HomeMy WebLinkAbout73-73 RESOLUTIONRESOLUTION NO.73-73
A RESOLUTION AUTHORIZING AND DIRECTING THE CONDEMNATION
OF RIGHTS OF WAY AND EASEMENTS FOR CONSTRUCTION, INSTALLATION
AND MAINTENANCE OF WATER LINES LOCATED NEAR HIGHWAY 71 SOUTH.
WHEREAS, The City of Fayetteville, Arkansas, is in the
process of obtaining the easements and rights of way for a
proposed water line location in the area of Highway No. 71
South necessitating rights of way and easements over certain
lands in Washington County, Arkansas, for construction, installation,
and maintenance of said water lines being constructed under
said project.
NOW, THEREFORE, BE IT RESOLVED BY THE BOARD OF DIRECTORS
OF THE CITY OF FAYETTEVILLE, ARKANSAS:
Section 1. For the purpose of constructing, installing
operating and maintaining (as more fully set forth in the
contract documents pertaining to said project ) a water
line, the necessary easements and rights of way in the
lands of the owners designated on the official plans located
in the City Engineer's office, be entered upon and taken,
and the City Attorney i"s hereby authorized and directed to
institute:] condemnation proceedings to acquire said easements
and rights of way in the manner required by law.
Section 2. That the questions in controversy in such
proceedings are likely to retard the progress of such
construction, and the City Attorney is further. authorized
and directed to petition the court for permission to
provide appropriate deposits with the registry of the
court for making compensation and payment �f damages in
order that an immediate possession of said land may be
secured and construction proceed prior to assessment and
payment of damages.
Section 3. That this resolution shall be in full force
and effect from and after its passage and approval.
1973. PASSED AND APPROVED this 2151- day of Art
APPROVED:
ATTEST:
• ���MAYOR