Loading...
HomeMy WebLinkAbout67-96 RESOLUTION• • • RESOLUTION NO. 67-96 A RESOLUTION AWARDING AN ENGINEERING CONTRACT WITH WITTENBURG, DELONY & DAVIDSON, IN AN AMOUNT NOT TO EXCEED $75,000, PLUS $10,000 REIMBURSABLE EXPENSE, TO PROVIDE ARCHITECTURAL AND ENGINEERING SERVICES FOR VARIOUS CIP AND HMR PARK PROJECTS; AND AUTHORIZING THE MAYOR TO SIGN EACH WORK ORDER UPON NEGOTIATION AND REVIEW Y BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF FAYETTEVILLE, ARKANSAS: Section 1. The City Council hereby awards an engineenng contract to Wittenburg, Delony & Davidson, in an amount not to exceed $75,000, plus $10,000 reimbursable expense, to provide architectural and engineering services for various CIP and HMR park projects and authorizes the Mayor and City Clerk to execute same. A copy of the contract is attached hereto marked Exhibit "A" and made a part hereof. Section 2. That the Mayor and City Clerk are hereby authorized to execute work orders upon the completion of negotiations for each project within the project amount and review. PASSED AND APPROVED this 4th day of June , 1996. • • `r_ ti�,'� \ I.t ` ATTEST: By: Traci Paul, City Clerk APPROVED; By: red Hanna, Mayor T 'H E AMERICA N INSTITUTE411 OF ARCHITECTS EXHIBIT A AIA Document B141 Standard Form of Agreement Between Owner and Architect 1987 EDITION THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES; CONSULTATION WITH AN ATTORNEY IS ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION. AGREEMENT made as of the Nineteen Hundred and BETWEEN the Owner: (Name and address) and the Architect: (Name and address) 30th Ninety -Six day of April CITY OF FAYETTEVILLE, ARKANSAS CITY ADMINISTRATION BUILDING 113 WEST MOUNTAIN STREET FAYETTEVILLE, ARKANSAS 72701 WITTENBERG, DELONY & DAVIDSON, INC. 100 WEST CENTER, SUITE 102 FAYETTEVILLE, ARKANSAS 72701 in the year of For the following Project: (Include detailed description of Project, location, address and scope.) A contract for various projects over a one (1) year period from the date of issue of the first work order which may include Improvements and Renovations to Wilson, Gulley, Davis, Lake Fayetteville South (Veterans), Holtz, Babe Ruth, Gregory, Finger, Pinecrest/Pine Valley, Brookbury and Boxwood Parks and/or other funded projects as may be required. The Owner and Architect agree as set forth below. Copyright 1917, 1926, 1948, 1951, 1953 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, ©1987 by The American Institute of Architects, 1735 New York Avenue, N.W., Washington, D.C. 20006. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United States and will be subject to legal prosecution. AIA DOCUMENT B141 • OWNER -ARCHITECT AGREEMENT • FOURTEENTH EDITION • A]Ae • ©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 WARNING: Unlicensed photocopying violates U.S. copyright laws and Is subject to legal prosecution. 8141-1987 1 EDITOR'S NOTE From time to time, the AIA makes minor corrections and clarifications in`its documents as they are reprinted. Changes in the 7/88 reprinting of the 1987 edition of B141 were made in Subparagraphs 2.6,1.and 113,2., Changes in this 6/92 reprinting were made in Subparagraph 2.6.10 and Paragraph 4.5. See'Section C of the Instruction.Sheet for a detailed descriptionof _ these changes._... a • ds • • • • TERMS AND CONDITIONS OF AGREEMENT BETWEEN OWNER AND ARCHITECT ARTICLE 1 ARCHITECT'S RESPONSIBILITIES 1.1 ARCHITECT'S SERVICES 1.1.1 The Architect's services consist of those services per- formed by the Architect, Architect's employees and Architect's consultants as enumerated in Articles 2 and 3 of this Agreement and any other services included in Article 12. 1.1.2 The Architect's services shall be performed as expedi- tiously as is consistent with professional skill and care and the orderly progress of the Work. Upon request of the Owner, the Architect shall submit for the Owner's approval a schedule for the performance of the Architect's services which may be adjusted as the Project proceeds, and shall include allowances for periods of time required for the Owner's review and for approval of submissions by authorities having jurisdiction over the Project. Time limits established by this schedule approved by the Owner shall not except for reasonable cause, be eaccded by the Architect or Owner. 1.1.3 The services covered by this Agreement are subject to the time limitations contained in Subparagraph 11.5.1. ARTICLE 2 SCOPE OF ARCHITECT'S BASIC SERVICES 2.1 DEFINITION 2.1.1 The Architect's Basic Services consist of those described in Paragraphs 2.2 through 2.6 and any other services identified in Article 12 as part of Basic Services, and include normal struc- tural, mechanical and electrical engineering services. 2.2 SCHEMATIC DESIGN PHASE 2.2.1 The Architect shall review the program furnished by the Owner to ascertain the requirements of the Project and shall arrive at a mutual understanding of such requirements with the Owner. 2.2.2 The Architect shall provide a preliminary evaluation of the Owner's program, schedule and construction budget requirements, each in terms of the other, subject to the limita- tions set forth in Subparagraph 5.2.1. 2.2.3 The Architect shall review with the Owner alternative approaches to design and construction of the Project. 2.2.4 Based on the mutually agreed-upon program, schedule and construction budget requirements, the Architect shall prepare, for approval by the Owner, Schematic Design Docu- ments consisting of drawings and other documents illustrating the scale and relationship of Project components. 2.2.5 The Architect shall submit to the Owner a preliminary estimate of Construction Cost based on current area volume or other unit costs. 2.3 DESIGN DEVELOPMENT PHASE 2.3.1 Based on the approved Schematic Design Documents and any adjustments authorized by the Owner in the program, schedule or construction budget, the Architect shall prepare, for approval by the Owner, Design Development Documents consisting of drawings and other documents to fix and describe the size and character of the Project as to architectural, struc- tural, mechanical and electrical systems, materials and such other elements as niay be appropriate. 2.3.2 The Architect shall advise the Owner of any adjustments to the preliminary estimate of Construction Cost. 2.4 CONSTRUCTION DOCUMENTS PHASE 2.4.1 Based on the approved Design Development Docu- ments and any further adjustments in the scope or quality of the Project or in the construction budget authorized by the Owner, the Architect shall prepare, for approval by the Owner, Construction Documents consisting of Drawings and Specifica- tions setting forth in detail the requirements for the construc- tion of the Project. • 2.4.2 The Architect shall assist the Owner in the preparation of the necessary bidding information, bidding forms, the Condi- tions of the Contract, and the form of Agreement between the Owner and Contractor. 2.4.3 The Architect shall advise the Owner of any adjustments to previous preliminary estimates of Construction Cost indi- cated by changes in requirements or general market conditions. 2.4.4 The Architect shall assist the Owner in connection with the Owner's responsibility for filing documents required for the approval of governmental authorities having jurisdiction over the Project. 2.5 BIDDING OR NEGOTIATION PHASE 2.5.1 The Architect, following the Owner's approval of the Construction Documents and of the latest preliminary estimate of Construction Cost, shall assist the Owner in obtaining bids or negotiated proposals and assist in awarding and preparing contracts for construction. 2.6 CONSTRUCTION PHASE—ADMINISTRATION OF THE CONSTRUCTION CONTRACT 2.6.1 The Architect's responsibility to provide Basic Services for the Construction Phase under this Agreement commences with the award of the Contract for Construction and termi- nates at the earlier of the issuance to the Owner of the final Certificate for Payment or 60 days after the date of Substan- tial Completion of the Work. 2.6.2 The Architect shall provide administration of the Con- tract for Construction as set forth below and in the edition of AIA Document A201, General Conditions of the Contract for Construction, current as of the date of this Agreement, unless otherwise provided in this Agreement. 2.6.3 Duties, responsibilities and limitations of authority of the Architect shall not be restricted, modified or extended without written agreement of the Owner and Architect with consent of the Contractor, which consent shall not he unreasombly withheld. AIA DOCUMENT B141 • OWNER -ARCHITECT AGREEMENT • FOURTEENTH EDITION • AIA° • ©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 WARNING: Unlicensed photocopying violates U.S. copyright laws and is subject to legal prosecution. B141-1987 2 • 2.6.4 The Architect shall be a representative of and shall advise and consult with the Owner (1) during construction until final payment to the Contractor is due, and (2) as an Additional Ser- vice at the Owner's direction from time to time during the cor- rection period described in the Contract for Construction. The • Architect shall have authority to act on behalf of the Owner only to the extent provided in this Agreement unless otherwise modified by written instrument. 2.6.5 The Architect shall visit the site at intervals appropriate to the stage of construction or as otherwise agreed by the Owner and Architect in writing to become generally familiar with the progress and quality of the Work completed and to determine in general if the Work is being performed in a man- ner indicating that the Work when completed will he in accor- dance with the Contract Documents. However, the Architect shall not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. On the basis of on-site observations as an architect, the Architect Shall keep the Owner informed of the progress and quality of the Work, and shall endeavor to guard the Owner against defects and deficiencies in the Work. (More extensive site . representation may be agreed to as an Additional Service, as described in Paragraph 3.2.) 2.6.6 The Architect shall not have control over or charge of and shall not be responsible for construction means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, since these are solely the Contractor's responsibility under the Contract for Construction. The Architect shall not be responsible for the Contractor's schedules or failure to carry out the Work in accor- dance with the Contract Documents. The Architect shall not have control over or charge of acts or omissions of the Contrac- tor, Subcontractors, or their agents or employees; or of any other persons performing portions of the Work. 2.6.7 The Architect shall at all times have access to the Work wherever it is in preparation or progress. 2.6.8 Except as may otherwise be provided in the Contract Documents or when direct communications have been spe- cially authorized, the Owner and Contractor shall communicate through the Architect. Communications by and with the Archi- tect's consultants shall be through the Architect. 2.6.9 Based on the Architect's observations and evaluations of the Contractor's Applications for Payment, the Architect shall review and certify the amounts due the Contractor. 2.6.10 The Architect's -certification for payment shall consti1 tute a representation to the Owner, based on the Architect's observations at the site as provided in Subparagraph 2.6.5 and on the data comprising the Contractor's Application for Pay- ment, that, to the best of the Architect's knowledge, informa- tion and belief, the Work has progressed to the point indicated and the quality of Work is in accordance with the Contract Documents. The foregoing representations are subject to an evaluation of the Work for conformance with the Contract Documents upon Substantial Completion, to results of subse- quent tests and inspections, to minor deviations from the Con-. tract Documents correctable prior to completion and to spe- cific qualifications expressed by the Architect. The issuance of a Certificate for Payment shall further constitute a -representation that the Contractor is entitled to payment in the amount certi- fied. However, the issuance of a Certificate for Payment shall not be a representation that the Architect has (1) made exhaus- tive or continuous on-site inspectionsto check the quality or • • • quantity of the Work, (2) reviewedconstruction means, meth- ods, techniques, sequences or procedures, (3) reviewed copies of requisitions received from Subcontractors and material sup- pliers and other data requested by the Owner to substantiate the Contractor's right to payment or (4) ascertained how or for what purpose the Contractor has used money previously paid on account of the Contract Sum. 2.6.11 The Architect shall have authority to reject Work which does not conform to the Contract Documents. Whenever the Architect considers it necessary or advisable for implementa- tion of the intent of the Contract Documents, the Architect will have authority to require additional inspection or testing of the Work in accordance with the provisions of the Contract Docu- ments, whether or not such Work is fabricated, installed or completed. However, neither this authority of the Architect nor a decision made in good faith either to exercise or not to exer- cise such authority shall give rise to a duty or responsibility of the Architect to the Contractor, Subcontractors, material and equipment suppliers, their agents or employees or other per- sons performing portions of the Work. 2.6.12 The Architect shall review and approve or take other appropriate action upon Contractor's submittals such as Shop Drawings, Product Data and Samples, but only for the limited purpose of 'checking for conformance with information given and the design concept expressed in the Contract Documents. The Architect's action shall be taken with such reasonable promptness 'as to cause no delay in the Work or in the con- struction of the Owner or of separate contractors, while allow- ing sufficient time in the Architect's professional judgment to permit adequate review. Review of such submittals is not con- ducted for the purpose of determining the accuracy and com- pleteness of other details such as dimensions and quantities or for substantiating instructions for installation or performance of equipment or systems designed by the Contractor, all of which remain the, responsibility of the Contractor to the extent required by the Contract Documents. The Architect's review shall not constitute approval of safety precautions or, unless otherwise specifically stated by the Architect, of construction means, methods, techniques, sequences or procedures. The Architect's approval of a •specific item shall not .indicate approval of an assembly of whichtheitem is a component. When professional certification of performance characteristics of materials, systems or equipment is required by' the Contract Documents, the Architect shall be entitled to rely upon such certification to establish that the materials, systems or equip- ment will meet the performance criteria required by the Con- tract Documents. 2.6.13 The Architect shall prepare Change Orders and Con- struction Change Directives with supporting documentation and data if deemed necessary by the Architect as provided in Subparagraphs 3.1.1 and 3.3.3, for the Owner's approval and execution in accordance with the Contract Documents, and may authorize minor changes in the Work not involving an adjustment in the Contract Sum or an extension of the Contract Time which are not inconsistent with the intent of the Contract Documents. 2.6.14 The Architect shall conduct inspections to determine the date or dates of Substantial Completion and the date of final completion, shall receive and forward to the Owner for the Owner's review and records written warranties and related documents required by the Contract Documents aid assem- bled by the Contractor, and shall issue a final Certificate for Pay- ment upon compliance with the requirements of the Contract Documents. S 3 8141-1987 AIA DOCUMENT B141 • OWNER -ARCHITECT AGREEMENT • FOURTEENTH EDITION • AIA® • ©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 WARNING: Unlicensed photocopying violates U.S. copyright laws and is subject to legal prosecution. • • • 2.6.15 The Architect shall interpret and decide matters con- cerning performance of the Owner and Contractor under the requirements of the Contract Documents on written request of either the Owner or Contractor. The Architect's response to such requests shall be made with reasonable promptness and within any time limits agreed upon. 2.6.16 Interpretations and decisions of the Architect shal] be consistent with the intent of and reasonably inferable from the Contract Documents and shall be in writing or in the form of drawings. When making such interpretations and initial deci- sions, the Architect shall endeavor to secure faithful perfor- mance by both Owner and Contractor, shall not show partiality to either, and shall not be liable for results of interpretations or decisions so rendered in good faith. 2.6.17 The Architect's decisions on matters relating to aesthe- tic effect shall be final if consistent with the intent expressed in the Contract Documents. 2.6.18 The Architect shall render written decisions within a reasonable time on all claims, disputes or other matters in ques- tion between the Owner and Contractor relating to the execu- tion or progress of the Work as provided in the Contract Documents. 2.6.19 The Architect's decisions on claims, disputes or other matters, including those in question between the Owner and Contractor, except for those relating to aesthetic effect as pro- vided in Subparagraph 2.6.17, shall be subject to arbitration as provided in this Agreement and in the Contract Documents. ARTICLE 3 ADDITIONAL SERVICES 3.1 GENERAL. 3.1.1 The services described in this Article 3 are not included in Basic Services unless so identified in Article 12, and they shall be paid for by the Owner as provided in this Agreement, in addition to the compensation for Basic Services. The services described under Paragraphs 3.2 and 3.4 shall only be provided if authorized or confirmed in writing by the Owner. If services described under Contingent Additional Services in Paragraph 3.3 are required due to circumstances beyond the Architect's control, the Architect shall notify the Owner prior to com- mencing such services. If the Owner deems that such services described under Paragraph 3.3 are not required, the Owner shall give prompt written notice to the Architect. If the Owner indicates in writing that all or part of such Contingent Addi- tional Services arc not required, the Architect shall have no obli- gation to provide those services. 3.2 PROJECT REPRESENTATION BEYOND BASIC SERVICES 3.2.1 If more extensive representation at the site than is described in Subparagraph 2.6.5 is required, the Architect shall provide one or more Project Representatives to assist in carry- ing out such additional on-site responsibilities. 3.2.2 Project Representatives shall be selected, employed and directed by the Architect, and the Architect shall be compen- sated therefor as agreed by the Owner and Architect. The dudes, responsibilities and limitations of authority of Project Representatives shall be as described in the edition of AIA Document B352 current as of the date of this Agreement, unless otherwise agreed. 3.2.3 Through the observations by such Project Represen- tatives, the Architect shall endeavor to provide fufther protec- tion for the Owner against defects and deficiencies in the Work, but the furnishing of such project representation shall not modify the rights, responsibilities or obligations of the Architect as described elsewhere in this Agreement. 3.3 CONTINGENT ADDITIONAL SERVICES 3.3.1 Making revisions in Drawings, Specifications or other documents when such revisions are: .1 inconsistent with approvals or instructions previously given by the Owner, including revisions made neces- sary by adjustments in the Owner's program or Proj- ect budget; .2 required by the enactment or revision of codes, laws or regulations subsequent to the preparation of such documents; or .3 due to changes required as a result of the Owner's fail- ure to render decisions in a timely manner. 3.3.2 Providing services required because of significant changes in the Project including, but not limited to, size, qual- ity, complexity, the Owner's schedule, or the method of bid- ding or negotiating and contracting for construction, except for services required under Subparagraph 5.2.5. 3.3.3 Preparing Drawings, Specifications and other documen- tation and supporting data, evaluating Contractor's proposals, and providing other services in connection with Change Orders and Construction Change Directives. 3.3.4 Providing services in connection with evaluating substi- tutions proposed by the Contractor and making subsequent revisions to Drawings, Specifications and other documentation resulting therefrom. 3.3.5 Providing consultation concerning replacement of Work damaged by fire or other cause during construction, and fur- nishing services required in connection with the replacement of such Work. 3.3.6 Providing services made necessary by the default of the Contractor, by major defects or deficiencies in the Work of the Contractor, or by failure of performance of either the Owner or Contractor under the Contract for Construction. 3.3.7 Providing services in evaluating an extensive number of claims submitted by the Contractor or others in connection with the Work. 3.3.8 Providing services in connection with a public hearing, arbitration proceeding or legal proceeding except where the Architect is party thereto. 3.3.9 Preparing documents for alternate, separate or sequential bids or providing services in connection with bidding, negotia- tion or construction prior to the completion of the Construc- tion Documents Phase. 3.4 OPTIONAL ADDITIONAL SERVICES 3.4.1 Providing analyses of the Owner's needs and program- ming the requirements of the Project. 3.4 2 Providing financial feasibility or other special studies. 3.4.3 Providing planning surveys, site evaluations or corn- parative studies of prospective sites. AIA DOCUMENT B141 • OWNER -ARCHITECT AGREEMENT • FOURTEENTH EDITION • MA° • 01987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 WARNING: Unlicensed photocopying violates U.S. copyright laws and Is subject to legal prosecution. B141-1987 4 • 3.4.4 Providing special surveys, environmental studies and submissions required for approvals of governmental authorities or others having jurisdiction over the Project. 1 , 3.4.5 Providing services relative to future facilities, systems and equipment. 3.4.6 Providing services to investigate existing conditions or facilities or to make measured drawings thereof. 3.4.7 Providing services to verify the accuracy of drawings or other information furnished by the Owner. 3.4.8 Providing coordination of construction performed by separate contractors or by the Owner's own forces and coordi- nation of services required in connection with construction performed and equipment supplied by the Owner. 3.4.9 Providing services in connection with the work of a con- struction manager or separate consultants retained by the Owner. 3.4.10 Providing detailed estimates of Construction Cost. 3.4.11 Providing detailed quantity surveys or inventories of material, equipment and labor. 3.4.12 Providing analyses of owning and operating costs. 3.4.13 Providing interior design and other similar services required for or in connection with the selection, procurement or installation of furniture, furnishings and related equipment. 3.4.14 Providing services for planning tenant.or rental spaces. 3.4.15 Making investigations, inventories of materials or equip- ment, or valuations and detailed appraisals of existing facilities. 3.4.16 Preparing a set of reproducible record drawings show- ing significant changes in the Work made during construction based on marked -up prints, 'drawings and other data furnished by the Contractor to the Architect. 3.4.17 Providing assistance in the utilization of equipment or systems such as testing, adjusting and balancing, preparation of operation and maintenance manuals, training personnel for operation and maintenance, and consultation during operation. 3.4.18 Providing services after issuance to the Owner of the final Certificate for Payment, or in the absence of a final Cer- tificate for Payment, more than 60 days after the date of Sub- stantial Completion of the Work. 3.4.19 Providing services of consultants for other than archi- tectural, structural,' mechanical and electrical engineering por- tions of the Project provided as a part of Basic Services. 3.4.20 Providing any other services not otherwise included in this Agreement or not customarily furnished in accordance with generally accepted architectural practice. ARTICLE 4 OWNER'S RESPONSIBILITIES 4.1 The Owner shall provide full information regarding requirements for the Project, including a program which shall set forth the Owner's objectives, schedule,,constraints and cri- teria, including space requirements and relationships, flexi- bility, expandability, special equipment, systems and site requirements. • 4.2 The Owner shall establish and update an overall budget for the Project, including the Construction Cost, the Owner's other costs and reasonable contingencies related to all of these costs. 4.3 If requested by the Architect, the Owner shall furnish evi- dence that financial arrangements have been made to. fulfill the Owner's obligations under this Agreement. i 4.4 The Owner shall designate a representative authorized to act on the Owner's behalf with respect to the Project. The Owner or such authorized representative shall render decisions in a timely manner pertaining to documents submitted by the Architect in order to avoid unreasonable delay in the orderly and sequential progress of the Architect's services. 4.5 The Owner. shall furnish surveys describing physical characteristics, legal limitations and utility locations for the site of the Project; and a written legal description of the site. The surveys and legal information shall include, as applicable, grades and lines of streets, alleys, pavements and adjoining property and structures; adjacent drainage; rights-of-way, restrictions, easements, encroachments, zoning, deed restric- tions, boundaries and contours of the site; locations, dimen- sions and necessary data pertaining to existing buildings, other improvements and trees; and information concerning available utility services and lines, both public and private, above and below grade, including inverts and depths. All the information on the survey shall be referenced to a Project benchmark. 4.6 The Owner shall furnish the services of geotechnical engi- neers when such services are requested by the Architect. Such services may include but are not limited to test borings, test pits,. determinations of soil bearing values, percolation tests, evaluations of hazardous materials, ground corrosion and resis- tivity tests, including necessary operations for ariticipating sub- soil conditions, with reports and appropriate professional recommendations. 4.6.1 The Owner shall furnish the services of other consul- tants when such services are reasonably required by the scope of the Project and are requested by the Architect. 4.7 The Owner shall furnish structural, mechanical, chemical, air and water pollution tests, tests for hazardous materials, and other laboratory and environmental tests, inspections and reports required by law or the Contract Documents. 4.8 The Owner shall furnish all legal, accounting and insurance counseling services as may be necessary at any time for the Project, including auditing services the Owner may require to 'verify.the Contractor's Applications for Payment or to ascertain how or for what purposes the Contractor has used the money paid by or on behalf of the Owner. 4.9 The services, information, surveys and reports required by Paragraphs 4.5 through 4.8 shall be furnished at the Owner's expense, and the Architect shall be entitled to rely upon the accuracy and completeness thereof. • 4.10 Prompt written notice shall be given by the Owner to the Architect if the Owner becomes aware of any fault or defect in the Project or nonconformance with the Contract Documents. 4.11 The proposed•language of certificates or certifications requested of the Architect or Architect's consultants shall be submitted to. the Architect for review and approval at least 14 days prior to execution. The Owner shall nor request certifica- tions that would require knowledge or services beyond the scope of this Agreement. 5 B141-1987 AIA DOCUMENT 8141 • OWNER -ARCHITECT AGREEMENT • FOURTEENTH EDITION • AIA • ©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 WARNING: Unlicensed photocopying violates U.S. copyright laws and Is subject to legal prosecution. • • • • ARTICLE 5 CONSTRUCTION COST 5.1 DEFINITION 5.1.1 The Construction Cost shall be the total cost or esti- mated cost to the Owner of all elements of the Project designed or specified by the Architect. 5.1.2 The Construction Cost shall include the cost at current market rates of labor and materials furnished by the Owner and equipment designed, specified, selected or specially provided for by the Architect, plus a reasonable allowance for the Con- tractor's overhead and profit. In addition, a reasonable allow- ance for contingencies shall be included for market conditions at the time of bidding and for changes in the Work during construction. 5.1.3 Construction Cost does not include the compensation of the Architect and Architect's consultants, the costs of the land, rights-of-way, financing or other costs which are the respon- sibility of the Owner as provided in Article 4. 5.2 RESPONSIBILITY FOR CONSTRUCTION COST 5.2.1 Evaluations of the Owner's Project budget, preliminary estimates of Construction Cost and detailed estimates of Con- struction Cost, if any, prepared by the Architect, represent the Architect's best judgment as a design professional familiar with the construction industry. It is recognized, however, that nei- ther the Architect nor the Owner has control over the cost of labor, materials or equipment, over the Contractor's methods of determining bid prices, or over competitive bidding, market or negotiating conditions. Accordingly, the Architect cannot and does not warrant or represent that bids or negotiated prices will not vary from the Owner's Project budget or from any estimate of Construction Cost or evaluation prepared or agreed to by the Architect. 5.2.2 No fixed limit of Construction Cost shall be established as a condition of this Agreement by the furnishing, proposal or establishment of a Project budget, unless such fixed limit has been agreed upon in writing and signed by the parties hereto. If such a fixed limit has been established, the Architect shall be permitted to include contingencies for design, bidding and price escalation, to determine what materials, equipment, com- ponent systems and types of construction are to be included in the Contract Documents, to make reasonable adjustments in the scope of the Project and to include in the Contract Docu- ments altemate bids to adjust the Construction Cost to the fixed limit. Fixed limits, if any, shall be increased in the amount of an increase in the Contract Sum occurring after execution of the Contract for Construction. 5.2.3 If the Bidding or Negotiation Phase has not commenced within 90 days after the Architect submits the Construction Documents to the Owner, any Project budget or fixed limit of Construction Cost shall be adjusted to reflect changes in the general level of prices in the construction industry between the date of submission of the Construction Documents to the Owner and the date on which proposals are sought. 5.2.4 If a fixed limit of Construction Cost (adjusted as pro- vided in Subparagraph 5.2.3) is exceeded by the lowest bona fide bid or negotiated proposal, the Owner shall: . 1 give written approval of an increase in such fixed limit; . 2 authorize rebidding or renegotiating of the Project within a reasonable time; .3 if the Project is abandoned, terminate in accordance with Paragraph 8.3; or .4 cooperate in revising the Project scope and quality as required to seduce the Construction Cost. 5.2.5 If the Owner chooses to proceed under Clause 5.2.4.4, the Architect,XJGdIlYt11MX36)40X%%r +. shall modify the Con- tract Documents as necessary to comply with the fixed limit, if established as a condition of this Agreement. The modification of Contract Documents shall be the limit of the Architect's responsibility arising out of the establishment of a fixed limit. The Architect shall be entitled to compensation in accordance with this Agreement for all services performed whether or not the Construction Phase is commenced. ARTICLE 6 USE OF ARCHITECT'S DRAWINGS, SPECIFICATIONS AND OTHER DOCUMENTS 6.1 The Drawings, Specifications and other documents pre- pared by the Architect for this Project are instruments of the Architect's service for use solely with respect to this Project and, unless otherwise provided, the Architect shall be deemed the author of these documents and shall retain all common law, statutory and other reserved rights, including the copyright. The Owner shall be permitted to retain copies, including repro- ducible copies, of the Architect's Drawings, Specifications and other documents for information and reference in connection with the Owner s use and occupancy of the Project. The Archi- tect's Drawings, Specifications or other documents shall not be used by the Owner or others on other projects, for additions to this Project or for completion of this Project by others, unless the Architect is adjudged to be in default under this Agreement, except by agreement in writing and with appropriate compen- sation to the Architect. 6.2 Submission or distribution of documents to meet official regulatory requirements or for similar purposes in connection with the Project is not to be construed as publication in deroga- tion of the Architect's reserved rights. DELETED xxefflaalxxx XX1WBITRAMD W X Claims, disputes or other matters in question between t partto this Agreement arising out of or relating to this ' . ce- ment o each thereof shall be subject to and decide • •y arbi- tration in a ordance with the Construction Ind : ry Arbitra- tion Rules of t American Arbitration Associ. '.n currently in effect unless the p.. ies mutually agree of - wise 7.2 Demand for arbitr. '•n shall b " ed in writing with the other party to this Agreem- •t a • with the American Arbitra- tion Association. A demand fo bitration shall be made within a reasonable time after claim, . ispute or other matter in question has arisen. In .. event shall t - demand for arbitration be made after the • to when institution > legal or equitable proceedings b. ri on such claim, dispute • other matter in question wo .. be barred by the applicable starlit.: •f limitations. 7.3 N' _ bitration arising out of or relating to this A: ment sh.. include, by consolidation, joinder or in any other m. • er additional person or entity not a party to this Agreemen AIA DOCUMENT 8141 • OWNER -ARCHITECT AGREEMENT • FOURTEENTH EDITION • AIAS • ©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 WARNING: Unlicensed photocopying violates U.S. copyright laws and is subject to legal prosecution. 8141-1987 6 DELETED ept.by written consent containing a specific reference this : eement signed by the Owner, Architect, and an .cher person o -miry sought to be joined. Consent to .itration involving an . ditional person or entity shall t constitute consent to arbitr. 'm of any claim, disput- .r other matter in question not describe. 'n the written c. ent or with a person or entity not named or d - 'bed t ein; The foregoing agree- ment to arbitrate and other . ements to arbitrate with an additional person or entity i y c., -nted to by the parties to this Agreement shall b- pecifically e • ceable in accordance with applicable laany court having j ' diction thereof. 7.4 The aw i rendered by the arbitrator or arbi : ors shall be final, . • udgment may be entered upon it in actor. . • e with ap. .ble law in any court having jurisdiction thereof. ARTICLE 8 . TERMINATION, SUSPENSION 6R ABANDONMENT 8.1 This Agreement may be terminated. by either party upon not less than seven days' written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination. 8.2 If the Project is suspended by the Owner for more than 30 consecutive days, the Architect shall be compensated for ser- vices performed prior to notice of such suspension. When the Project is resumed, the Architect's compensation shall be equi- tably adjusted to provide for expenses incurred in the interrup- tion and resumption of the Architect's services. • 8.3 This Agreementmaybe terminated by the Owner upon not less than seven days' written notice to the Architect in the event that the Project is permanently abandoned. If the Project is abandoned bythe Owner for more than 90 consecutive days, the Architect may terminate this Agreement by giving written notice. • 8.4 Failureofthe Owner to make payments to the•Architect in accordance with this Agreement shall be considered substantial nonperformance and cause for termination. - l 8.5 If the Owner fails to make payment when due the Archi- tect for services and expenses, the Architect may, upon seven days' written notice to the Owner, suspend performance of ser- vices under this Agreement: •Unless •payment in full is received by the Architect within.sev.en.days, of the date of the notice, the suspension shall take effect. without further notice. In the event of a .suspension of services, the Architect shall have no liability to.the Owner for delay or damage caused the Owner because of such suspension of services. 8.6 In the event of termination not the fault of the Architect, the Architect shall be compensated for services performed prior to termination, together with Reimbursable Expenses then due and all Termination Expenses as defined in Paragraph 8.7. 8.7 Termination Expenses are in addition to compensation for Basic and Additional Services, and include expenses which are directly attributable to termination: Termination Expenses shall be computed as a percentage of the total compensation for Basic Services and Additional Services earned to the time of ter- mination, as follows: .1 Twenty percent of the total compensation for Basic and Additional Services earned to date if termination occurs before or during the predesign, site analysis, or Schematic Design Phases; or • 1 • . 2 Ten percent of the total compensation for Basic and Additional Services earned to date if termination occurs during the Design Development Phase; or . 3 Five percent of the total compensation for Basic and Additional Services earned to date if termination occurs during any subsequent phase. ARTICLE 9' MISCELLANEOUS PROVISIONS • 9.1 Unless otherwise. provided, this Agreement shall be gov- erned by the law of: the • principal place of business of the Architect. 9.2 Terms in this Agreement shall have the same meaning as those in AIA Document A201, General Conditions of the Con- tract for Construction, current as of the date of this Agreement. 9.3 Causes of action between the parties to this Agreement pertaining to acts or failures to act shall be .deemed to have accrued and the applicable statutes of limitations shall com- menceto run not later than either the date of Substantial Com- pletion for acts or failures to act occurring prior to Substantial Completion, or the date of issuance of the final Certificate for Payment for acts or failures to act occurring after Substantial Completion. • • 9.4 The Owner and Architect waive all rights against each other and against .the contractors, consultants, agents and employees of the other for damages, but only to the extent cov- ered by property insurance during construction, except such rights as they may have to the proceeds of such insurance as set forth in the edition of AIA Document A201, General Conditions of the Contract for Construction, current as of the date of this Agreement. The Owner and Architect each shall require similar waivers from their contractors, consultants and agents. • 9.5 The Owner and Architect, respectively, bind themselves, their partners, successors, assigns and legal representatives to the other party to this Agreement and to the partners, succes- sors, assigns and legal representatives of such other party with 'respect to all covenants of this Agreement. Neither Owner nor Architect shall assign this Agreement without the written con- sent of the other. 9.6 This Agreement represents the entire and integrated agree- ment between the Owner and Architect and supersedes all prior negotiations, representations or agreements, either writ- ten or oral. This Agreement may be amended only by written instrument signed by both Owner and Architect. 9.7 Nothing contained in this Agreement shall create a contrac- tual relationship with or a cause of action in favor of a third party against either the Owner or Architect. 9.8 Unless otherwise provided in this Agreement, the Architect and Architect's consultants shall have no responsibility for the discovery, presence, handling, removal or disposal of or expo- sure of persons to hazardous materials in any form at the Project site, induding but not limited to asbestos, asbestos products, polychlorinated biphenyl (PCB) or other toxic substances. 9.9 The Architect shall have the right to include representa- tions of the design of the Project, including photographs of the exterior and interior, among the Architect's promotional and professional materials. The Architect's materials shall not include the Owner's confidential or proprietary information if the Owner has previously advised the Architect in writing of 7 . B141-1987 AIA DOCUMENT B141 • OWNER -ARCHITECT AGREEMENT • FOURTEENTH EDITION • AIA® ©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 WARNING: Unlicensed photocopying violates U.S. copyright laws and is subject to legal prosecution. • • r • the specific information considered by the Owner to be confi- dential or proprietary. The Owner shall provide professional credit for the Architect on the construction sign and in the pro- motional materials for the Project. ARTICLE 10 PAYMENTS TO THE ARCHITECT 10.1 DIRECT PERSONNEL EXPENSE 10.1.1 Direct Personnel Expense is defined as the direct salaries of the Architect's personnel engaged on the Project and the portion of the cost of their mandatory and customary con- tributions and benefits •related thereto, such as employment taxes and other statutory employee benefits, insurance, sick leave holidays, vacations, pensions and similar contributions and benefits. 10.2 REIMBURSABLE EXPENSES 10.2.1 Reimbursable Expenses are in addition to compensa- tion for Basic and Additional Services and include expenses incurred by the Architect and Architect's employees and con- sultants in the interest of the Project, as identified in the follow- ing Clauses. 10.2.1.1 Expense of transportation in connection with the Project; expenses in connection with authorized out-of-town travel; long-distance communications; and fees paid for secur- ing approval of authorities having jurisdiction over the Project. 10.2.1.2 Expense of reproductions, postage and handling of Drawings, Specifications and other documents. 10.2.1.3 If authorized in advance by the Owner, expense of overtime work requiring higher than regular rates. 10.2.1.4 Expense of renderings, models and mock-ups requested by the Owner. 10.2.1.5 Expense of additional insurance coverage or limits, including professional liability insurance, requested by the Owner in excess of that normally carried by the Architect and Architect's consultants. 10.2.1.6 Expense of computer-aided design and drafting equipment time when used in connection with the Project. 10.3 PAYMENTS ON ACCOUNT OF BASIC SERVICES 10.3.1 An initial payment as set forth in Paragraph 11.1 is the minimum payment under this Agreement. 10.3.2 Subsequent payments for Basic Services shall be made monthly and, where applicable, shall be in proportion to ser- vices performed within each phase of service, on the basis set forth in Subparagraph 11.2.2. 10.3.3 If and to the extent that the time initially established in Subparagraph 11.5.1 of this Agreement is exceeded or extended through no fault of the Architect, compensation for any ser- vices rendered during the additional period of rime shall be computed in the manner set forth in Subparagraph 11.3.2. 10.3.4 When compensation is based on a percentage of Con- struction Cost and any portions of the Project are deleted or otherwise not constructed, compensation for those portions of the Project shall be payable to the extent services are per- formed on those portions, in accordance with the schedule set forth in Subparagraph 11.2.2, based on (1) the lowest bona fide bid or negotiated proposal, or (2) if no such bid or proposal is received, the most.recent preliminary estimate of Construction Cost or detailed estimate of Construction Cost for such por- tions of the Project. 10.4 PAYMENTS ON ACCOUNT OF ADDITIONAL SERVICES 10.4.1 Payments on account of the Architect's Additional Services and for Reimbursable Expenses shall be made monthly upon presentation of the Architects statement of services ren- dered or expenses incurred 10.5 PAYMENTS WITHHELD 10.5.1 No deductions shall be made from the Architect's com- pensation on account of penalty, liquidated damages or other sums withheld from payments to contractors, or on account of the cost of changes in the Work other than those for which the Architect has been found to be liable. 10.6 ARCHITECT'S ACCOUNTING RECORDS 10.6.1 Records of Reimbursable Expenses and expenses per- taining to Additional Services and services performed on the basis of a multiple of Direct Personnel Expense shall be avail- able to the Owner or the Owner's authorized representative at mutually convenient times. ARTICLE 11 BASIS OF COMPENSATION The Owner shall compensate the Architect as follows: 1LXXXWANIONAMMIXIXXXXXXX VX�f Xi4KKXXOt mm»KdGXsX g`EXa'e*iXQYXa1X(X31Yd(d414d( 14tXt8XtXd(�YvSAXAMAX XXXIe7 X XY�X VXXXXXXXXXXXXXXXX 11.2 BASIC COMPENSATION 11.2.1 FOR BASIC SERVICES, as described in Article 2, and any other services included in Article 12 as part of Basic Services, Basic Compensation shall be computed as follows: (Insert basis of compensation, including stiprdated sums, multiples or percentages, and identify plusses to which particular methods of compensation apply, if neces#t7t) Fees for individual projects will be based on the scope of work .and.fee .agreement set out in individual Work Orders agreed to by both parties for each project. See Article 12 for adittional information. AIA DOCUMENT 0141 • OWNER -ARCHITECT AGREEMENT • FOURTEENTH EDITION • AIA® • ©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 WARNING: Unlicensed photocopying violates U.S. copyright laws and is subject to legal prosecution. B141-1987 8 • • 11.2.2 Where compensation is based on a -stipulated sum or percentage of Construction Cost, progress payments for Basic Services in each phase shall total the following percentages of the total Basic Compensation payable: (Insert additional phases as appropriate) - - Schematic Design Phase: Design Development Phase: Construction Documents Phase: Bidding or NegotiationPhase: Construction Phase: percent'(15 %) percent (20 %) percent (40%) percent ( 5%) , percent (20 %) Total Basic Compensation: - - 11.3 COMPENSATION FOR ADDITIONAL SERVICES one hundred percent (100%) • s. 11.3.1 FOR PROJECT REPRESENTATION BEYOND BASIC SERVICES as described in Paragraph 3.2, compensation shall be com- puted as follows: • Employees' time at a multiple of two and three fourths (2.75) times their Direct Personnel Expense as defined in paragraph 10.1 • 11.3.2 FOR ADDITIONAL SERVICES OF THE ARCHITECT, as described in Articles 3 and 12, other than (1) Additional Project Representation, as described in Paragraph 3.2, and (2) services included in Article 12 as part of Basic Services, but.excluding services of consultants, compensation shall be computed as follows: • (Insert basis of compensation, includingrates and/or multiples of Direct Personnel Expense for Principals and employees. and identify Principals and classify enployees, if required- identify specific services to which particular methods of compensation apply if necessary) Employees' time at a multiple of two and three fouths (2.75) times their Direct Personnel Expense as defined in paragraph 10.1 11.3.3 FOR ADDITIONAL SERVICES OF CONSULTANTS, including additional structural, mechanical and electrical engineering services and those provided under Subparagraph 3.4.19 or identified in Article 12 as part of Additional Services, a multiple of one & one fourth ( 1.25 ) times the amounts billed to the Architect for such services. (Identify specific types of consultants in Article 12, if required.) 11.4 REIMBURSABLE EXPENSES 11.4.1 FOR REIMBURSABLE EXPENSES, as described in Paragraph 10.2, and any other items included in Article 12 as Reimbursable Expenses, a multiple of one ( 1.00) times the expenses incurred by the Architect, the Architect's employees and consultants in the interest of the Project. 11.5 . ADDITIONAL PROVISIONS ..,.,... .......,_.....yr. ....................................,....., . ...... .. , .. fl. P• . , 11.5.1 IF THE BASIC SERVICES covered by this Agreement have not been completed within thirth-six ( • 36 ) months of the date hereof, through no fault of the Architect, extension of the Architect's services beyond that time shall be compensated as provided in Subparagraphs 10.3.3 and 11.3.2. • 11.5.2 Payments are due and payable th 1 rty.. -° (3^ = ') days from the date of the Architect's invoice. ITIMPX9Cr itXXXr,XXXXU XXXXxx, O XXXOrKgrXR x grOP�p�4t x R ORIXIXXXx 11,86 5fXk .YR kSE �tSI `XY n i�E`k.k 'HI tk �kRYQ- XRk'X�X5c �Ficxxxxxxxxx (`gYIffif`R'k 1 YYRYTArY kx., • (Usury laws and requirements under the Federal Truth in Lending Act, similar stateand.local consumer credit laws audother regulations.at theOwners and Archi- tect's principal places of business, the location of the Pmject and elsewhere may affect the validity of this lirovision. Specific legal advice should be obtained with respect to deletions or modifications, and also regarding requirements such as written disclosures or waivers) 9 6141-1987 AIA DOCUMENT B141 • OWNER -ARCHITECT AGREEMENT • FOURTEENTH EDITION • AIA® • ©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 . WARNING: Unlicensed photocopying violates U.S. copyright laws and is subject to legal prosecution. • • 11.5.3 The rates and multiples set forth for Additional Services shall be annually adjusted in accordance with normal salary review practices of the Architect. ARTICLE 12 OTHER CONDITIONS OR SERVICES (Insert descriptions of other services, identify Additional Services included within Basic Compensation and modifications to the payment and compensation terms included in this Agreement.) 12.1 The scope of work and fee for each individual project to be completed under this Agreement is to be determined by a written Work Order for each project. Upon acceptance by both parties each agreed to Work Order will be subject to the conditions of this contract Articles 1 thru 12. 12.2 The scope of work for this contract including all Work Orders is to include Improvements and Renovations to various Parks for a total overall budget not to exceed"$600,000.00 12.3 Work required in each Work Order will be billed by the hour using the attached Hourly Rate Schedule. The Total Fee for all Work Orders is not to exceed $75,000.00, not including Reimbursable Expenses. 12.4 The Total amount for Reimbursable Expenses as described in Article:10 is not to exceed $10,000.00. This Agreement entered into as of the day and year first written above. OWNER ARCHITECT (Signalise) Mr. Fred Hanna Mayor, City of Fayetteville (Printed name and title) AIA (Si4nature) Mr. Richard Alderman Principal, Northwest Arkansas Office WD&D (Prt'nted name and title) CAUTION: You should sign an original AIA document which has this caution printed in red. An original assures that changes will not be obscured as may occur when documents are reproduced. AIA DOCUMENT B141 • OWNER -ARCHITECT AGREEMENT • FOURTEENTH EDITION • AIA • ©19S7 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 WARNING: Unlicensed photocopying violates U.S. copyright laws and Is subject to legal prosecution. B141-1987 10 • P. .17 • • • WITTENBERG. DELONY & DAVIDSON. INC. Architecture Planning Interior Design Northwest Arkansas Office • 100 West Center / Suite 102 • Fayetteville. Alt 72701 • FAX 501/443-9515 • 501/443-6666 ATTACHMENT #1 HOURLY RATE SCHEDULE CITY OF FAYETTEVILLE PARKS IMPROVEMENTS PROJECTS APRIL 30TH, 1996 Principal $100.00 Principal Architect $ 80.00 Project Job Captain $ 70.00 Project Designer $ 50.00 Specification Writer $ 50.00 Project Construction Coordinator $ 55.00 Project Job Site Representative $ 55.00 _ AGENDA REQUEST X CONTRACT REVIEW GRANT REVIEW For the STAFF REVIEW -FORM Fayetteville City Council w,'Neh6e4y, 0,e/on yd DQriidssii • 6-/8'14 Res. 6 7-9d 4ior g ors / pi.. Ks iCROFiLM b meeting of FROM: Dale D. Clark Parks and Recreation Name Division p„hl i c works Department ACTION REQUIRED: Request approval of _Work Order #1 for improvements and renova- tions to Gulley and Davis Park based on a proposed budget of $39,000 for Gulley Park and $79,100 for Davis Park and to approve a budget adiustrnent recognizing a grant award of $30,000 from Arkansas Dept of Parks and Tourism_ This work order is COST TO CITY: for Wittenburg, Delony, and Davidson and is not to exceed $15,00 $ 118,100 Cti) Cost of this Request See Attached Account Number .CPP Pttarhad Project Number $ 187.824 (see attached) Category/Project Budget $ 0 Funds Used To Date $ 187,821 Remaining Balance 0 park Tmrrn..emen*s Category/Project Name Program Name Parks Development Fund and Sales Tax Capital Impr Fnd Fund BUDGET REVIEW: Budgeted Item x Budget Adjustment Attached Budg4t Coordinator Administrative Services Director CONTRACT/GRANT/LEASE /L(..!✓ Accou` ein= Mange 7,4 side. _ • • ity Attorney Purchasing Officer REVIEW: 6i36/6 GRANTING AGENCY: Date In/ernal Auditor 4)-1-1 9(o Date Date9k 1, Date STAFF RECOMMENDATION: Department Director Administra i've S ices Director /^ / / w Mayor Date Date Date Cross Reference New Item: Yes NO Prev Ord/Res $ : %2 P.S 6 ) - 9,G Orig Contract Date: • Schedule of Parks Funding for Gulley and Davis Parks Project # Description 96,031 95,015 96,029 94,017 (See Note) 96,096 Total • Cost of This Req Budget Amount Funds Used to Date Funds Availabl 27,000 10,000 6,000 63,100 12,000 118,100 27,000 22,324 41,400 22,100 75,000 187,824 0 0 0 0 0 0 27,000 22,324 41,400 22,100 75,000 187 824 Note: Funding for this project is from Sales Tax Capital Improvement Fund - $22,100, Green Space - $11,000 and a Grant Award of $30,000. • FAYETTEVIQLE THE CITY OF FAYETTEVILLE, ARKANSAS DEPARTMENTAL CORRESPONDENCE TO: Kevin Crosso, Public Works Director FROM: Dale D. Carks Director [ �" DATE• June 10, 1996 SUBJECT: Work Order #1 for Davis and Gulley Park On June 4, 1996 the city council passed a resolution awarding an engineering contract to Wittenburg, Delony and Davidson to provide architectural and engineering services for various CIP and HMR park projects and authorizing the mayor to sign each work order. Work Order #1 from Wittenburg, Delony, Davidson will involve park development at Davis Park and Gulley Park. Davis Park will utilize a grant from the Arkansas Department of Parks and Tourism. A basketball court, tot playground and ADA access will be developed. Also included in this project is the installation of two -rail wood fencing around the perimeter of the park and the creation of an attractive entrance way to the park. The Gulley Park development will include a parking lot, ADA access and a hydraulic study of the Gulley bridges to satisfy a requirement of FEMA. Please accept this contract review for Work Order #1. If you need any further information, please contact us. PROFESSIONAL SEO/ICES SUPPLEMENT • AIA DOCUMENT G604 (Instructions on reverse side) WORK ORDER #1 • In accordance with the AGREEMENT dated: Apri 1 30th, 1996 BETWEEN: The Owner: The City of Fayetteville, Arkansas and: The Architect: Wittenberg, Delony & Davidson, Inc. Fayetteville, Arkansas for the Project: (Insert Project name and address as it appears in the Agreement.) A contract for various projects over a one (1) year period at City of Fayetteville Parks. Cy7 authorization is Q(g(cj int 0 (given) (strike one) to proceed with Additional Services i n accordance with Article #12 0 to proceed with revised scope of Basic Services Q to incur Reimbursable Expenses OR O notification is made -. ( 0 of the need to proceed with Contingent Additional services ❑ of the need for other services AS FOLLOWS: Work Order #1 for Improvements and Renovations to Gulley and Davis Parks based on a proposed Owner's budget of $39,000.00 for Gulley Park and $79,100.00 for Davis Park. • The following adjustments shall be made to compensation and time. • Compensation: (Insert provisions in accordance with the Agreement, oras otherwise agreed bP the pansies) Hourly Expenses for Architectural Services in an amount A proposed reimbursable expense budget in the amount of Time: preen provisions covering time of commencement and completion of authorized services as applicable.) No change Prompt written notice is required if the services indicated are not needed. not to exceed $12,500.00. $2,500.00. SUBMITTED BY. (Signature) Richard Alderman Principal, Northwest AR Office WD&D (Printed name and title) 4-30-1996 (Date) AIA AUTHORIZATION IS GIVEN or NOTIFIA� C%I �ACKNOWLEDGED BY: e we) Mr.. Fred Hanna Mayor, City of Fayetteville (Signa (Panted name and title) (Date) Sune /8, /c/% CAUTION: You should sign an original AIA document which has this caution printed in red. An original assures that changes will not be obscured as may occur when documents are reproduced. See Instruction Sheet for Limited License for Reproduction of this document. AIA DOCUMENT G604 • PROFESSIONAL SERVICES SUPPLEMENT • Alit* • 01993 • THE AMERICAN INS11TWE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006-5292 • WARNING: Unlicensed photocopying violates U.S.copyright laws and will subject the violator to legal prosecution. G604-1993 INSTRUCTION SHEET. FOR AIA. DOCUMENT 6604, PROFESSIONAL. SERVICES SUPPLEMENT A. GENERAL INFORMATION 1. Purpose • AIA Document 0601 is intended w formalize the procedures for authorizing supplemental professional actions such as proceeding with Additional Services, expanding thc.scope. of Basic Services or incurring Reimbursable Expen.scs.9t`shouid only he used to record actions authorized in accordance with the Agreement between the parties for professional services. It will provide a written record of each author- ization, giving particulars of activities, compensation and time. 2. Limited License for Reproduction `AlA ihiatmen[ 0.604 isii.chpvi-ighted it ork and may' mit be reproduced -or exce>lited from in suhstdntial' part Tithuut the express written permission of the AL1. The 0604 document is intended to he used as a consumable—[hat is, the original document purchased by the user is intended to be consumed in the course of being used, There is no implied permission to reproduce this document, nor does member- ship in The American Institute of Architects confer any further rights to reproduce them. • A cautionary notice is printed in red on the original of this document This notice distinguishes an original AMA document from copies and counterfeits"1'viensure accuracy and uniformity of language, purchasers should use only an original AIA document or one that has been reproduced under a special limited license from the AIA. A limited license is hereby granted to retail purchasers to reproduce a maximum of ten copies cif a completed or executed 0604, but only for use in connection with a particular Project. G604 may not be reproduced for Project Manuals. Rather, if a user wishes to include it as an example in a Project Manual, the normal practice is to purchase a quantity of the printed forms and bind one in each of the Project Manuals. Partial modifications. if any, may he accomplished without completing the form by using separate Supplementary Conditions. B. CHANGES IN FORMAT AND CONTENT FROM THE PREVIOUS EDITION The 0601 document has been expanded to permit modification of both Owner -Architect and Architect -Consultant agreements. Two primary options are provided_ one requesting or granting authorization to take action not previously contemplated by an existing agreement, the other notffying•a party uh.afrexisting agreement that services not previously cohtemplated may he required: ' -- n C. COMPLETING THE GG04 FORM :The date to he filled in on the first line should he the date of the original Agreement between the paries. The document 15 appropriate for use by any two parties who have an agreement for professional services. Therefore, the Owner could author- ize the Architect to take some action, or the document could be used for Architect -Engineer, Architect -Interior Designer, or other relation- ships. The names of the parties should be indicated as they appear in the Agreement. Similarly, the Project's nairic and address'should he described 3s they ailifhear in the -Agreement. - ' " One or more actions maybe designated and each should be fully described under "AS FOLLOWS: Complete provisions for compensation and time should be listed Often, the basis of compensation will he covered in the Agreement, such as for Additional Services. Whether by reference, restatement or new agreement, full particulars of compensation and time should be included here. For. example: "Compensation for Additional Services shall be in accordance with Paragraph 11.3 of the Agreement"; The time for per- formance of Design Development services shall be extended by twenty-one (21) calendar days. _ If additional sheets are used to describe authorized action, compensation or time, these should be identified in the appropriate place, and the number of additional sheets should he stated. It is advisable for both parties to initial and date all such sheers. The G604 document should be signed in a manner consistent with that of the original Agreement In case of any question, it is appropriate to ascertain whether the other party has authority to authorize or agree to perform the activities contemplated herein. • 4,4 AIA DOCUMENT 6604 • INSTRUCTION SHEET FOR PROFESSIONAL. SERVICES SUPPLEMENT • 1903 EDITION • AIA' THE AMERICAN INsTfrIiTE OP ARCHIFECIs, 1735 NEW YORK AVENUE. N.W.- WASHINGTON, D.C. 20006-5292 G604-1993 •ity of Fayetteville, Arkansas Budget Adjustment Form Budget Year epartment: Sales Tax Capital Improvements 1996 ivision: rogram: _?dk Date Requested 06/13/96 Adjustment # Project or Item Requested: Approval of budget adjustment recognizing a grant award from Arkansas Department of Parks and Tourism and increasing the expenditure budget park improvements planned for Bryce (Davis) Park. Projector Item Deleted: None. Additional revenue and related project cost are being recognized. Justification of this Increase: The City has received notification of a matching grant award from the Arkansas Department of Parks and Tourism. Account Name Park Improvements Justification of this Decrease: No decrease is proposed. Additional revenue and related expenditure is being recognized. Increase Amount Account Number ..- • Project Number.. 30,000 4470 9470 5806 94017.47 Decrease State Grants Account Name 30,000 4470 0947 Approval Signatures Budget Office Use Onium ufr 7 4-(3-1. Budget rdinator Department Director Admin. Se A Date of Approval Posted to General Ledger Entered in Category Log. Mayor C:\APP\96BUD\DA VISBA. WKI Budget Office Copy June 12, 1995 • • STATE OF ARKANSAS OFFICE OF THE GOVERNOR State Capitol Little Rock 72201 The Honorable Fred Hanna Mayor of Fayetteville 113 West Mountain Fayetteville, Arkansas 72701 Dear Mayor Hanna: Jim Guy Tucker Governor The Department of Parks and Tourism's Outdoor Recreation Grants Advisory Committee has recommended that the City of Fayetteville be awarded a grant based on their 1995 application for matching grant funds. It gives me great pleasure to award the City of Fayetteville a matching grant in the amount of $30,000.00. This grant is to assist in the development of a picnic area, pavilion, playground, walking trail, and basketball court at Bryce Park. The Department of Parks and Tourism will contact you in the near future to explain what will be necessary to proceed with your project. I want to congratulate you on your efforts to provide quality outdoor recreation facilities for your citizens Sincerely, a. im Guy Tucker JGT:sc cc: Senator David Malone Representative Charles Stewart Richard W. Davies, Executive Director • Department of Parks and Tourism COPtIZ% Vai✓I D26tnwt, BAs t 3 PepT.