
when:
(i) A support system, such as under-
pinning, is provided to ensure the
safety of employees and the stability
of the structure; or
(ii) The excavation is in stable rock;
or, -
(iii) A registered professional engi-
neer has approved the determination
that the structure is sufficently re-
moved from the excavation so as to be
unaffected by the excavation activity;
orl
(iv) A registered professional engi-
neer has approved the determination
that such excavation work will not
pose a hazard to employees..
(3) Sidewalks, pavements, and appur-
tenant structure shall not be under -
m ned unless a support system or an-
other method of protection is provided
to protect employees from the possible
collapse of such structures.
(j) Protection of employees from
loose rock or soil. (1) Adequate protec-
tion shall be provided to protect em-
ployees from loose rock or soil that
could pose a hazard by falling or roll-
ing from an excavation face. Such pro-
tection shall consist of scaling to
remove loose material; installation of
protective barricades at intervals as
necessary on the face to stop and con-
tain falling material; or -other means
that provide equivalent protection.
(2) Employeesshall be protected
from excavated 'or other materials or
equipment that could pose a hazard by
falling or rolling into excavations. Pro-
tection shall be provided by. placing
and keeping such materials or equip -
merit at least 2 feet (.61 m) from the
edge of excavations, or by the use of
retaining devices that are sufficient to
prevent materials or equipment from
falling or rolling into excavations, or
by a combination of both if necessary.
(k) Inspections. (1) Daily inspections
of excavations, the adjacent areas, and
protective systems shall be made by a
competent person for evidence of a sit-
uation that could result in possible
cave-ins, indications of failure of pro-
tective systems, hazardous atmos-
pheres, or other hazardous conditions.
An inspection shall be conducted by
the competent person prior to the
start of work and as needed through-
out the shift. Inspections shall also be
made after every rainstorm or other
hazard increasing occurrence. These
inspections are only required when
employee exposure can be reasonably
anticipated.
(2) Where the competent person
finds evidence of a situation that could
result in a possible cave-in, indications
of failure of protective systems, haz-
ardous atmospheres, or other hazard-
ous conditions, exposed employees
shall be removed from the hazardous
area until the necessary precautions
have been taken .to ensure their
safety.
(1) Fall protection. (1) Where em=
ployees or equipment are required or
permitted to cross over excavations,
walkways or bridges with standard
guardrails shall be provided.
rl
L
h
I
U
I
7i
Li
I
I
I
I
I
I
H
I
222
S
IOccupational Safety and Health Admin., Labor
§ 1926.652
I
I
I
I
I
I
I
I
I
I
I
I
H
I
I
(2) Adequate barrier physical protec-
tion shall be provided at all remotely
located excavations. All wells, pits,
shafts, etc., shall be barricaded or cov-
ered. Upon completion of exploration
and similar operations, temporary
wells, pits, shafts, etc., shall be back -
filled.
§ 1926.652 Requirements for protective
systems.
(a) Protection of employees in exca-
vations. (1) Each employee in an exca-
vation shall be protected from cave-ins
by an adequate protective system de-
signed in accordance with paragraph
(b) or (c) of this section except when:
(i) Excavations are made entirely in
stable rock; or
(ii) Excavations are less than 5 feet
(1.52m) in depth and examination of
the ground by a competent person
provides no indication of a potential
cave-in.
(2) Protective systems shall have the
capacity to resist without failure all
loads that are intended or could rea-
sonably be expected to be applied or
transmitted to the system.
(b) Design of sloping and benching
systems. The slopes and configurations
of sloping and benching systems shall
be selected and constructed by the em-
ployer or his designee and shall be in
accordance with the requirements of
paragraph (b)(1); or, in the alterna-
tive, paragraph (b)(2); or, in the alter-
native, paragraph (b)(3), or, in the al-
ternative, paragraph (b)(4), as follows:
(1) Option (1) —Allowable configura-
tions and slopes. (i) Excavations shall
be sloped at an angle not steeper than
one and one-half horizontal to one
vertical (34 degrees measured from the
horizontal), unless the employer uses
one of the other options listed below.
(ii) Slopes specified in paragraph
(b)(1)(i) of this section, shall be exca-
vated to form configurations that are
in accordance with the slopes shown
for Type C soil in Appendix B to this
subpart.
(2) Option (2) —Determination of
slopes and configurations using Ap-
pendices A and B. Maximum allowable
slopes, and allowable configurations
for sloping and benching systems,
shall be determined in accordance
with the conditions and requirements
set forth in appendices A and B to this
subpart.
(3) Option (3) —Designs using other
tabulated data. (i) Designs of sloping
or benching systems shall be selected
from and be in accordance with tabu-
lated data, such as tables and charts.
(ii) The tabulated data shall be in
written form and shall include all of
the following:
(A) Identification of the parameters
that affect the selection of a sloping
or benching system drawn from such
data;
(B) Identification of the limits of use
of the data, to include the magnitude
and configuration of slopes deter-
mined to be safe;
(C) Explanatory information as may
be necessary to aid the user in making
a correct - selection of a protective
system from the data.
(iii) At least one copy of the tabulat-
ed data which identifies the registered
professional engineer who approved
the data, shall be maintained at the
jobsite during construction of the pro-
tective system. After that time the
data may be stored off the jobsite, but
a copy of the data shall be made avail-
able to the Secretary upon request.
(4) Option (4) —Design by a regis-
tered professional engineer. (i) Sloping
and benching systems not utilizing
Option (1) or Option (2) or Option (3)
under paragraph (b) of this section
shall be approved by a registered pro-
fessional engineer.
(ii) Designs shall be in written form
and shall include at least the follow-
ing:
(A) The magnitude of the slopes
that were determined to be safe for
the particular project;
(B) The configurations that were de-
termined to be safe for the particular
project; and
(C) The identity of the registered
professional engineer approving the
design.
(iii) At least one copy of the design
shall be maintained at the jobsite
while the slope is being constructed.
After that time the design need not be
at the jobsite, but a copy shall be
made available to the Secretary upon
request.
(c) Design of support systems, shield
systems, and other protective systems.
I
223
§ T926;652
29-CFR-Ch. XVf '=1 -'92 -Edition)
Designs of support systems shield sys-
tems,. and other protective systems
shall be. selected and -constructed by
the employer:or his designee and shall
be .in -zaccordance with -the require-
tnents of --paragraph (c)(i); or, in 'the
alternative, paragraph (c)(2); or, in the
alternative,?paragraph (c)(3); or, in.tlie
alternative; -paragraph (c)(4) as fol-
lows:
(1) Option (1) Designs using'appen-
dices A, C and D. Designs for timber
shoring in trenches shall be .deter-
mined in accordance with the condi-
tions and requirements set forth in ap-
pendices A and C to this subpart. De-
signs for aluminum hydraulic shoring
shall be in accordance with paragraph
(c)(2) of this section, but if manufac-
turer's tabulated data cannot be uti-
lized, designs shall be in accordance
with appendix D.
(2) Option (2) —Designs Using Manu-
facturer's Tabulated Data. (i) Design
of support systems, shield systems, or
'other protective systems that are
drawn from manufacturer's tabulated
data shall be in accordance with all
specifications, recommendations, and
limitations issued or made by the man-
ufacturer.
(ii) Deviation from the specifica-
tions, recommendations, and limita-
tions issued or made by the manufac-
turer shall only be allowed after the
manufacturer issues specific written
approval.
(iii) Manufacturer's specifications,
recommendations, and limitations, and
manufacturer's approval to deviate -
from the specifications, recommenda-
tions, and limitations shall be in writ-
ten form at the jobsite during con-
struction of the protective system.
After that time this data may be
stored off the jobsite, but a copy shall
be made available . to the Secretary
upon request.
(3) Option (3) Designs using other
tabulated data. (i) Designs of support
systems, shield systems, or other pro-
tective systems shall be selected from
and be in accordance with tabulated
data, such as tables and charts.
(ii) The tabulated data shall be in
written form and include all of the fol-
lowing:
(A) Identification -of .the parameters
that affect the selection of a :protec-
tive system .drawn from such .data;
(B) Identification of the-limits.of use
of the data;
(-C) Explanatory information as •may
be -necessary to aid.the user in:malcing
-a correct selection of a .protective
system from .the data.
(iii) At least one copy ofthe.tabuiat-
ed data, which identifies the 'regis-
tered professional engineer who ap-
-proved the data, shall be maintained
at the jobsite during construction . of -
the protective system After that time
the data may be stored off the jobsite,
but a copy of the data shall be made
available to the Secretary upon re-
quest.
(4) Option (4) —Design by a regis-
tered professional engineer. (i) Sup-
port systems, shield systems, and
other protective systems not utilizing
Option 1, Option 2 or Option 3, above,
shall be approved by a registered pro-
fessional engineer.
(ii) Designs shall be in written form
and shall include the following:
(A) A plan indicating the sizes,
types, and configurations of the mate-
rials to be used in the protective
system; and
(B) The identity of the registered
professional engineer approving the
design.
(iii) At least one copy of the design
shall be maintained at the jobsite
during construction of the protective
system. After that time, the design
may be stored off the jobsite, but a
copy of the design shall be made avail-
able to the Secretary upon request.
(d) Materials and equipment. (1) Ma-
terials and equipment used for protec-
tive systems shall be free from damage
or defects that might impair their
proper function.
(2) Manufactured materials and
equipment used for protective systems
shall be used and maintained in a
manner that is consistent with the rec-
ommendations of the manufacturer,,
and in a manner that will prevent em-
ployee exposure to hazards.
(3) When material or equipment
that is used for protective systems is
damaged, a competent person shall ex-
amine the material or'equipment:and
evaluate its suitability for continued
Li
I
I
I
I
I
1l
I
`J
I
L
I
I
I
I
I
I
224
IOccupational Safety and Health Admin., Labor
Subpt. P, App. A
I
I
I
I
I
I
I
I
I
I
I
L
I
Li
I
use. If the competent person cannot
assure the material or equipment is
able to support the intended loads or
is otherwise suitable for safe use, then
such material or equipment shall be
removed from service, and shall be
evaluated and approved by a regis-
tered professional engineer before
being returned to service.
(e) Installation and removal of sup-
port —(1) General (i) Members of sup-
port systems shall be securely connect-
ed together to prevent sliding, falling,
kickouts, or other predictable failure.
(ii) Support systems shall be in-
stalled and removed in a manner that
protects employees from cave-ins,
structural collapses, or from being
struck by members of the support
system.
(iii) Individual members of support
systems shall not be subjected to loads
exceeding those which those members
were designed to withstand.
(iv) Before temporary removal of in-
dividual members begins, additional
precautions shall be taken to ensure
the safety of employees, such as in-
stalling other structural members to
carry the loads imposed on the sup-
port system.
(v) Removal shall begin at, and
progress from, the bottom of the exca-
vation. Members shall be released
slowly so as to note any indication of
possible failure of the remaining mem-
bers of the structure or possible cave-
in of the sides of the excavation.
(vi) Back-illing shall progress to-
gether with the removal of support
systems from excavations. -
(2) Additional requirements for sup-
port systems for trench excavations. (i)
Excavation of material to a level no
greater than 2 feet (.61 m) below the
bottom of the members of a support
system shall be permitted, but only if
the system is designed to resist the
forces calculated for the full depth of
the trench, and there are no indica-
tions while the trench is open of a pos-
sible loss of soil from behind or below
the bottom of the support system.
(ii) Installation of a support system
shall be closely coordinated with the
excavation of trenches.
(f) Sloping and benching systems.
Employees shall not be permitted to
work on the faces of sloped or benched
excavations at levels above other em-
ployees except when employees at the
lower levels are adequately protected
from the hazard of falling, rolling, or
sliding material or equipment.
(g) Shield systems —(1) General (i)
Shield systems shall not be subjected
to loads exceeding those which the
system was designed to withstand.
(ii) Shields shall be installed in a
manner to restrict lateral or other
hazardous movement of the shield in
the event of the application of sudden
lateral loads.
(iii) Employees shall be protected
from the hazard of cave-ins when en-
tering or exiting the areas protected
by shields.
(iv) Employees shall not be allowed
in shields when shields are being in-
stalled, removed, or moved vertically.
(2) Additional requirement for shield
systems used in trench excavations.
Excavations of earth material to a
level not greater than 2 feet (.61 m)
below the bottom of a shield shall be
permitted, but only if the shield is de-
signed to resist the forces calculated
for the full depth of the trench, and
there are no indications while the
trench is open of a possible loss of soil
from behind or below the bottom of
the shield.
APPENDIX A TO SUBPART P -SOIL
CLASSIFICATION
(a) Scope and application ---(I) Scope. This
appendix describes a method of classifying
soil and rock deposits based on site and envi-
ronmental conditions, and on the structure
and composition of the earth deposits. The
appendix contains definitions, sets forth re-
quirements, and describes acceptable visual
and manual tests for use in classifying soils.
(2) Application. This appendix applies
when a - sloping or benching system is de-
signed in accordance with the requirements
set forth in § 1926.652(b)(2) as a method of
protection for employees from cave-ins.
This appendix also applies when timber
shoring for excavations is designed as a
method of protection from cave-ins in ac-
cordance with appendix C to subpart P of
part 1926, and when aluminum hydraulic
shoring is designed in accordance with ap-
pendix D. This Appendix also applies if
other protective systems are designed and
selected for use from data prepared in ac-
cordance with the requirements set forth in
§ 1926.652(c), and the use of the data is
[1
225
Subpt. P, App. A
29 CFR Ch. XVII (7-1-92 Edition)
predicated on the use of the soil classifica-
tion system set forth in this appendix.
(b) Definitions. The definitions and exam-
ples given below are based on, in whole or in
part, the following: American Society for
Testing Materials (ASTM) Standards D653-
85 and D2488; The Unified Soils Classifica-
tion System, The U.S. Department of Agri-
culture (USDA) Textural Classification
Scheme; and The National Bureau of Stand-
ards Report BSS -121.
Cemented soil means a soil in which the
particles are held together by a chemical
agent, such as calcium carbonate, such that
a hand -size sample cannot be crushed into
powder or individual soil particles by finger
pressure.
Cohesive soil means clay (fine grained
soil), or soil with a high clay content, which
has cohesive strength. Cohesive soil does
not crumble, can be excavated with vertical
sideslopes, and is plastic when moist. Cohe-
sive soil is hard to break up when dry, and
exhibits significant cohesion when sub-
merged. Cohesive soils include clayey silt,
sandy clay, silty clay, clay and organic clay.
Dry soil means soil that does not exhibit
visible signs of moisture content.
•;. Fissured means a soil material that has a
-tendency to break along definite planes of
fracture with little resistance, or a material
that exhibits open cracks, such as tension
cracks, in an exposed surface.
Granular soil means gravel, sand, or silt,
(coarse grained soil) with little or no clay
content. Granular soil has no cohesive
strength. Some moist granular soils exhibit
apparent cohesion. Granular soil cannot be
molded when moist and crumbles easily
when dry.
Layered system means two or more dis-
tinctly different soil or rock types arranged
in layers. Micaceous seams or weakened
planes in rock or shale are considered lay-
ered.
Moist soil means a condition in which a
soil looks and feels damp. Moist cohesive.
soil can easily be shaped into a ball and
rolled into small diameter threads before
crumbling. Moist granular soil that contains
some cohesive material will exhibit signs of
cohesion between particles.
Plastic means a property of a soil which
allows the soil to be deformed or molded
without cracking, or appreciable volume
change.
Saturated soil means a soil in which the
voids are filled with water. Saturation does
not require flow. Saturation, or near satura-
tion, is necessary for the proper use of in-
struments such as a pocket penetrometer or
sheer vane.
Soil classification system means, for the
purpose of this subpart, a method of catego-
rizing soil and rock deposits in a hierarchy
of Stable Rock, Type A, Type B, and Type
C, in decreasing order of stability. The cate-
gories are determined based on an analysis
of the properties and performance charac-
teristics of the deposits and the environ-
mental conditions of exposure.
Stable rock means natural solid mineral
matter that can be excavated with vertical
sides and remain intact while exposed.
Submerged soil means soil which is under-
water or is free seeping.
Type A means cohesive soils with an un-
confined compressive strength of 1.5 ton per
square foot (tsf) (144 kPa) or greater. Exam-
ples of cohesive soils are: clay, silty clay,
sandy clay, clay loam and, in some cases,
silty . clay loam and sandy clay loam. Ce-
mented soils such as caliche and hardpan
are also considered Type A. However, no soil
is Type A if:
(I) The soil is fissured; or
(ii) The soil is subject to vibration from
heavy traffic, pile driving, or similar effects;
or
(iii) The soil has been previously dis-
turbed; or
(iv) The soil is part of a sloped, layered
system where the layers dip into the excava-
tion on a slope of four horizontal to one ver-
tical (4H:1V) or greater; or
(v) The material is subject to other factors
that would require it to be classified as a
less stable material.
Type B means:
(i) Cohesive soil with an unconfined com-
pressive strength greater than 0.5 tsf (48
kPa) but less than 1.5 tsf (144 kPa); or
(ii) Granular cohesionless soils including:
angular gravel (similar to crushed rock), silt,
silt loam, sandy loam and, in some cases,
silty clay loam and sandy clay loam.
(iii) Previously disturbed soils except
those which would otherwise be classed as
Type C soil
(iv) Soil that meets the unconfined com-
pressive strength or cementation require-
ments for Type A, but is fissured or subject
to vibration; or
(v) Dry rock that is not stable; or
(vi) Material that is part of a sloped, lay-
ered system where the layers dip into the
excavation on a slope less steep than four
horizontal to one vertical (4H:1V), but only
if the material would otherwise be classified
as Type B.
Type C means:
(i) Cohesive soil with an unconfined com-
pressive strength of 0.5 tsf (48 kPa) or less;
or
(ii) Granular soils including gravel, sand,
and loamy sand; or
(ill) Submerged soil or soil from which
water is freely seeping; or
(iv) Submerged rock that is not stable, or
(v) Material in a sloped, layered system
where the layers dip into the excavation or
a slope of four horizontal to one vertical
(4H:1V) or steeper.
IJ
I
I
I
L
I
I
I
I
I
I
I
I
I
226
IOccupational Safety and Health Admin., Labor
Subpt. P, App. A
I
I
I
I
I
I
I
I
C
I
LI
I
I
I
I
1H
7"
U
Unconfined compressive strength means
the load per unit area at which a soil will
fail in compression. It can be determined by
laboratory testing, or estimated in the field
using a pocket penetromete_, by thumb pen-
etration tests, and other methods.
Wet soil means soil that contains signifi-
cantly more moisture than moist soil, but in
such a range of values that cohesive materi-
al will slump or begin to flow when vibrated.
Granular material that would exhibit cohe-
sive properties when moist will lose those
cohesive properties when wet.
(c) Requirements —(1) Classification of
soil and rock deposits. Each soil and rock
deposit shall be classified by a competent
person as Stable Rock. Type A. Type B. or
Type C in accordance with the definitions
set forth In paragraph (b) of this appendix.
(2) Basis of classification. The classifica-
tion of the deposits shall be made based on
the results of at least one visual and at least
one manual analysis. Such analyses shall be
conducted by a competent person using
tests described in paragraph (d) below, or in
other recognized methods of soil classifica-
tion and testing such as those adopted by
the America Society for Testing Materials,
or the U.S. Department of Agriculture tex-
tural classification system.
(3) Visual and manual analyses. The
visual and manual analyses, such as those
noted as being acceptable in paragraph (d)
of this appendix, shall be designed and con-
ducted to provide sufficient quantitative
and qualitative information as may be nec-
essary to identify properly the properties,
factors, and conditions affecting the classifi-
cation of the deposits.
(4) Layered systems. Ln a layered system.
the system shall be classified in accordance
with its weakest layer. However, each layer
may be classified individually where a more
stable layer lies under a less stable layer.
(5) Reclassification. U, after classifying a
deposit, the properties, factors, or condi-
tions affecting its classification change in
any way, the changes shall be evaluated by
a competent person. The deposit shall be re-
classified as necessary to reflect the
changed circumstances.
(d) Acceptable visual and manual tests. —
(1) Visual tests. Visual analysis is conducted
to determine qualitative information regard-
ing -the excavation site in general, the soil
adjacent to the excavation, the soil forming
the sides of the open excavation, and the
soil taken as samples from excavated mate-
rial.
(i) Observe samples of soil that arc exca-
vated and soil in the sides of the excavation.
Estimate the range of particle sizes and the
relative amounts of the particle sizes. Soil
that is primarily composed of flee -grained
material is cohesive material Soil composed
primarily of coarse -grained sand or gravel Is
granular material.
(ii) Observe soil as it is excavated. Soil
that remains In clumps when excavated is
cohesive. Soil that breaks up easily and does
not stay in clumps is granular.
(iii) Observe the side of the opened exca-
vation and the surface area adjacent to the
excavation. Crack -like openings such as ten-
sion cracks could indicate fissured material.
If chunks of soil spall off a vertical side, the
soil could be fissured. Small spalls are evi-
dence of moving ground and are Indications
of potentially hazardous situations.
(iv) Observe the area adjacent to the exca-
vation and the excavation itself for evidence
of existing utility and other underground
structures, and to identify previously dis-
turbed soil.
(v) Observe the opened side of the excava-
tion to identify layered systems. Examine
layered systems to Identify if the layers
slope toward the excavation. Estimate the
degree of slope of the layers.
(vi) Observe the area adjacent to the exca-
vation and the sides of the opened excava-
tion for evidence of surface water, water
seeping from the sides of the excavation, or
the location of the level of the water table.
(vii) Observe the area adjacent to the ex-
cavation and the area within the excavation
for sources of vibration that may affect the
stability of the excavation face.
(2) Manual tests. Manual analysis of soil
samples is conducted to determine quantita-
tive as well as qualitative properties of soil
and to provide more information in order to
classify soil properly.
(i) Plasticity. Mold a moist or wet sample
of soil into a ball and attempt to roll it into
threads as thin as Ys -inch in diameter. Cohe-
sive material can be successfully rolled Into
threads without crumbling. For example, if
at least a two inch (50 mm) length of y, -inch
thread can be held on one end without tear-
ing, the soil is cohesive.
(ii) Dry strength. If the soil is dry and
crumbles on its own or with moderate pres-
sure into individual grains or fine powder, It
is granular (any combination of gravel,
sand, or silt). If the soil is dry and falls into
clumps which break up into smaller clumps,
but the smaller clumps can only be broken
up with difficulty, it may be clay in any
combination with gravel, sand or silt. If the
dry soil breaks into clumps which do not
break up Into small clumps and which can
only be broken with difficulty, and there is
no visual indication the soil is fissured, the
soil may be considered unfissured.
(iii) Thumb penetration. The thumb pene-
tration test can be used to estimate the un-
confined compressive strength of cohesive
soils. (This test is based on the thumb pene-
tration test described in American Society
for Testing and Materials (ASTM) Standard
designation D2488 —"Standard Recommend-
ed Practice for Description of Soils (Visual -
I
227
bpt. P,.App. B
29 CFR Ch. XVII (7-1-92 Edition)
Manual Procedure).") Type A soils with an
unconfined compressive strength of 1.5 tsf
can be readily indented by the thumb; how-
ever, they can be penetrated by the thumb
only with very great effort. Type C soils
with an unconfined compressive strength of
0.5 tsf can be easily penetrated• several
inches by the thumb, and can be molded by
light finger pressure. This test should be
conducted on an undisturbed soil sample,
such as a large clump of spoil, as soon as
practicable after excavation to keep to a mi-
minum the effects of exposure to drying in-
fluences. If the excavation is later exposed
to' wetting influences (rain, flooding), the
classification of the soil must be changed ac-
cordingly.
(iv) Other strength tests. Estimates of un-
confined compressive strength of soils can
also be obtained by use of a pocket pene-
trometer or by using a hand -operated shear -
vane.
(v) Drying test. The basic purpose of the
drying test is to differentiate between cohe-
sive material with fissures, unfissured cohe-
sive material, and granular material. The
procedure for the drying test involves
drying a sample of soil that is approximate-
ly,one inch thick (2.54 cm) and six inches
(15.24 cm) in diameter until it is thoroughly
dry:
(A) If the sample develops cracks as it
dries, significant fissures are. indicated.
(B) Samples that dry without cracking are
to be broken by hand. If considerable force
is necessary to break a sample, the soil has
significant cohesive material content. The
soil can be classified as a unfissured cohe-
sive material and the unconfined compres-
sive strength should be determined.
(C) If a sample breaks easily by hand, it is
either a fissured cohesive material or a
granular material. To distinguish between
the two, pulverize the dried clumps of the
sample by hand or by stepping on them. If
the clumps do not pulverize easily, the ma-
terial is cohesive with fissures. If they pul-
verize easily into very small fragments, the
material is granular.
APPENDIx B TO SUBPART P -SLOPING
AND BENCHING
(a) Scope and application. This appendix
contains specifications for sloping and
benching when used as methods of protect-
ing employees working in excavations from
cave-ins. The requirements of this appendix
apply when the design of sloping and bench -
ing protective systems is to be performed in
accordance with the requirements set forth
in § 1926.652(b)(2).
(b) Definitions.
Actual slope means the slope to which an
excavation face is excavated.
Distress means that the soil is in a condi-
tion where a cave-in is imminent or is likely
to occur. Distress is evidenced by such phe-
nomena as the development of fissures in
the face of or adjacent to an open excava-
tion; the subsidence of the edge of an exca-
vation; the slumping of material from the
face or the bulging or heaving of material
from the bottom of an excavation; the spall-
ing of material from the face of an excava-
tion; and ravelling, i.e., small amounts of
material such as pebbles or little clumps of
material suddenly separating from the face
of an excavation and trickling or rolling
down into the excavation.
Maximum allowable slope means the
steepest incline of an excavation face that is
acceptable for the most favorable site condi-
tions as protection against cave-ins, and is
expressed as the ratio of horizontal distance
to vertical rise (H:V). -
Short term exposure means a period of
time less than or equal to 24 hours that an
excavation is open.
(c) Requirements —(1) Soil classification.
Soil and rock deposits shall be classified in
accordance with appendix A to subpart P of
part 1926.
(2) Maximum allowable slope. The maxi-
mum allowable slope for a soil or rock de-
posit shall be determined from Table B-1 of
this appendix.
(3) Actual slope. (i) The actual slope shall
not be steeper than the maximum allowable
slope.
(ii) The actual slope shall be less steep
than the maximum allowable slope, when
there are signs of distress. If that situation
occurs, the slope shall be cut back to an
actual slope which is at least ½ horizontal
to one vertical (i4H:1V) less steep than the
maximum allowable slope.
(iii) When surcharge loads from stored
material or equipment, operating equip-
ment, or traffic are present, a competent
person shall determine the degree to which
the actual slope must be reduced below the
maximum allowable slope, and shall assure
that such reduction is achieved. Surcharge
loads from adjacent structures shall be eval-
uated in accordance with § 1926.651(1).
(4) Configurations. Configurations of slop-
ing and benching systems shall be in accord-
ance with Figure B-1.
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
Li
Occupational Safety and Health Admin., Labor
Subpt. P, App. B
TABLE B-1
MAXIMUM ALLOWABLE SLOPES
SOIL OR ROCK TYPE
0A7fMuM ALLOWABLE SLOPES(H:V)C1]
FOR EXCAVATIONS LESS THAN 20
FEET
rro131
STABLE ROCK
VERTICAL (90°)
TYPE A (2)
3/4:1 (53°)
TYPE B
1:1 ;45c)
TYPE C
1k:1 (34°)
NOTES:
1. Numbers shown in parentheses next to maximum allowable slopes are angles expressed in
degrees from the horizontal. Angles have been rounded off.
2. A short-term maximum allowable slope of 1/2H:1V (63') is allowed in
excavations in Type A soil that are 12 feet (3.67 m) or less in depth.
Short-term maximum allowable slopes for excavations greater than 12
feet (3.67 m) in depth shall be 3/4H:1V (53').
3. Sloping or benching for excavations greater than 20 feet deep shall be designed by a registered
professional engineer.
Figure B-1
Slope Configurations
(All slopes stated below are in the horizontal to vertical ratio)
B-1.1 Excavations made in Type A soil
1. All simple slope excavation 20 feet or less in depth shall have a maximum allowable
slope of i'.:1.
Subpt. P, App. B 29 CFa2 Ch. XVII (7-1-92 Edition)
I
20' Max. � 1
3/4
SIMPLE SLOPE -GENERAL
Exception: Simple slope excavations which are open 24 hours or less (short term) and
which are 12 feet or less in depth shall have a maximum allowable slope of 54:1.
12' Max.
1
1/2
I.
SIMPLE SLOPE —SHORT TERM
�1 2. All benched excavations 20 feet or less in depth shall have a maximum allowable slope
of 3'. to 1 and maximum bench dimensions as follows:
3/4
20' Max.
I
1
1
1
230-
' Occupational Safety and Health Admin., Labor Subpt. P, App. B
SIMPLE BENCH
/
II /
20' Max. /
5'
Max. 3/4
4' Max.
MULTIPLE BENCH
3. All excavations 8 feet or less in depth which have unsupported vertically sided lower
portions shall have a maximum vertical side of 3¼ feet.
1
1 rMax.
Max.
' UNSUPPORTED VERTICALLY SIDED LOWER PORTION -MAXIMUM 8 FEET IN DEPTH
All excavations more than 8 feet but not more than 12 feet in depth which unsupported
vertically sided lower portions shall have a maximum allowable slope of 1:1 and a maximum
' vertical side of 3Y: feet.
1
1 al
' 12' Max.
3i' Max.
1
' 231
Subpt. P, App. B 29 CF iz Ch. XVI1 (7-1-92 Edition)
UNSUPPORTED VERTICALLY SIDED LOWER PORTION -MAXIMUM 12 PEET IN DEPTH
All excavations 20 feet or less in depth which have vertically sided lower portions that are
supported or shielded shall have a maximum allowable slope of 34:1. The support or shield
system must extend at least 18 inches above the top of the vertical side.
Support or shield system 7—
20' Max.
3/'+
18" Min.
Total height of vertical side
SUPORTED OR SHIELDED VERTICALLY SIDED LOWER PORTION
4. All other simple slope, compound slope, and vertically sided lower portion excavations
shall be in accordance with the other options permitted under § 1926.652(b).
ri
B-1.2 Excavations Made in Type B Soil
1. All simple slope excavations 20 feet or less in depth shall have a maximum allowable
slope of 1:1.
SIMPLE SLOPE
2. All benched excavations 20 feet or less in depth shall have a maximum allowable slope
of�1:1 and maximum bench dimensions as follows:
I
I
I
I
I
J
Li
I
I
1J
L
I
I
H
I
I
I
I
232
[1
Occupational Safety and Health Admin., Labor
Subpt. P, App. B
This bench allowed in cohesive soil only.
20' Max
4'
Max.
SINGLE BENCH
This bench allowed in cohesive soil only
i
'
20' Max. '
A
Max_ i 1
4' Max. I
MULTIPLE BENCH
3. All excavations 20 feet or less in depth which have vertically sided lower portions shall
be shielded or supported to a height at least 18 inches above the top of the vertical side. All
such excavations shall have a maximum allowable slope of 1:1.
-�—� Support or shield system
ical side
233
Subpt. P, App. B 29 CFR Ch. XVII (7-1-92 Edition)
VERTICALLY SIDED LOWER PORTION
4. All other sloped excavations shall be in accordance with the other options permitted in
§ 1926.652(b).
B-1.3 Excavations Made in Type C Soil
1. All simple slope excavations 20 feet or less in depth shall have a maximum allowable
slope of 1'A:1.
H
� ?0' Max.
� 1
i I
H_____
t§
SIMPLE SLOPE
1 2. All excavations 20 feet or less in depth which have vertically sided lower portions shall
be shielded or supported to a height at least 18 inches above the top of the vertical side. All
such excavations shall have a maximum allowable slope of 1'/s:1.
L18" Min.
Total height of vertical side
1
1
1
1
234
p.1
Occupational Safety and Health Admin., Labor Subpt. P, App. B
VERTICAL SIDED LOWER PORTION
3. All other sloped excavations shall be in accordance with the other options permitted in
§ 1926.652(b).
B-1.4 Excavations Made in Layered Soils
1. All excavations 20 feet or less in depth made In layered soils shall have a maximum
allowable slope for each layer as set forth below.
B OVER A
C OVER A
B / 1
C OVER d
235
Subpt. P, App. C
29 CFR Ch. XV11 (7-1-92 Edition) I
A n'Go'O
A OVER C
c A 1
1S
3 �1
1#
� � 1
1½
B OVER C
2. All other sloped excavations shall be in accordance with the other options permitted in
§'1926.652(b).
APPENDIX C TO SUBPART P --TIMBER
SHORING FOR TRENCHES
,(a) Scope. This appendix contains infor-
mation that can be used timber shoring is
provided as a method of protection from
cave-ins in trenches that do not exceed 20
feet (6.1 m) in depth. This appendix must be
used when design of timber shoring protec-
tive systems is to be performed in accord-
ance with § 1926.652(c)(1). Other timber
shoring configurations; other systems of
support such as hydraulic and pneumatic
systems; and other protective systems such
as sloping, benching, shielding, and freezing
systems must be designed in accordance
with the requirements set forth in
§ 1926.652(b) and § 1926.652(c).
(b) Soil Classification. In order to use the
data presented in this appendix, the soil
type or types in which the excavation is
made must first be determined using the
soil classification method set forth in appen-
dix A of subpart P of this part.
(c) Presentation of Information. Informa-
tion is presented in several forms as follows:
(1) Information is presented in tabular
form in Tables C-1.1, C-1.2, and C-1.3, and
Tables C-2.1, C-2.2 and C-2.3 following
I
I
I
I
In
I
I
I
I
I
I
I
I
I
I
2
36
' Occupationai:Safety and Health Admin., Labor
Subpt. P, App. C
1
I.
C
I
I
I
I
I
Li
I
I
I
I
I
Li
I
paragraph (g) of the appendix. Each table
presents the minimum sizes of timber mem-
bers to use in a shoring system,' and each
table contains data only for the particular
soil ,type in which the excavation or -portion
of the excavation is made. The data are ar-
ranged to allow the user the flexibility ;to
select from among several acceptable con-
figluaiions of members based on varying
the horizontal sp..cing of the crossbraces.
Stable rock is exempt from shoring require-
ments and therefore, no data'are-presented
for this condition.
(2) Information concerning the basis of
the tabular data and the limitations of the
data is presented in paragraph (d) of this
appendix, and on the tables themselves.
(3) Information explaining the use of the
tabular data is presented in paragraph (e) of
this appendix.
(4) Information illustrating the use of the
tabular data is presented in paragraph (f) of
this appendix.
(5) Miscellaneous notations regarding
Tables C-1.1 through C-1.3 and Tables C-
2.1 through C-2.3 are presented in para-
graph (g) of this Appendix.
'" (d) Basis and limitations of the data. —(1)
Dimensions of timber members. (i)'The sizes
of the timber members listed in Tables C -
;1.I through C-1.3 are taken from the Na-
tional Bureau of Standards (NBS) report,
"Recommended Technical Provisions for
Construction Practice in Shoring and Slop-
ing of Trenches and Excavations." In addi-
tion, where NBS did not recommend specific
sizes of members, member sizes are based on
an analysis of the sizes required for use by
existing codes and on empirical practice.
(ii) The required dimensions of the mem-
bers listed in Tables C-1.1 through C-1.3
refer to actual dimensions and not nominal
dimensions of the timber. Employers want-
ing to use nominal size shoring are directed
to Tables C-2.1 through C-2.3, or have this
choice under § 1926.652(c)(3), and are re-
ferred to The Corps of Engineers, The
Bureau of Reclamation or data from other
acceptable sources.
(2) Limitation of application. (I) It is not
intended that the timber shoring specifica-
tion apply to every situation that may be
experienced In the field. These data were
developed to apply to the situations that are
most commonly experienced in current
trenching practice. Shoring systems for use
in situations that are not covered by the
data in this appendix must be designed as
specified in 4 1926.652(c).
(it) When any of the following conditions
are present, the members specified in the
tables are not considered adequate. Either'
an alternate timber shoring system must be
designed or another type of protective
system designed In accordance with
3 1926.652.
'(A) When loads imposed by structures or
by stored material adjacent to the trench
weigh in excess of the load Imposed by a
two -foot soil -surcharge. The term "adja-
cent" as used here means the area within a
horizontal distance from the• edge of the
trench equal to the depth of.the trench.
• (B).W.hen verticalJoads Imposed -on cross
braces exceed a 240 -pound gravity load dis-
tributed on a one -foot, section of the center
of the crossbrace.
(C) When surcharge loads are present
from equipment weighing in excess of 20,000
pounds.
(D) When only the lower portion of a
trench is shored and the remaining portion
of the trench is sloped or benched unless
The sloped portion Is sloped at an angle less
steep than three horizontal to one vertical;
or the members are selected from the tables
for use at a depth which is determined from
the top of the overall trench, and not from
the toe of the sloped portion.
(e) Use of Tables. The members of the
shoring system that are to be selected using
this information are the cross braces, the
uprights, and the wales, where wales are re-
quired. Minimum sizes of members are spec -
Wed for use in different types of soil. There
are six tables of information, two for each
soil type. The soil type must first be deter-
mined in accordance with the soil classifica-
tion system described in appendix A to sub-
part P of part 1926. Using the appropriate
table, the selection of the size and spacing
of the members is then made. The selection
is based on the depth and width of the
trench where the members are to be in-
stalled and, in most instances, the selection
is also based on the horizontal spacing of
the crossbraces. Instances where a choice of
horizontal spacing of crossbracing is avail-
able, the horizontal spacing of the cross -
braces must be chosen by the user before
the size of any member can be determined.
When the soil type, the width and depth of
the trench, and the horizontal spacing of
the crossbraces are known, the size and ver-
tical spacing of the crossbraces, the size and
vertical spacing of the wales, and the size
and horizontal spacing of the uprights can
be read from the appropriate table.
(f) Examples to Illustrate the Use of Tables
C-1.1 through C-1.3.
(1) Example 1.
A trench dug in Type A soil is 13 feet deep
and five feet wide.
From Table C-1.1, for acceptable arrange-
ments of timber can be used.
Arrangement #1
Space 4x4 crossbraces at six feet hoti-on-
tally and four feet vertically.
Wales are not required.
I
237
5ubpt. P, App. C
29 CFR Ch. XVII (7-1-92 Edition)
i Space 3x8 uprights
ly. This arrangement
"skip shoring."
at six feet horizontal -
is commonly called
Arrangement #2
Space 4x6 crossbraces at eight feet hori-
zontally and four feet vertically.
Space 8x8 wales at four feet vertically.
Space 2x6 uprights at four feet horizon-
tally.
Arrangement #3
1 Space 6x6 crossbraces at 10 feet horizon-
tally and four feet vertically.
Space 8x 10 wales at four feet vertically.
Space 2x6 uprights at five feet horizontal-
ly.
Arrangement #4
! Space 6x6 crossbraces at 12 feet horizon-
tally and four feet vertically.
I Space 10xl0 wales at four feet vertically.
Spaces 3x8 uprights at six feet horizon-
tally. -
(2) Example 2.
A trench dug in Type B soil in 13 feet
deep and five feet wide. From Table C-1.2
..three acceptable arrangements of members
are listed.
Arrangement #1
Space 6x6 crossbraces at six feet horizon-
tally and five feet vertically.
Space 8x8 wales at five feet vertically.
Space 2x6 uprights at two feet horizontal-
ly.
Arrangement/$2
Space 6x8 crossbraces at eight feet hori-
zontally and five feet vertically.
Space 10X10 wales at five feet vertically.
Space 2x6 uprights at two feet horizontal-
ly.
Arrangement #3
Space 8x8 crossbraces at 10 feet horizon-
tally and five feet vertically.
Space 10x12 wales at five feet vertically.
Space 2x6 uprights at two feet vertically.
(3) Example 3.
A trench dug in Type C soil is 13 feet deep
and five feet wide.
From Table C-1.3 two acceptable arrange-
ments of members can be used.
i
Arrangement #1
Space 8x8 crossbraces at six feet horizon-
tally and five feet vertically.
1 Space 10X12 wales at five feet vertically.
1 Position 2x6 uprights as closely together
as possible.
j If water must be retained use special
tongue and groove uprights to form tight
sheeting.
Arrangement #2
Space 8x10 crossbraces at eight feet hori-
zontally and five feet vertically.
Space 12x12 wales at five feet vertically.
Position 2x6 uprights in a close sheeting
configuration unless water pressure must be
resisted. Tight sheeting must be used where
water must be retained.
(4) Example 4.
A trench dug in Type C soil is 20 feet deep
and 11 feet wide. The size and spacing of
members for the section of trench that is
over 15 feet in depth is determined using
Table C-1.3. Only one arrangement of mem-
bers is provided.
Space 8x10 crossbraces at six feet hori-
zontally and five feet vertically.
Space 12x 12 wales at five feet vertically.
Use 3x6 tight sheeting.
Use of Tables C-2.1 through C-2.3 would
follow the same procedures.
(g) Notes for all Tables. -
1. Member sizes at spacings other than in-
dicated are to be determined as specified in
§ 1926.652(c), "Design of Protective Sys-
tems."
2. When conditions are saturated or sub-
merged use Tight Sheeting. Tight Sheeting
refers to the use of specially -edged timber
planks (e.g., tongue and groove) at least
three inches thick, steel sheet piling, or
similar construction that when driven or
placed in position provide a tight wall to
resist the lateral pressure of. water and to
prevent the loss of backfill material. Close
Sheeting refers to the placement of planks
side -by -side allowing as little space as possi-
ble between them.
3. All spacing indicated is measured center
to center.
4. Wales to be installed with greater di-
mension horizontal.
5. If the vertical distance from the center
of the lowest crossbrace to the bottom of
the trench exceeds two and one-half feet,
uprights shall be firmly embedded or a
mudsill shall be used. Where uprights are
embedded, the vertical distance from the
center of the lowest crossbrace to the
bottom of the trench shall not exceed 36
inches. When mudsills are used, the vertical
distance shall not exceed 42 inches. Mudsills
are wales that are installed at the toe of the
trench side.
6. Trench jacks may be used in lieu of or
in combination with timber crossbraces.
7. Placement cf crossbraces. When the ver-
tical spacing of crossbraces is four feet,
place the top crossbrace no more than two
feet below the top of the trench. When the
vertical spacing of crossbraces is five feet,
place the top crossbrace no more than 2.5
feet below the top of the trench.
I
I
I
I
I
I
I
Li
I
I
I
I
H
I
I
238
Occupational Safety and Health Admin., Labor
Subpt. P, App. C
u
z
m
U
Q
d
J
Q
p
\O
-
x
x
Z
N
N
O
O
$ W
>C
x
W LL
N
a
C.
J
Q
E
•
V
Z
O
H m
•
ac
`�
.O
.o
O)
Q
x
x
C
O.
W L
E
O
O
n
L
L q
00
W L
V W
1 V
V F
_
L
J
R' U W
.
I
C W
O
Q W
<
c
v
v
v
L
W
a
Q
J
N
W N
Q
in N
O -...
W —
Q
a
W fl
N Z
0.-'-
m
^
O
O
0
N
-
Z
O
X
y 4
v)
Z
03
2
m
O
b
m
O
O �-.
•S
c a
E
C
i-
L T
r
H-
W
y q
+
c
u W
O E
Li _
W
Q LL
O
C -v
V
v
Q
J E r
l
6 v
v
v
v
v
C) .C
03
N
Q 1 x
— 1
=
N C
U N
f-
.O
\O
.p
\O
C
O
T L
Q
`O
x
X
X
x
x
x
O
O
O
C -.
C
j
.p
\O
\O
.O
.O
.C
x
X
x
x
x
_ N
C
\O
b
\p
C
03
O
C
O
W C
W
N
%
X
tO
to
toC
O
O
Q
q
U
j
X
x
X
x
x
x
x
>4
x
q
W
W
J
O: W
c_,_
- C
O
I.- C
Q
U1-.
\O
\C
to
to
\D
.O
\D
I 41
0
x
x
X
x
x
x
X
to
x
b
)-
O
W
V
v
v
x
X
-.L
W
[Y
J
.0
C
)O
to
\p
\O
tO
C
O
CO
O J
-
C
O
O
W
H N
C
O
C)O
)O
x
X
x
b
b
CC
•-E
C-
V
x
X
x
x
x
X
x
J
V
C
C.
V
V
\O
.O
\O
\D
0
O
Q y
O
u E
O
L v
V
C.
\O
C.
\O
\p
)p
.O
O w
Q
X
x
x
X
X
X
X
X
x
.D
6
L
L
v
v
V
v
v
\O
\O
\O
\O
X
Y J
6
q J
O U
W
C
N
O
- -
O
O
O
O
O
O
O
C)
W
.-
'-
O
O
O
O
O
Z
x C
OC
LL
a
a
N
W
S
Q_ —
p
O
C
C r
a
C
a.
d
a
C_
L_
W
O
O
_
_
_
F -LL U.-
C O W
in O O
O O
W O
W W W
1-
u')
O O
> N
O 6' W
..y
•-+f- C')
O
r
239
'Subpt. P, App. C
29 CFR Ch. XVII (7-1-92 Edition)
r.
#
W
00
Cl'
F
C 9
Z
E
H
V
O
N
H
L
L1
" I-
N
y
v
w
o
z
F
n
N
H
Z
U
H
S
S
in
F
U
Z
H
I
O
in
L
a
Z
m
K
LI
F
C
>>a.
F
C
a
H
I
H
p
I
F
N
U
Z
U
N
F
Z
•
H
F
O F
0
0
x m
x
x
U
CU
N
N
N
z
a...
L
m
O
p
p
J
N
-
N
N
N
E
p
CU
H
O
p
p
p
#
U
x
x
x
#
['1
t1
C,
U
-Zr'
CU
in
h
h
h
in
h
in
in
in
W6 41
N v
4
a
_
O
O
O
N
O
N
N
3
N Z
m
m
r
H M
N
in
m
O
C)
O
O
m
O
N
r
r
r
Or.
Z F
F H
-C
OIU
in
in
✓1
in
in
in
U
N
in
4] < L
> O
O
O
O
H
'0
m
m
m
m
m
-+
x
x
x
x
x
x
x
x
t.-.
`J
O
'D
'0
m
m
m
p
O
r•v
F N
O
m
m
m
m
m
m
r
'a
.o
e
m
m
m
m
N
(-J=0
<
V
F
'0
b
.O
.o
m
m
m
^.
xm
.0
d
d
.D
'a
a0
[Y
�
N
F
N
O
0
O
o
f
'D
.O
.O
•O
m
m
m
x
x
x
x
x
x.
x
x x
U.
.1
'O
.o
�O
'.D
'p
m
m
0
m
.o
m
m
C
m
m
V
x
x
x
x
x
x
x
x
.T
•O
'O
'.0
'a
cc
m
m
.-.
CU
F
Z
N F
0
0
0
-•
O
O
O
r
O
O
O
Z
HH {a
F
F
H
F
H
F
H
F
H
mU
O
d
.O
m
aJ
.O
m
O
41
O< .
v
•'
j
a u
W
L
d
L
L
L
L
L
m o
a
a
L
W
N
Cl'
O
J
N Z
>
>
>
N Z
p
O
N Z
_ n
F OH
L k Z 4
Lao
O4I t_1
vi O O
O O ✓i
in O p
>N
O
-
F � .
1
1
1
1
1
I ' t
Occupational Safety and Health Admin., Labor
Subpt. P, App. C
<
Ii
h
m
F
I-.
Z
C
W-
i
U
W
0
—
W
U
I-
x
W
v
m
EF
o
i
2
^
—
U
r
Z
W
r
=
G
F
I
U
O
Z
m
K
�
h
U
to
'Si
W
F
6
a'
F
x
0
F
N
U
Z
U
U N
Sc
0-0
n U
0
Z
C a
F u
=0
O H
I-i---
___
N
W
U
W
—
W {Y
K
J
C-
=
G
a
.J
.a
G
S
J
Z
W
f
`
.r
x
N
b
.O
.O
'a
.O
.O
%
x
x
x
S
V
N
N
N
N
N
(mil
Lu
W
U
S
Z ^
W
Fu F
W 6 W
>Y
(/j v
W
N Z
O
N
N
N
N
N—
X
_
x
x
_
%
_
x
m
O
N
O
N
N
o
V
Z
Sc
F —F
W G LS
✓\
>L W
N
O
O
O
O
O
O
—
x
x
%
x
x
x
J
a
m
O
m
O
—
O
O
W
O
O
O
9
m
{/l
v
J
9
m
m
m
m
m
W
0=
<
U
O
!-.
O
O
O
m
W
m
m
—
m
—
0.
x
x
%
%
x
X
N
F
J
'
m
m
m
m
m
N
¢h.
F
O
O
O
U
m
s
y
X
X
X
%
X
x
F
J
'0
m
m
m
m
m
O
M
3
O
F
O
O
O
m
-.
m
y
x
x
x
'-C
K
J
V
m
m
m
m
m
(Si
2
F
O
O
—0
O
—
—0
—
—
0
M Y .•
F
~m
F
Z
K V W
C
m
O
0
.0
Y
0
.O
0
0
O G W
Gu
U u
m u
0 0U
N u
W
=a.�=
Y—
Uo-
L
00000.
u
0000
W
N
J
J
VlZ
J
J
V1 Z
N Z
J
Vl
(nZ
VI Z
N
O OKWO
HL
> N
0
—
241
29 Chit Ch. XVII (7-1-92 Edition)
Subpt. P, App. C
III
U
Z
M
O
X
U
V
d
N
O
O
'0
C
Z
V
V
V
v
O
N
r-.
N
�
F
O F
C
pJ
U
W
x
x
w
W W
.r
v
W
C
0<
3
O
N
N
n
V
.p
d
x
x
x
x
V
V
V
V
W
Cl,
d
'
d
x
x
x
U
n
m
n
n
U
Z
V
9
z
IL
F M
U
U
U -
x0
00
cc
W G
ZU
ZW
-t
ZW
-.r
.:
'5
'5
V
ILIP
> a
x
V
c
XC
0
V
-
.J
N Z
u-
'-
a
a
H
00•
00-
m
m
00
vJ
W
.-.
m
y
Z
ZO
ZO
x
x
x
x
'x
'x
x
'0m
C
x
x
U
0
U
• Z
O
Y U W
W < W
.r
v
C
v
v
C
C
> a W
N
'5
'0
C
C
C
J
O
C
C
C
.J
ti
x
x
x
x
x
x
x
x
x
¢r
m
L
V
V
'O
.O
C
.O
'a
C
'0
.O
O
G
N
n
O
U
H
V
.O
.O
v7
.O
C
'0
.O
`.
C
'a
C
v
v
d
b
x
x
x
x
L
b
b
'a
C
C
x
y
C
C
W
U
U
H
V
V
C
C
V
C
.O
'a
u^
.OJ
x
x
x
x
x
x
x
x
x
x
x
.C
x
=
U
V
V
V
V
V
V
C
C
'0
.D
b
.G
N
F
N
O
W
O
d'
O
F
•r
•:
.o
.D
'a
.O
o
U
C
x
x
x
x
'C
x
x
x
'C x
x
.O
.O
C
D.
V
V
V
V
V
V
.O
.p
C
x
'a
x
x
F
'0
C
w
3'O
V
•1
d
C
.O
'0
e
a
x
x
x
x
'C x
x
'C x
'C x
x
L
V
V
V
V
V
VJ
.O
YJ
.p
.p
'a
W
F
O
O
O
O
O
O
O
O
O
O
F
F
H
H
F
H
H
F
H
O
F
O
H
x w
U
0 6 W
N
'O
m
O
N
C
4I
O
N
Q.
L W
W
Y
L
y
v
p
O
=
O
=a.
W
W
L
=
H OH
L W Z W
N O O
O O ✓�
W W W O
H �
Ln O O
W O
O C Es.
H _
_
F N
>
H'-'
O
242
Occupational Safety and Health Admin., Labor Subpt. P, App. C
'
Z N
V
X
< V
Y
' N
6 m
F X
O
N
O
O F
m
w xx x
W W n v
1 r .. r
O O O O
m
X X % X rn v v v
WV
' K W 6 O
N Y J( O .O d .O .p .p .p
2
U �%j n X % X O}
W 0 u u u V
W i O
W U • O
C
' C Y •t n V
r J N F r Y
VI 6' 1' V EL in Vfl in in in N in in H U U
W w <
W • a,U > O, x u
N ,,.
W W Y U
6 i
' v y, N O O eq O r N U V
O r .-� m m m O
_ N
F a U N .O m m m O O m O N C Y
= Z
• pp L D
Zr-.< Z F y r c T
U r y F r W C A
M •. U, C V W J' in N in in in N
W E
V u L
S = O > G, .. x u
Z N m
< f• i X < b C
O
N
U .T ., F N .p .p m m m m m m m �J u
Z � G. X X X % % X X X X CU,
J `V v' d .O m m m m mJ
o a u
W -0
C
n u
O. .N-, W L.JFN .O .O .O m m m m m m L N
U � x x X X X X u>
m m m m
z m ,
W
W U H u Y
F 0 C
C. .V O m m m m m Y I
2 J x Y. x x x x x x X —o
W .a .o m .o .o m n
m > A
i t C1-0 ti V
-0 0I-.
F" N L `O b ¢ d b m m m m m c a
C-. X x x X x x x x x WE
C J. V v V .O 'a .O .O '0m Y
r
'4 d m m m m m �.
X Y. x X X % X % X —o
N V
_ O O O _ O O O _
r r F
F F F F F F F F F O m C
C U W O ¢ O Y .O ¢ O Y .O m O U O
0<14 V u J Y u Y u W OX
C.Is.
r O. L_ o O L 1 f VC L S C.0 r 00 W
0 Nv p y�2 J J a ___ J J J VI2 Ca
F U F
W 2 W L 140
(4014W W W r O O O O in in
O L' Cs. F. —. �. F. — — � �N 0 N
1
1
1 243
29 CFR Ch. XVII (7-1-92 Edition)
Subpt. P, App. C
Ci
F
CO
Z
H
41
N
U
U
H
H
=
W
I
c
u
IY
IL]
v
H
F
N
a
H.
t
N
•
S.
N
M
+
u
W
.-
1
<
O
U
Z
"
II
p
9
V
Z
U
W
F
-
-.
K
W
u
m
a
L
„•
N
O
f
'Jl
U
Z
N
V
C),
<
F
Z
O
N
F
O F+
W
U
I.)
1
v
L
m
O
S
E
4
Jr+
x
x
x
x
<
n.
n
en
t'1
v
-
v
U
. Z
L y f^
✓1
✓1
vl
v1
N
> L L
V
O
N
O
N
N
m
O
O
O
N
p
CF
U m
•
✓1
V�
N
V\
vl
In
> 1
O
m
m
x
x
m
m
m
m
m
N
m
m
o
x
x
x
m
m
w
m
m
j
m
m
m
m'
d'0
x
x
x
x
m
c
m
m
C),
O
'
O
m
X
x
x
K
m
.O
•O
•O
0
m
c
3
O
V
'0
•O
'0
m
m
°J
x
x
x
x
x
.5
a
.o
.o
'a
m
m
t
lh Z F
O
O
O
0
O
O
F
O
U
u
_
F
—
_
Z
Y U 4
O<
.D
m
O
m
d
L_
L_
O"
Uu
Uu
d u
W L
U
U J
4l
41
y
_
y p
L
L
dO
WOL
N O
0
W O
010
m Z
>
0
mZ
mZ
0
NZ
NZ
m
m
=—
OH
-
Is: O W
" O O
O O
O O
Ia1O
C s r.
F -v
—tin
� H
> N
1...
244
' Occupational Safety and Hearth Admin., Labor
Subpt. P, .App. D
E
L
L
II
I
F
H
C
H
I
I
I
I
I
II
I
I
APPENDIx D TO SUBPART P—ALU'MINuas
.HYDRAULIC SHORING FOR TRnrClgs
1a) Scope: This appendix contains. infor-
mation that -can be used when aluminum
hydraulic shoring is provided as a method
of.•protection ,against cave-ins in trenches
t,hat,do not exceed 20 feet (6.1m) In iiepth.
This appendix must be used when design of
the aluminum hydraulic protective system
cannot be performed In accordance with
f 1926.652(c)(2).
(b) Soil Classification. In order to use
data presented In this appendix, the soil
type or types in which the excavation 1s
made must first be determined using the
soil classification method set forth In appen-
dix A of subpart P of part 1926.
(c) Presentation of information_ Informa-
tion is presented in several forms as follows:
(1) Information is presented in tabular
form in Tables D-1.1, D-1.2, D-1.3 and E-
1.4. Each table presents the maximum verti-
cal and horizontal spacings that may be
used with various aluminum member sizes
and various hydraulic cylinder sizes. Each
table contains data only for the particular
soil type in which the excavation or portion
of the excavation is made. Tables D-1.1 and
D-1.2 are for vertical shores in Types A and
B soil. Tables D-1.3 and D1.4 are for hori-
zontal waler systems in Types B and C soil.
(2) Information concerning the basis of
the tabular data and the limitations of the
data is presented in paragraph (d) of this
appendix.
(3) Information explaining the use of the
tabular data is presented In paragraph (e) of
this appendix.
(4) Information illustrating the use of the
tabular data is presented in paragraph (f) of
this appendix.
(5) Miscellaneous notations (footnotes) re-
garding Table D-1.1 through D-1.4 are pre-
sented in paragraph (g) of this appendix.
(6) Figures, illustrating typical installa-
tions of hydraulic shoring, are included just
prior to the Tables. The Illustrations page is
entitled "Aluminum Hydraulic Shoring:
Typical Installations.'
(d) Basis and limitations of the data.
(1) Vertical shore rails and horizontal
wales are those that meet the Section Mod-
ulus requirements in the D-1 Tables. Alumi-
num material is 6061-T6 or material of
equivalent strength and properties.
(2) Hydraulic cylinders specifications. (i)
2 -inch cylinders shall be a minimum 2 -inch
Inside diameter with a minimum safe work-
ing capacity of no less than 18,000 pounds
axial compressive load at maximum exten-
sion. Maximum extension is to Include full
range of cylinder extensions as recommend-
ed by product manufaturer.
(II) 3 -inch cylinders shall be a minimum 3 -
inch inside diameter with a safe working ca-
pacity of not less than 30,000 pounds axial
compressive load atextenslons as recom-
mended by product manufacturer.
(3) Limitation of application.
(I) It is not intended that the aluminum
hydraulic specification apply to every sltua-
tlpn that may be experienced in the field.
These data were developed to, apply o the
situations that are most commonly experi-
enced in current trenching practice. Shoring
systems for use In 'situations that are not
covered by the data in this appendix must
be 'otherwise designed as specified in
t 1926.652(c).
(ii) When any of the following conditions
are present, the members specified In the.
Tables are not considered adequate. In this
case, an alternative aluminum hydraulic
shoring system or other type of protective
system must be designed in accordance with
t 1926.652.
(A) When vertical loads imposed on cross
braces exceed a 100 Pound gravity load dis-
tributed on a one foot section of the center
of the hydraulic cylinder.
(B) When surcharge loads are present
from equipment weighing in excess of
20,000 pounds.
(C) When only the lower portion or a
trench is shored and the remaining portion
of the trench is sloped or benched unless:
The sloped portion is sloped at an angle less
steep than three horizontal to one vertical:
or the members are selected from the tables
for use at a depth which is determined from
the top of the overall trench, and not from
the toe of the sloped portion.
(e) Use of Tables D-1.1, D-1.2, D-1.3 and
D-1.4. The members of the shoring system
that are to be selected using this informa-
tion are the hydraulic cylinders, and either
the vertical shores or the horizontal wales.
When a waler system is used the vertical
timber sheeting to be used is also selected
from these tables. The Tables D-1.1 and D-
1.2 for vertical shores are used in Type A
and B soils that do not require sheeting.
Type B soils that may require sheeting, and
Type C soils that always require sheeting
are found in the horizontal wale Tables D-
1.3 and D-1.4. The soil type must first be de-
termined in accordance with the soil classifi-
cation system described In appendix A to
subpart P of part 1926. Using the appropri-
ate table, the selection of the size and spac-
ing of the members is made. The selection is
based on the depth and width of the trench
where the members are to be installed. In
these tables the vertical spacing is held con-
stant at four feet on center. The tables
show the maximum horizontal spacing of
cylinders allowed for each size of wale in
the wafer system tables, and in the vertical
shore tables, the hydraulic cylinder horizon-
tal spacing is the same as the vertical shore
spacing.
I
245
Subpt. P, App. D 29 CFR Ch. XVII (7-1-92 Edition) '
(f) Example to Illustrate the Use of the
Tables:
(1) Example 1:
A trench dug in Type A soil is 6 feet deep
and 3 feet wide. From Table D-1.1: Find ver-
tical shores and 2 inch diameter cylinders
spaced 8 feet on center (o.c.) horizontally
and 4 feet on center (o.c.) vertically. (See
Figures 1 & 3 for typical installations.)
(2) Example 2:
A trench is dug in Type B soil that does
not require sheeting, 13 feet deep and 5 feet
wide. From Table D-1.2: Find vertical shores
and 2 inch diameter cylinders spaced 6.5
feet o.c. horizontally and 4 feet o.c. vertical-
ly. (See Figures 1 & 3 for typical installa-
tions.)
(3) A trench is dug in Type B soil that
does not require sheeting, but does experi-
ence some minor raveling of the trench face.
The trench is 16 feet deep and 9 feet wide.
From Table D-1.2: Find vertical shores and
2 inch diameter cylinder (with special overs-
leeves as designated by footnote #2) spaced
5.5 feet o.c. horizontally and 4 feet o.c. verti-
cally, plywood (per footnote (g)(7) to the D-
1 Table) should be used behind the shores.
.,(See Figures 2 & 3 for typical installations.)
(4) Example 4: A trench is dug in previous-
ly disturbed Type B soil, with characteris-
tics of a Type C soil, and will require sheet -
ling. The trench is 18 feet deep and 12 feet
wide. 8 foot horizontal spacing between cyl-
• inders is desired for working space. From
Table D-1.3: Find horizontal wale with a
section modulus of 14.0 spaced at 4 feet o.c.
vertically and 3 inch diameter cylinder
spaced at 9 feet maximum o.c. horizontally.
3X12 timber sheeting is required at close
spacing vertically. (See Figure 4 for typical
installation.)
(5) Example 5: A trench is dug in Type C
soil, 9 feet deep and 4 feet wide. Horizontal
cylinder spacing in excess of 6 feet is desired
for working space. From Table D-1.4: Find
horizontal wale with a section modulus of
7.0 and 2 inch diameter cylinders spaced at
6.5 feet o.c. horizontally. Or, find horizontal
wale with a 14.0 section modulus and 3 inch
diameter cylinder spaced at 10 feet o.c. hori-
zontally. Both wales are spaced 4 feet o.c.
vertically. 3x12 timber sheeting is required
at close spacing vertically. (See Figure 4 for
typical installation.)
(g) Footnotes, and general notes, for
Tables D-1.1, D-1.2, D-1.3, and D-1.4.
(1) For applications other than those
listed in the tables, refer to § 1926.652(c)(2)
for use of manufacturer's tabulated data.
For trench depths in excess of 20 feet, refer
to § 1926.652(c)(2) and § 1926.652(c)(3).
(2) 2 inch diameter cylinders, at this
width, shall have structural steel tube
(3.5x3.5x0.1875) 3.5 x 0.1875) oversleeves, or structural
oversleeves of manufacturer's specification,
extending the full, collapsed length.
(3) Hydraulic cylinders capacities. (i) 2
inch cylinders shall be a minimum 2 -inch
inside diameter with a safe working capacity
of not less than 18,000 pounds axial com-
pressive load at maximum extension. Maxi-
mum extension is to include full range of
cylinder extensions as recommended by
product manufacturer.
(ii) 3 -inch cylinders shall be a minimum 3 -
inch inside diameter with a safe work capac-
ity of not less than 30,000 pounds axial com-
pressive load at maximum extension. Maxi-
mum extension is to include full range of
cylinder extensions as recommended by
product manufacturer.
(4) All spacing indicated is measured
center to center.
(5) Vertical shoring rails shall have a min-
imum section modulus of 0.40 inch.
(6) When vertical shores are used, there
must be a minimum of three shores spaced
equally, horizontally, in a group.
(7) Plywood shall be 1.125 in. thick
softwood or 0.75 inch. thick, 14 ply, arctic
white birch (Finland form). Please note that
plywood is not intended as a structural
member, but only for prevention of local
raveling (sloughing of the trench face) be-
tween shores. _
(8) See appendix C for timber specifica-
tions.
(9) Wales are calculated for simple span
conditions.
(10) See appendix D, item (d), for basis
and limitations of the data.
I
I
I
I
I
I
I
I
H
I
J
I
I
I
Lii
I
1l
Occupational Safety and Health Admin., Labor Subpt. P, App. D
ALUMINUM HYDRAULIC SHORING
TYPICAL INSTALLATIONS
FIGURE NO. 1
Y LAICAL yy.PAy FIGURE NO. 2
rn DA.LtC !•OAM VI TC.I ALIA•.I.y
IYNT PAACDCJ NYCAAIAS LOAM
/ Iwrt PLVwDODI
N0IIZO T AL SPACIYD D/// II
I /
SPACING J
VERTICAL RAIL
N TOR ALL IC
C?L 100EI
ID• MAX.
VEST ICAL RAIL 9
XT09AULIC CTLIMDER I8 *11.
VERTICAL `"I
SPACING C 13• F,1
-VERTICAL
SPACING
AMAX. • 'Ab
2' MAX. j' MAX.
PLYWOOD
FIGURE NO. 3 FIGURE NO. 4
VEAtCY ALU• PAJM ALVW •.SAUC Y.OAM
.VWwC •.C•O at. wAl LAStills UPRIGMt
IIGCAmI IT VCAU S M E E t I Y G
a`
S �
M0R120NiAl SPYL
VERTICAL d -'
VERTICAL RAIL j' MAX. /
T PA[IYG /
3 HYDRAULIC
C TIIMDER
VERTICAL
SPACING
A• MAX.
Y T
j MAX,
wAll
Y TO IAULIC
CiL INOEI
247
311-'.12 O-92..-9
bpt. P, App. D
29 CFR Ch. XVii (7-1-92 Edition)
C
z
=ca
-uaW
O
p
F
CID
;a.
Z
I
�
I .
Q
a
�
�
L:J
--
U[Fcl
cO
zg
O
0
Ua
T
w
N
_
LU
°OLL.
U
W
w
F
wO
i-
NQO
O
O>
Pr
C]
c
T
w
C
O
q
a
N
¢
z
q
U
<
�U
..
o
.-.
>
I-
0
a
F
z
z
?
O
U
L
00
00
X
N
<
<
O
T-.
0
cr
0
0
w
z
w
w
O
w
0
v
w
v O
W.
wow
w
>
^a-
>^a.-
>
a.N
w
C:
F
0
U
0
a
0
O
O
248
U
O
U
U
a
a.
C
C
C
c
0
N
u
•
C,
L
C
O - N
v v
v I-
co
E E
U U
U - -
wq O
_ •
C 'O t
(C Cc
U U
vi c,fl
� a a
QUO
—C#)V)
• N
^'-
U0
0 0
w z Z
1
1
1
1
I
Occupational Safety and Health Admin., Labor
Subpt. P, App. D
I
I
I
I
I
I
I
H
I
I
I
I
H
H
I
I 1
C-
-- U
0 zu
WE-
O a
W
U
U
Z �N �F-
00 ZLUw
U. > F ¢ O
zO 0 6z a
c
z 3 0
K
(A u 0 z CaJ
N U a W Z
O � }
Ica¢
Q 2 F r ¢ U
U W W O U F
Z} r [-U V c _
!' T C Q 1
l"'
¢ O
T
L
00 Z 2 '1
0 U
^
u
K K
c
n c c
WV
d n
t ! Q
C 01)
U F_ z 0 C 0 C 0 C V
u O z Lj J 1,. F O W O H v, ••>—c_—
C
— > — C — > N W
p F 0 O 0 O 0 O >O `c O
O4)
goo
L• Z Z
' 249
Subpt. P, App. D
I
U
z
O
ii
I,.,
v}-
-�
CL
<r�a
C
F
<
z3c:
<
29 CFR Ch. XVII (7-1-92 Edition)
U
NZ
-
M
t„
I
I
V
W
N z
(
LN•
N
0 z
I
M
m
O
�
J
N
1-
O
I
x
en
Y Y
—
z
z
z
z
Z
z
z
z
i
_z
n
-
en
r
.-i
en
rh
en
.-.
r -1
} _
.0
—
NZ
Y
Y U
O
O
...
O
C
...
v:
C
O
?
0<
oo
.:
m
O
r.
C
F
O
u
zv
ry
I:J
N
N
N
'r
zuZWZL
Z
Z;_
Z
z
zr
Z
Z_
0
r
r
_
}�
z
r
J Q
Q
N v
r'.
N O
cr'.
r
U
N
5u6
6
Z
Z
z
a
U
.0
x
LL
C
n Z
¢
O
0
...
Y V
C
J
O•
C
C
—
-,
V
...
�.
>
0<
90
T
N
v^
x
C
r.
>-0
c
Z
Z
Z
a
Z
ZZ
a
a
7_
_
_
_
_
J
N
N
.•.
N
e.
r-.
ry
..
,...
U-'
-
. y
Z
ti U
-
-
�
-
c
-
IC..
c
-
z
•
-
LJ
v
-
LIZ
-
H
U
w
c
p
c
O
c
O
o
o
-
L
0
O
-a.
--
>-,.
r
u
0
>
F
I
1
I
1
250
Occupational Safety and Health Admin., Labor
Subpt. P. App. D
I
P
I
H
H
H
I
H
H
H
I
I
I
I
I
U
aNz t O O U N
d -0 N N
X X X
O- N
- z z z z z z z z z
F J n en en en n n r1 en n
Uo
- NZ a' K O vl C O vl O 'rto O
U ≥ 0< `O C vl 00 M1 v. .G
^ m
OU,
Wv�i1 E u
U z N J F- N N N n
Z -.Z•• Z Z •'
C } z O J ` N rON0 t'1 NO enr1 NO N'.
O U K U p Z Z z z C
rn vl U r, oo O c
UL O Lam., K U O h O O r O U,C C <
T > O < .o oo en r .c
o<}F o p
a to ? Y' C z 5 -
C U
z z z z z z z z z u
F Q C w J N N t^. N C'1 f'1 N t^,
o
c� �_
z_ F _ c `
C NZ O C
Y V � p r p O ^ m c �n O r
J 0< V' .G C V1 OC F Y .G V
< - a
N Z V
O J v^. C C vi O C �n - _ .-. . r(-
N LJO — —
lJ u u ^ o
tJjtO
< - o CEEn
0z F _ L
U
� L L z v o A C C u
Y c - C E
< < 0
C
U F a O a O ti O - u u
N
C O w L9 > L - > - G - > - ^ lry Li h .. .. d
p Fes- �- O O O > >
C " ^ N C C
V 00
8 Z Z U
' 251
Subpt. P, App. E 29 CFR Ch. XVII (7-1-92 Edition)
APPENDIX E TO SUBPART P -ALTERNATIVES TO TIMBER SHORING
18"
VERT
SPAC
4' MA
RTICAL RAIL
YDRAULIC CYLINDER
Figure 1. Aluminum. Hydraulic Shoring
a
1
I 1 r
i!
O O O O
Figure 2. Pneumatic/hydraulic Shoring
252
1
1
1
1
1
1
1
1
1
1
1
1
1
1
1
1
1
1
1
iOccupational Safety and Health Admin., Labor Subpt. P, App. E
1
1
S. III 11 n r�r..r
Figure J. Trench Jacks (Screw Jacks)
1
i
1
1
1 - _
Figure 4. Trench Shields
1
1
1
1 253
Subpt.
P, App. F
29
CFR Ch. XVII (7-1-92 Edition)
APPENDS% F TO SUBPART P
—SELECTION OF
PROTECTIVE SYSTEMS
I
I The following figures are a graphic summary of the requirements contained in subpart P
for excavations 20 feet or less in depth. Protective systems for use in excavations more than
20 feet in depth must be designed by a registered professional engineer in accordance with
4 1926.652 (b) and (c).
Is the excavation more
than 5 feet in depth?
Is there potential
for cave-in?
Sloping.
selected.
Is the excavation
entirely in stable rock?
Excavation may. be
made with
vertical sides.
Excavation must be
sloped, shored, or
shielded.
Shoring or shielding
selected.
Go to Figure 2 I Co to Figure 3
FIGURE 1 - PRELIMINARY DECISIONS
1
1
I
1
254
Occupational Safety and Health Admin., Labor
Subpt. P, App. F
Excavation must comply with
one of the following three
options:
Option 1:
51926.652 (b)(2) which
requires Appendices A
and 3 to be followed
Option 2:
1926.652 (b)(3) which
requires other tabulated
data fsee definition) to
be followed.
Option 3:
£1926.652 (b)(4) which
requires the excavation
to be designed by a
registered professional
engineer.
Sloping selected as the
method of protection
Will soil classification
be made in accordance
with ,1926.652 (b)?
NO
Excavations must comply
with$1926.652 (b)(1) which
requires a slope of llH:1V
(34'.
FIGURE 2.- SLOPING OPTIONS
255
Subpt. P, App. F
29 CPR Ch. XVII (7-1-92 Edition)
I
Shoring or shielding selected
as the method of protection.
Soil classification is required
when shoring or shielding is
used. The excavation must comply
with one of the following four
options:
Option 1
.1926.652 (c)(1) which requires
Appendices A and C to be followed
(e.g. timber shoring).
Option 2
1926,652 (c)(2) which requires
manufacturers data to be followed
(e.g. hydraulic shoring,trench
jacks, air shores, shields).
Option 3
51926.652 (c)(3) which requires
tabulated data (see definition)
to be followed (e.g. any system
as per the tabulated data).
Option 4
,1926.652 (c)(4) which requires
the excavation to be designed
by a registered professional
engineer (e.g. any designed
system).
FIGURE 3 - SHORING AND SHIELDING OPTIONS
I
I
I
I
I
I
I
I
L
I
I
I
I
I
I
I
256 '
2
' 3
I
I
I
I
I
Special Provisions and Requirements
Foster adapters or swivel adapters are to be used wrapped for
attaching valves to tees. These adapter assemblies, like all
metal fittings, must be polywrapped.
All ductile, cast or stainless pipe and/or fittings shall have
aplyethylene encasement.
Fire Hydrants:
The contractor should also paint the bonnets as follows
Color Flow Under Fire Conditions
Light Blue 1500 gpm
Light Green 1000-1499 gpm
Orange 500-999 gpm
Red 4 499 gpm
All of the mix details are available at Lowe's on North
College Avenue. Other paint suppliers should be able to match
from the following information. Specification information for
these paints is on the attached Lowe's information. We
recommend that any hydrants with the red color bonnet be
painted first with Metal Primer 48938 Red. These paints are
all glossy enamel, but not reflective.
Blue Blue Lupine
Green Light Adam Green
Orange Bright Tangerine
Red Fireberry or manufacturer's
original red
Meter box lids should be C -109P, as made by Western Iron. Do
not use locking lids. Additional, high lids shall be used in
area which have traffic potential (in driveways, etc.).
5. valve boxes shall be of the U. S. Pipe (American Flow Control)
trench adapter type, in the correct length to match the bury
of the main. All lids shall be ductile iron. All lids shall
have a concrete pad with a minimum of 18" square or round
dimension. These shall be used in both paved and unpaved
applications. Tracer wire connections on the valve box
assemblies shall be installed per the attached drawing.
6. Polyethelylene (PE) service lines shall be acceptable for 1"
and 2" service lines from the main to the meter. Stiffeners
must be used (1 3/4" long for 3/4" and 1" pipe, and 3" long
for 2" pipe). Compression unions shall be used to attach the
PE pipe. The PE pipe must be bedded in grit or sand. SB2 is
not acceptable. Pipe shall be 200 psi Driscoll pipe et
specifications) rated for a working pressure of 200 psi.
I
I
I
H
L
I
H
H
I
F
P
I
I
I
I
I
I
specifications) rated for a working pressure of 200 psi.
7. Tracer wire must be installed from the water main to each and
every meter box, placed with the water service line. These
tracer wires shall be continuous with the tracer wire used for
the water main, so that the main may be traced from the meter.
8. Galvanized services, fittings adapters and other hardware are
prohibited under any circumstances. If no brass fitting is
available, stainless steel shall be used.
9. Connections on service lines shall be made with brass
compression fittings (Mueller H15403 or approved equal).
Sweated attachments are not acceptable.
10. Fill dirt or gravel must be compacted around valve boxes, fire
hydrants, and other surface attachments.
11. Service lines shall be buried at a depth of 30" below curb
line all the way to the meter box. (Justification -we have
many services which are going to freeze under bad winter
q• conditions because yards are cut down after the developer is
z finished.
Neither concrete nor corrugated metal pipe shall be permitted
for water or sewer line encasements.
13. Smooth steel encasements shall be used. Encasement pipe to be
used for water line installations shall not have been used for
any conveyance purpose in the past.
14. Water and sewer lines in encasements shall include self -
restraining gaskets (field -lock gaskets for ductile iron or
bell restraints for PVC) for all joints inside the encasement
pipe and for the first joint in each direction outside the
encasement pipe.
15. Pipes under culverts, creeks, retaining walls, or other
difficult and/or dangerous to maintain areas shall be encased.
16. Encasements shall be sealed on the ends with rubber end caps.
Encasements shall not be filled with sand.
17. Wood shall not be used as encasement spacers. Manufactured
spacers of Smith -Blair model 883 shall be used. Three spacers
shall be installed per joint so that the spacers are equally
spaced along the length of the pipeline.
18. If water is to be shut off for any reason, there shall be a
preconstruction meeting prior to the shut off. The shut off
must conform to the letter published with the notifications
attached to that letter.
I
19. Precast valve box concrete collars are acceptable in unpaved
areas.
20. Polywrap or pre -installed plastic coating is required for
copper service lines.
21. Valves, bends, reducers and other hardware near bends shall be
positively bolted, all -threaded, or mechanically joined to
each other. Bolted includes single and double flanged
adapters (such as Foster Adapters or Swivel Adapters) which
provide a solid bolted or mechanical joint type connection.
H
H
H
I
H
H
I
I
I
I
I
I
22. For all -threads, eye -bolt attachments are not acceptable.
23. Fire hydrant valves shall be positively connected to the water
main. If the hydrant leg is greater than 70 feet, an
additional valve shall be placed near the hydrant, between 5'
and 10' from the hydrant. Like all valves, this valve shall
be retained.
24. Calls for valves to be operated must meet the same
requirements of being arranged by 10:00 AM the day prior to
the desired time. No valves or other water system
appurtenances which have been accepted by the City, may be
operated by any individuals other than City employees (or by
personnel under their supervision) unless specific permission
is given from the Water/Sewer Maintenance Superintendent.
25. Under no circumstances shall water
water service in the course of
written permission from the Wat
Superintendent. In the event that
a customer, each customer shall be
memorandum.
be shut off to any active
new construction without
:r and Sewer Maintenance
water must be shut off to
notified per the attached
26. All valves, bends, hydrant shoes, and other hardware shall be
restrained with Megalug style retainers or approved equal.
27. All bolts shall be stainless steel.
28. In final inspections, the entire new water system shall be
tested for continuity with the tracer wire. The contractor
shall hook up a tracer box of a type similar to those employed
by the City and the inspector shall see that the entire system
can be traced.
29. All copper for services shall be type K.
30. All 2" PVC pipe shall be DR 13.5, 200 psi working pressure.
31. Gate valves shall be as per the existing specifications with
the following amendment: they shall be epoxy coated of the
following model: Mueller A2360-20 (in -line) and A2360-16
(tapping) or approved equal.
I
32. Butterfly valves shall be as per the existing specifications
with the following amendment: they shall be epoxy coated of
the following model: Mueller B3211-20-121. Valves 1" through
20" shall have valve discs constructed of alloy cast meeting
ASTM A-126 class B.
' 33. Service yokes for 3/4" domestic services shall be Mueller H -
2404R, 5/8" by 3/4" by 12" (correction to current
specification).
I
I
I
I
I
I
I
C
C
1
1
1
1
THE CITY OF (AY(TTFVq((. ARKANSAS _— ...
1.
' DEPARTMENTAL CORRESPONDENCE
' To: Record
From: David Jurgens, Water/Sewer
' Date: May 13, 1997
Re: Water Shut Down and Boil Orders For Contractor Work
This is the procedure to be followed any time a contractor must
shut down water to any customers serviced by the Fayetteville water
system.
First, shutting down water to any customers for a planned job shall
be avoided whenever Possible. All possible efforts must be made to
,keep water flowing to all customers. if the shut down involves
' >hosta1s, health facilities, schools, food service establishments,
?day care centers, industries, and other water -critical facilities,
temporary water service must be provided at the contractor's or
' developer's expense.
In the event that water must be shut off to a customer, customer shall be notified no later than 72 hours each
ing
' days, whichever is longer), in advance with a form provided(or three
Water and Sewer Maintenance Superintendent. A copy of this form is
attached. The contractor is responsible to hand out these advance
' notices to each customer who will be out of service after specific
coordination with the Water and Sewer Maintenance Department.
The City reserves the right to establish the day and time for the
water shut -down. This may include, but is not limited to,
inimum
usrequiring
usage for that shut -down take place at the customers, and will frequently be the
nightmand/or
' weekend work.
when possible, we would like to have the work performed no later in
the week than Wednesday, so we can have the boil order results back
in the same week as the work is performed.
' Steps of the process are as follows:
1. Identify the potential need to shut down the water.
' 2. Coordinate with the Water/Sewer Department to identify
exactly what addresses will be impacted and what valves must be
operated. Jointly ensure that all of these valves are in proper
working order.
I
I
I
' 3. Meet with the following to ensure all parties are involved
and fully aware of the project and what is involved. This meeting
will normally be held at the City Engineer's office at least 4
' working days prior to the shut down The"following must attend:
the designing engineer (or his representative) ,representative) I the contractor, the
City's engineering inspector, and a representative of the
Water/Sewer Department. The designing engineer or contractor must
' bring with them the list of addresses to be affected. They must
also have detailed plans for the work to be performed and plans for
any temporary water services to be provided. Coordination must be
made with each critical water user prior to this meeting. Points
of contact (names and telephone numbers) for each must be on the
:list.
4. Hand out notices to the customers three working days in
advance. Each individual address that is notified must be written
down; and a copy of the list must be delivered to the Water and
Sewer Department within two working hours of the notices being
-.distributed. This list should exactly match the list identified in
advance, per paragraph 3, above. If apartments or other multi-
, dwelling structures are involved, notice must be delivered to each
individual residence. Legally, notices can not be put in
mailboxes.
' 5. Confirm with both Engineering and Water/Sewer no later
than 10:00 a.m. the day prior to the work being performed to
confirm inspection and valve operation. (Engineer/Contractor].
6. Perform the work.
' 7. Notify Water/Sewer when finished with job, so they can
take water samples for the boil order.
' 8. Issue boil order releases when sample results are
returned. The contractor is responsible to issue the releases
within four hours of their return, under supervision of one
Water/Sewer employee.
1
I have attached two separate notices which may have to be
' distributed. The first is for water pressure reduction, when no
boil order will be required. The second is when a boil order will
be required. The decision of which is required will be made in the
meeting at Engineering (step 3).
I\3PKC1\eocc-cox.nw
LI
I
H
I
I
I
I
I
I
I
I
I
I
I
I
irl
FAYETTEVI LLE
THE CITY OF FAYETTEVILLE. ARKANSAS
NOTICE TO THE CUSTOMER
Due to maintenance of a water main it was necessary to shut the
water off to make repairs. Although the water that has been left
standing in the water main is still considered safe, as a
precautionary measure the Arkansas State Health Department requires
the City to ask you to boil your cooking and drinking water for 5
minutes before using. This boil order will be in effect until the
water has been tested and approved by the Arkansas State Health
a Department. The results should be known in 5 to 7 days. You will be
notified as soon as the Water Division receives approval from the
State Health Department.
Again, there is no evidence that the water is contaminated, but for
your safety a precautionary boil order has been issued for your
residence or business.
If you have any questions please call, Fayetteville Water Division
575-8386.
DAVE Mayetteville
es
WaterSewer Maintenance Manager City
I
113 WEST MOUNTAIN 72701
THE CITY OF FAYETTEVILLE, ARKANSAS
NOTICE TO THE CUSTOMER
C,
I
I
I
I
H
I
Due to scheduled water system maintenance in your area, the
contractor listed below, under supervision of the engineerlisted
below, must reduce the water pressure in the area serving your
business or residence. The water pressure will be reduced at the
following time:
DATE TURNED DOWN:
TIME TURNED DOWN (approximate):
TIME TURNED DOWN (approximate):
•If you need to draw up water
time.
e
:As this is simply a temporary
be no break in the integrity
there is no requirement for
perfectly safe to drink as so
for use, please due so before this
reduction in pressure and there will
of the lines providing your water,
a boil order. Your water will be
on as full pressure is restored.
If you have any questions, please call one of the following:
Engineer:
Neee/Coepeny Phone
Contractor:
Nnee/Coepeny Phone
IThank you for your patience and consideration.
I
DAVID JURGENS
Water/Sewer Maintenance Superintendent
575-8386
I
I
' PRM\C:\APP\MPpATA\Do[L-CON. LT2
1: FAYETTEVI LLE
I.
ITHE CITY OF FAYETTEVIIIE. ARKANSAS
I
I
C
NOTICE TO THE CUSTOMER
Due to scheduled water system maintenance in your .area.,. the
contractor listed below, under supervision of -the engineer listed
below, must shut the water off to your business or residence. The
water will be off as follows:
DATE TURNED OFF (approximate):
TIME TURNED OFF (approximate):
TIME TURNED ON (approximate):
If you need to draw up water for use, please due so before this
'time.
Once your water has been turned back on, the State Health
Department requires that we ask that you boil your cooking and
drinking water for 5 minutes until you receive notice that the boil
I order is lifted. The boil order will be in effect until the water
has been tested and approved by the State Health Department. The
results should he known in 5 to 7 days. You will be notified via
' letter on your door as soon as the Water/Sewer Department receives
approval from the Health Department.
This boil order is a precautionary requirement. The chances. of
contamination in your water are slight, but we must publish the
boil order as a precautionary safety "measure and to meet State
regulations.
IIf you have any questions, please call one of the following:
' Engineer:
Rama/Company Phone
Contractor:
Name/Company phone
Thank you for your patience and consideration.
' DAVID JURGENS
Water & Sewer Maintenance Superintendent
575-8386
pRM\C:\App\WTDATA\DOI L -CON. LTA
1
ze•d -10i01
BOIL OPDER
FORM
DATE NOTIFIED
ADDRESSES:
DATE CLEARED
CREW FOREMAN
-n .I O r'OC'IC
ni
SNnrcin rt ?NS 8 N310f WOKS uusc:8@ 666T -LT -£0
CJ
• BSI►Si
-
I
I
I
I
I
I
I
I
I
t. Prune early in life of the tree so pruning wounds are small
and so strowth goes where you want it.
2. Begin your visual inspection at the top of the tree and work
downward.
3. identify the best leader and lateral branches (scaffold limbsi
before you begin pruning and remove dcfecztve pans before
pruning for forth.
4. Don't wonv about protecting pruning cuts. For aesthetics.
you may feel better painting larger wounds with a neutral -
color tree paint. but the evidence is that it does not prevent
or reduce decay.
5. Keep your tools sharp. One -hand pruning shears with
curved blades Iserateunl work bet on young trees.
6. make saucy a number one priority For high branches use a
pole pruner. Some. like the one pictured, have both a saw
and shears on the same tool. A major job on a big tree
should be done by a professional arbormt.
7. When you prune back to the trunk or a larger limb.
branches too small to have formed a collar (swollen area at
base) should be cut close. INodce in the drawing of the
pruning shears that the curling blade Is cutting upward for
less effort and a close cut.) Otherwise. follow the rules of
good pruning of larger limbs by cutting just outside the
branch ridge and collar and at a slight down -and -outward
angle Iso as not to injure the collart Do not law a
protruding stub.
When simply shortening a small branch. make the cut at a
lateral bud or another lateral branch (referred to as -head"
or 'headback phoning" L Favor a bud that will produce a
branch that will grow in a desired direction (usually
outward). The cut should be sharp and clean and made at
a slight angle about /. inch beyond the bud.
a!
Wolter Pruning during domancy is the most common practice. It results in a vigoutous burst of
new growth in the spring and should be used if that is the dmlred effect it is uacally best to wait until
the coldest part of winter has passed. Some species, such u maples, walnuts and birches. may -bleed"
when the sap begins to flow This is not harmful and will cease when the tree leafs out.
Summer TO direct the growth by slowing the branches you dori t want. or to slow or'dwarf' the
development of a tree or branch. pruning should be done soon after seasonal growth is complete. The
reason for the slowing effect is that you reduce the tool leaf surface. thereby reducing the amount of
food manufactured and sent to the roots for their development and next year's growth of the crowns
Another reaaan to prune in the summer is for cnrtecttve purposes. Defective limbs can be seen
more easily. or limbs that hang dawn too far under the weight of leaves.
Pall Because decay fungi spread their spores profusely In the fall and healing of wounds seems to b
slower on fall cuts, this is a good time to leave your pruning tools in storage.
Flowering Trees if your purpose for pruning is to enhance flowering; 1. For trees or shrubs
that bloom in summer or fall on current years growth (ad., rsape myrdel. prune in winter
2. For trees that bloom in spring from buds on one -year -old wood leg. dogwood and flowering fruit
trees), prune when their flowers fade.
Caution: in some arras of the countryt diseases or insect o n rence may be affected by the tune of
pruning Check wvirh your counry extension agent or city forttter, or an arborist or nursery operator to
see if there are any beef problems.
rSII an tY nt.Lrri\ two I
OR DK.hNCac
tvieTAL
app
4INIMVM
MINIMUM
—._. _ IO' E1INI MUM ----
SAMPLE TREE PROTECTION FENCING
Diagram 3
z _1
I
I�caelTl�� ooT_zo _- '1
ROOT PRUNING
Diagram 1
Scum.: Steve Clark & Associates
I —
'FAYETTEVILLE
I
THE CITY OF FAYETTEVILLE. ARKANSAS
April 5, 1999
I
I
C
Sue Lee
4041 Wedington Drive
Fayetteville, AR 72703
Dear Ms. Lee:
;,The following is
water distribution line
RE: Highway 16 West Waterline
Job No. 99028
Parcel No. 765-16252-000
Side Letter
a list of concerns expressed relating to the construction of the proposed
as it crosses your property:
Construction will necessitate the removal of certain trees and shrubs within
' the easement area. The City tries to avoid damage to and the loss of trees
and other vegetation; however, there are times when circumstances leave
no other choice. The City cannot adequately compensate you for the loss
' of mature trees that are in landscaped areas; however, the following
proposed compensation will allow you, at your discretion, to have a local
nursery plant similar trees/shrubs as a substitute for those that will have to
be removed:
' 1 -13" pine @ $200 $200
Standard nursery installation on the above (50%) 100
' Total proposed compensation for landscape damages $300
o The two saplings farthest north within the "tree farm" area shall be spade
' dug and transplanted by the contractor either south of their present location
or to another location specified by you yet out of the way of the waterline.
' o All other trees should be avoided and protected by the contractor. However,
please be aware that some roots will be clean cut during construction.
' If you have any further concerns or comments, please contact Ed Connell at (501) 444-
3415, Jill Goddard at 444-3407, or in their absence, Sid Norbash, Project Engineer, at 575-8205.
Sincerely yours,
' Jim Beavers
City Engineer
JBljsg
113 WEST MOUNTAIN 72701 501 521-7700
c•v cn.
I FAYETTEVILLE
I
' THE CITY OF FAYETTEVILLE, ARKANSAS
' April 12, 1999
Pat & Janie Gazzola
P.O. Box 1152
Fayetteville, AR 72702-1152
RE: Highway 16 West Waterline
Job No. 99028
Parcel No. 765-16254-000
Side Letter
' Dear Mr. & Mrs. Gazzola
As per your discussions with Jill Goddard on April 8, 1999, the following is a list of
concerns expressed relating to the construction of the proposed waterline as it crosses your
property:
' C> Contractor is to avoid cutting asphalt surface of parking lot in order to avoid
damage to petromat underneath asphalt. Instead, the concrete pavement
of the driveways, is to be saw cut with placement of the waterline being
approximately centered underneath the "Catfish Hole" sign.
Arrangements will be made with Ozarks Electric for the guy wires to be
' released temporarily for placement of the waterline and then reset.
c The "Catfish Hole" sign and the lighting fixtures will be temporarily removed
for construction purposes and reset as close as possible to their original
locations.
1
1
1
1
If you have any further concerns or comments, please contact Ed Connell at 444-3415, Jill
Goddard at 444-3407, or in their absence, Sid Norbash, Project Engineer, at 575-8205.
Sincerely yours,
/Jim Beavers
City Engineer
JB/jsg
113 WEST MOUNTAIN 72701 501 521-7700
FAX 501 575-8257
IFAYETTEVILLE
C
CITY OF FAYETTEVILLE. ARKANSAS
April 5, 1999
' WHM Land Investments, Inc.
and
Robertson Oil Company, Inc.
'Attn: F. L. "Butch" Robertson
P.O. Box 310
Fayetteville, AR 72702-0310
1
1
I
1
I
1
1
1
1
1
1
RE: Highway 16 West Waterline
Job No. 99028
Parcel No. 765-16251-000
Side Letter
Dear Mr. Robertson
4
The following is a list of concerns expressed relating to the construction of the proposed
water distribution line as it crosses your property:
The two
posts
on either side of
the
driveway
will be moved
by the contractor
south of
their
present
location
so
they are
out of the way
of the waterline.
If
you have
any further concerns or comments,
please contact Ed Connell
at
(501) 444=
3415, Jill
Goddard
at 444-3407, or in their absence, Sid
Norbash, Project Engineer,
at
575-8205.
Sincerely yours,
Jim Beavers
City Engineer
JBrjsg
1113 WEST MOUNTAIN 72701 501 521-7700
FAX 501 575.9757
I. FAYETTEVILLE
Li
THE CITY OF FAYETTEVILLE, ARKANSAS
IApril 8, 1999
1
Orther D. & Betty A. Feagin
' 4023 Wedington Drive
Fayetteville, AR 72701
IRE: Highway 16 West Waterline
Job No. 99028
' Dear Mr. and Mrs. Feagin:
' The City of Fayetteville is planning the installation of an 18 -inch waterline along a
portion of Highway 16 West from Shiloh Drive to just west of Meadowlands Drive. On
April 6, 1999, I met with F. L. "Butch" Robertson, one of the owners of the property north
' of yours, to discuss easements needed across their property. He informed me that you
have a driveway easement with them.
' This letter is to inform you that the posts on either side of your driveway will need
to be moved by the contractor south a few feet of their present location in order to be out
of the easement area requested for the waterline. (Enclosed is a copy of a side letter
given to Mr. Robertson.)
If you have any concerns, comments, or want to discuss this project, please feel free
Ito call Ed Connell at 444-3415, myself at 444-3407, or Sid Norbash, Project Engineer, at
575-8205.
Sincerely,
J S. Goddard
Land Agent
' fjsg
Enclosure
1
113 WEST MOUNTAIN 72701 501 521-7700
coy [(M C,c o,c,
EAYETTEVILLE
I
' THE CITY OF FAYETTEVILLE. ARKANSAS
' April 5, 1999
WHM Land Investments, Inc.
and
Robertson Oil Company, Inc.
Attn: F. L. "Butch" Robertson
P.O. Box 310
Fayetteville, AR 72702-0310
RE: Highway 16 West Waterline
Job No. 99028
Parcel No. 765-16251-000
Side Letter
Dear Mr. Robertson:
The following is a list of concerns expressed relating to the construction of the proposed
water distribution line as it crosses your property:
o The two posts on either side of the driveway will be moved by the contractor
south of their present location so they are out of the way of the waterline.
If you have any further concerns or comments, please contact Ed Connell at (501) 444=
3415, Jill Goddard at 444-3407, or in their absence, Sid Norbash, Project Engineer, at 575-8205.
Sincerely yours, in•Jim Beavers
City Engineer
JBCsg
I
I
C
' 113WESTMOUNTAIN 72701 501521-7700
I FAYETTEVILLE
1
1 THE CITY OF FAYETTEVILLE. ARKANSAS
1 April 8, 1999 -
1 Airways Freight Corporation
Attn: Dale W. Caudle
P.O. Box 1888
Fayetteville, AR 72702-1888
RE: Highway 16 West Waterline
1 Job No. 99028
Parcel No. 765-1625-001
Side Letter #2
1 Dear Mr. Caudle:
1 * In follow up to a meeting this morning between Ken Center and Jill Goddard,
representative for the City, the following is a list of concerns relating to the construction of the
proposed water distribution line as it crosses your property:
Construction across your property will -Lot take place until after June 1, 1999.
(This is in order to avoid any inconvenience during your open house
festivities of May 14-15, 1999.)
The fire hydrant will be located just west of your west property line instead
on your property as originally shown (see enclosed drawing).
The tulip trees are to be moved south just outside of the permanent
easement boundaries (see enclosed drawing). No additional temporary
construction easement area is expected to be needed.
If you have any further concerns or comments, please contact Ed Connell at (501) 444-
3415, Jill Goddard at 444-3407, or in their absence, Sid Norbash, Project Engineer, at 575-8205.
Sincerely yours,
Jt
Iv1 Jim Beavers
City Engineer
I
JBfjsg
Hr�
1 113 WEST MOUNTAIN 72701 501 521-7700
FAYETTEVILLE
I
' THE CITY OF FAYETTEVILLE. ARKANSAS
April 5, 1999
Airways Freight Corporation
Attn: Dale W. Caudle
P.O. Box 1888
'Fayetteville, AR 72702-1888
RE: Highway 16 West Waterline
' Job No. 99028
Parcel No. 765-1625-001
Side Letter
' Dear Mr. Caudle:
' 'The following is a list of concerns expressed relating to the construction of the proposed
water distribution line as it crosses your property:
The two tulip trees (one on either side of the driveway and inside the fence)
shall be spade dug and transplanted by the contractor either south of their
present location or to another location specified by you yet out of the way of
' the waterline.
The crab apple trees (3 on the east side and 5 on the west side), although
they are within the permanent easement area, are to be protected by the
contractor. Temporary protective fencing is to be placed around each tree.
However, the crab apple closest to the tulip tree on the west side of the
driveway may need to be transplanted to a new location as the tulip trees.
o The fencing along the east and west property lines and along either side of
the driveway will be temporarily removed for the construction of the waterline
' and will be replaced in as good or better condition as first found. We hope
that only the rails be temporarily removed; however, some posts may need
to be reset.
' If you have any further concerns or comments, please contact Ed Connell at (501) 444-
3415, Jill Goddard at 444-3407, or in their absence, Sid Norbash, Project Engineer, at 575-8205.
' Sincerely yours,
Jim Beavers
City Engineer
' JBrjsg
113 WEST MOUNTAIN 72701 501 5217700
C.AV Cn• C7c.ovc7
I FAYETTEVILLE
I
THE CITY OF FAYETTEVILLE, ARKANSAS
1 April 15, 1999
First United Pentecostal Church
1 Attn: Trustees
3701 Wedington Drive
Fayetteville, AR 72701
1 RE: Highway 16 West Waterline
Job No. 99028
1 Water Tap
Dear Trustees:
1
'a. Thank you for the executed document on the above mentioned project.
Compensation has been requested and should be forwarded to you within the next two
1 weeks.
1 As per your inquiry about a water tap, the City will compensate you for the
anticipated cost of a water tap ($425.00) for the proposed relocation of the service line
across your property —to be relocated on the west side of the property. (A check has been
1 requested.) However, you will need to come to the City Engineering Department and make
arrangements for this water tap at the appropriate time.
1 If you have any questions or need additional information, please feel free to call
either Jill Goddard at 444-3407, Sid Norbash, Project Engineer at 575-8205 or myself at
575-8206.
1 Sincerely,
1 Jim Beavers
City Engineer
' JBisg
I
113 WEST MOUNTAIN 72701 501 521-7700
CAV Cr1 C7C.anIC7
IFAYETTEVILLE
[1
THE CITY OF FAYETrEVILLE, ARKANSAS
April 8, 1999
First United Pentecostal Church
Attn: Trustees
3701 Wedington Drive
Fayetteville, AR 72701
RE: Highway 16 West Waterline
Job No. 99028
Parcel No. 765-16249-000
Side Letter #2
1
1
1
1
1
1
1
1
1
1
Dear Trustees:
i
£The following is a list of concerns expressed during the meeting earlier today between Rev.
Ray Hassell, Rev. John Hassell, and Jill Goddard, representative for the City, relating to the
construction of the proposed water distribution line as it crosses church property:
The engineer has agreed to move the hydrant location to the east side of the
driveway (see attached drawing).
As
to the driveway,
plans are still to saw cut
and re -asphalt. To bore under
the
driveway is not
a feasible
option in this
situation.
If
you have
any further concerns or comments,
please contact Ed Connell
at
(501) 444-
3415, Jill
Goddard
at 444-3407, or in their absence, Sid
Norbash, Project Engineer,
at
575-8205.
Sincerely yours,
Jim Beavers
City Engineer
JBfjsg
13 WEST MOUNTAIN 72701 501 521-7700
CAY C(1• CVC.Gfc'
I FAYETTEVILLE
1
1 THE CITY OF FAYETTEVILLE. ARKANSAS
1 April 5, 1999
1 First United Pentecostal Church
Attn: Trustees
3701 Wedington Drive
1 Fayetteville, AR 72701
RE: Highway 16 West Waterline
1 Job No. 99028
Parcel No. 765-16249-000
Side Letter
1 Dear Trustees:
1 The following is a list of concerns expressed relating to the construction of the proposed
water distribution line as it crosses church property:
1 The six Bradford pear trees, although they are within the permanent
easement area, are to be protected by the contractor. Temporary protective
fencing is to be placed around each tree. However, please be aware that
some tree limbs will need to be trimmed back.
1 The fencing along the east and west sides will be temporarily removed for
the construction of the waterline and will be replaced in as good or better
1 condition as first found.
If
you have
any further concerns or comments,
please contact Ed Connell
at
(501) 444-
1 3415, Jill
Goddard
at 444-3407, or in their absence, Sid
Norbash, Project Engineer,
at
575-8205.
Sincerely yours,
Jim Beavers
City Engineer
JB/jsg
C
I
113 WEST MOUNTAIN 72701 501 521.7700
cAV cm c,c.n-,c,
I FAYETTEVILLE
I
' THE CITY OF FAYETTEVILLE. ARKANSAS
April 5, 1999
1
I
Ozarks Electric Cooperative Corporation
Attn: Board of Directors
P.O. Box 848
' Fayetteville, AR 72702-0848
RE: Highway 16 West Waterline
' Job No. 99028
Parcel No. 765-16248-000
Parcel No. 765-13729-000
' Parcel No. 765-13730-000
Side Letter
' Dear Gentlemen and Ladies of the Board:
The following is a list of concerns expressed relating to the construction of the proposed
water distribution line as it crosses your property:
' o Construction will necessitate the removal of certain trees and shrubs within
the easement area. The City tries to avoid damage to and the loss of trees
' and other vegetation; however, there are times when circumstances leave
no other choice. The City cannot adequately compensate you for the loss
of mature trees that are in landscaped areas; however, the following
' proposed compensation will allow you, at your discretion, to have a local
nursery plant similar trees/shrubs as a substitute for those that will have to
be removed:
' 1 - 12" diameter tree = 2 @ $140 $280
Standard nursery installation on the above (50%) 140
' Total proposed compensation for landscape damages $420
Any sod destroyed by construction will be replaced with Bermuda sod.
' If you have any further concerns or comments, please contact Ed Connell at (501) 444-
3415, Jill Goddard at 444-3407, or in their absence, Sid Norbash, Project Engineer, at 575-8205.
' Sincerely yours,
Its
Jim Beavers
City Engineer
' JBfjsg
13 WEST MOUNTAIN 72701 501 521-7700
FAX 501 575-8257